Grantees Personnel and Subcontractors Sample Clauses

Grantees Personnel and Subcontractors. Qualifications
AutoNDA by SimpleDocs
Grantees Personnel and Subcontractors. Qualifications Xxxxxxx agrees to maintain the organizational and administrative capacity and capabilities to carry out all duties and responsibilities under the Contract. Grantee Agents assigned to perform the duties and responsibilities under the Contract must be and remain properly trained and qualified for the functions they are to perform. Notwithstanding the transfer or turnover of personnel, Xxxxxxx remains obligated to perform all duties and responsibilities under the Contract without degradation and in strict accordance with the terms of the Contract.
Grantees Personnel and Subcontractors 

Related to Grantees Personnel and Subcontractors

  • Employees and Subcontractors The Contractor shall ensure that PII is not disclosed to employees, subcontractors, or other persons or entities unless they have a legitimate educational interest and only for purposes necessary to provide services under the Contract. The Contractor agrees that it will not utilize any subcontractors or outside entities to provide services outside the Contract and shall not disclose any PII other than as required in this DPA. Contractor shall ensure that all employees and subcontractors comply with the terