GEP Damages Sample Clauses

GEP Damages. The Parties agree that the damages sustained by Xxxxx associated with Seller’s failure to achieve the Guaranteed Energy Production requirement would be difficult or impossible to determine, or that obtaining an adequate remedy would be unreasonably time consuming or expensive and therefore agree that Seller shall pay the GEP Damages to Buyer as liquidated damages. In no event shall Buyer be obligated to pay GEP Damages.
Sample 1Sample 2Sample 3See All (26)
AutoNDA by SimpleDocs
GEP Damages. If Seller actually delivers Generation Facility Bundled Green Energy during a Performance Measurement Period in an amount (together with (A) any deemed amounts set forth in the last sentence of Section 1.1.2(a) above during such Performance Measurement Period, and (B) GEP Damages Credited Amounts associated with the immediately-prior Performance Measurement Period) that is less than the Guaranteed Energy Production applicable to such Performance Measurement Period (“GEP Failure Event”), Seller shall be liable to Buyer for GEP Damages associated with such GEP Failure Event, which GEP Damages shall be paid by Seller no later than thirty (30) days following an invoice therefor by Xxxxx; provided that Buyer may instead elect to offset GEP Damages payable by Seller against future payments to be made to Seller under this Agreement or draw on Delivery Period Security for the payment thereof.
Sample 1

Related to GEP Damages

  • Direct Damages A PARTY’S DAMAGES RESULTING FROM A BREACH OR VIOLATION OF ANY REPRESENTATION, WARRANTY, COVENANT, AGREEMENT OR CONDITION CONTAINED IN THIS AGREEMENT OR ANY ACT OR OMISSION ARISING FROM OR RELATED TO THIS AGREEMENT SHALL BE LIMITED TO ACTUAL DIRECT DAMAGES AND SHALL NOT INCLUDE ANY OTHER LOSS OR DAMAGE, INCLUDING INDIRECT, SPECIAL, CONSEQUENTIAL, INCIDENTAL, EXEMPLARY OR PUNITIVE DAMAGES, INCLUDING LOST PROFITS, PRODUCTION, OR REVENUES, AND EACH PARTY RELEASES THE OTHER PARTY FROM ALL SUCH CLAIMS FOR LOSS OR DAMAGE OTHER THAN ACTUAL DIRECT DAMAGES; PROVIDED THAT THIS LIMITATION TO DIRECT DAMAGES SHALL NOT LIMIT THE PARTIES’ INDEMNIFICATION OBLIGATIONS UNDER Section 3.5(c), Section 7.3, AND Article 15.

  • Liability for Damages 1. The Purchaser shall be liable for any damages sustained by the State arising from Purchaser’s breach of the terms of this Contract and the State may cause all or part of the performance bond to be forfeited to recover such damages. 2. In the event that a portion of the timber sale under this Contract is resold as a result of the Purchaser’s forfeiture and the stumpage rate pursuant to the resold contract is lower than the stumpage rate provided herein, the difference between the original rate and the new rate shall be considered damages and the Purchaser shall be liable to the State for those damages. The State may cause all or part of the Purchaser’s performance bond to be forfeited to recover such damages.

  • Delay Damages If the Commercial Operation Date is not achieved by the date set forth therefor in Section 3.1(a) (as extended pursuant to Section 3.1(c)), Seller shall pay to Buyer damages for each month from and after such date until the Commercial Operation Date at the rate of $1.50 per kwh of Contract Maximum Amount up to a maximum of twelve (12) months of delay, pro rated for partial months (“Delay Damages”). Delay Damages shall be due under this Section 3.2(a) without regard to whether Buyer exercises its right to terminate this Agreement pursuant to Section 9.3; provided, however, that if Buyer exercises its right to terminate this Agreement under Section 9.3, Delay Damages shall be due and owing to the extent that such Delay Damages were due and owing at the date of such termination. If the Facility has not achieved the Commercial Operation by the date set forth therefor in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), for any reason, Seller shall have the right to terminate this Agreement at any time after that deadline date (as so extended) until either the Facility achieves the Commercial Operation Date or Buyer terminates this Agreement under Section 9.3 (regardless of whether or not Seller elected to continue to construct the Project). In the event Seller so terminates this Agreement, Seller shall be liable to Buyer on the date of such termination for (x) the entire amount of Delay Damages that would otherwise accrue (or have accrued) by such date plus (y) the undrawn amount of any Development Period Security provided to Buyer by Seller; provided, however, that if Seller terminates this Agreement on the deadline set forth for the Commercial Operation Date in Section 3.1(a) (as the same may be extended in accordance with Section 3.1(c)), Seller shall not be required to pay any Delay Damages hereunder but shall forfeit the Development Period Security. Subject to the foregoing sentence, neither Party shall have any liability to the other Party with respect to a termination of this Agreement by Seller under this Section 3.2(b). Each Party agrees and acknowledges that (i) the damages that Buyer would incur due to Seller’s delay in achieving the Commercial Operation Date would be difficult or impossible to predict with certainty, and (ii) it is impractical and difficult to assess actual damages in the circumstances stated, and therefore the Delay Damages and other damages as agreed to by the Parties and set forth herein are a fair and reasonable calculation of such damages. Notwithstanding the foregoing, this Article shall not limit the amount of damages payable to Buyer if this Agreement is terminated by Buyer as a result of Seller’s failure to achieve the Commercial Operation Date. Any such termination damages shall be determined in accordance with Article 9. By the tenth (10th) day following the end of the calendar month in which Delay Damages first become due and continuing by the tenth (10th) day of each calendar month during the period in which Delay Damages accrue (and the following months if applicable), Buyer shall deliver to Seller an invoice showing Buyer’s computation of such damages and any amount due Buyer in respect thereof for the preceding calendar month. No later than ten (10) days after receiving such an invoice, Seller shall pay to Buyer, by wire transfer of immediately available funds to an account specified in writing by Buyer or by any other means agreed to by the Parties in writing from time to time, the amount set forth as due in such invoice. If Seller fails to pay such amounts when due, Buyer may draw upon the Development Period Security for payment of such Delay Damages, and Buyer may exercise any other remedies available for Seller’s default hereunder.

  • Punitive Damages The Administrative Agent, the Lenders and the Borrower hereby agree that no such Person shall have a remedy of punitive or exemplary damages against any other party to a Loan Document and each such Person hereby waives any right or claim to punitive or exemplary damages that they may now have or may arise in the future in connection with any Dispute, whether such Dispute is resolved through arbitration or judicially.

  • Actual Damages Contractor is liable to CMHA for all actual and direct damages caused by Contractor’s default. In the event Contractor fails to provide services or material as provided for in the Contract Documents, CMHA may substitute the services and/or material from a third party. CMHA may recover the costs associated with acquiring substitute services and/or materials, less any expense or costs saved by Contractor’s default, from Contractor.

  • Special Damages NOTWITHSTANDING ANY OTHER PROVISION OF THIS AGREEMENT TO THE CONTRARY, AND EXCEPT AS PROVIDED BELOW, IN NO EVENT WILL EITHER PARTY OR ANY PERSON IN ITS GROUP BE LIABLE FOR SPECIAL, INCIDENTAL, INDIRECT, COLLATERAL, CONSEQUENTIAL OR PUNITIVE DAMAGES OR LOST PROFITS SUFFERED BY AN INDEMNITEE, HOWEVER CAUSED AND ON ANY THEORY OF LIABILITY, IN CONNECTION WITH ANY DAMAGES ARISING HEREUNDER OR THEREUNDER; PROVIDED, HOWEVER, THAT TO THE EXTENT AN INDEMNIFIED PARTY IS REQUIRED TO PAY ANY DAMAGES, INCLUDING SPECIAL, INCIDENTAL, INDIRECT, COLLATERAL, CONSEQUENTIAL OR PUNITIVE DAMAGES OR LOST PROFITS (OTHER THAN DAMAGES OR LOST PROFITS CONSTITUTING EXCLUDED LIABILITIES), TO A PERSON WHO IS NOT IN EITHER GROUP IN CONNECTION WITH A THIRD PARTY CLAIM, SUCH DAMAGES WILL CONSTITUTE DIRECT DAMAGES AND WILL NOT BE SUBJECT TO THE LIMITATION SET FORTH IN THIS SECTION 11.17.

  • Indirect Damages To the maximum extent permitted by Law, the Stripe Parties will not be liable to you or your Affiliates in relation to this Agreement or the Services during and after the Term (whether in contract, negligence, strict liability or tort, or on other legal or equitable grounds) for any lost profits, personal injury, property damage, loss of data, business interruption, indirect, incidental, consequential, exemplary, special, reliance, or punitive damages, even if these losses, damages, or costs are foreseeable, and whether or not you or the Stripe Parties have been advised of their possibility.

  • Monetary Damages In the event that the Partnership breaches its obligations set forth in Article 2, Article 3, or Article 6 with respect to a Protected Partner the Protected Partner’s sole right shall be to receive from the Partnership, and the Partnership shall pay to such Protected Partner as damages, an amount equal to: (a) in the case of a violation of Articles 3 or 0, xxx xxxxxxxxx xxxxxxx, xxxxx and local income taxes incurred by the Protected Partner or an Indirect Owner as a result of the income or gain allocated to, or otherwise recognized by, such Protected Partner with respect to its Units by reason of such breach; (b) in the case of a violation of Article 0, xxx xxxxxxxxx xxxxxxx xxxxx, and local income taxes incurred by the Protected Partner or an Indirect Owner with respect the Excess Protected Gain incurred with respect to the Gain Limitation Property that is allocable to such Protected Partner under the Partnership Agreement and Section 2.3 hereof (computed without regard to the principles set forth in the parenthetical in the first paragraph of Section 2.1); plus in the case of either (a) or (b), an amount equal to the aggregate federal, state, and local income taxes payable by the Protected Partner or an Indirect Owner as a result of the receipt of any payment required under this Section 4.1. For purposes of computing the amount of federal, state, and local income taxes required to be paid by a Protected Partner (or Indirect Owner), (i) any deduction for state income taxes payable as a result thereof actually allowed in computing federal income taxes shall be taken into account, and (ii) a Protected Partner’s (or Indirect Owner’s) tax liability shall be computed using the highest federal, state and local marginal income tax rates that would be applicable to such Protected Partner’s (or Indirect Owner’s) taxable income (taking into account the character and type of such income or gain) for the year with respect to which the taxes must be paid, without regard to any deductions, losses or credits that may be available to such Protected Partner (or Indirect Owner) that would reduce or offset its actual taxable income or actual tax liability if such deductions, losses or credits could be utilized by the Protected Partner (or Indirect Owner) to offset other income, gain or taxes of the Protected Partner(or Indirect Owner), either in the current year, in earlier years, or in later years).

  • Consequential Damages Neither party to this Agreement shall be liable to the other party for special, indirect or consequential damages under any provision of this Agreement or for any special, indirect or consequential damages arising out of any act or failure to act hereunder.

  • Exclusion of Consequential Damages ‌ Notwithstanding anything contained herein to the contrary, neither Party will be liable under this Agreement or under any cause of action relating to the subject matter of this Agreement for any special, indirect, incidental, punitive, exemplary or consequential damages, including loss of profits, loss of use of any property or claims of customers or contractors of the Parties for any such damages.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!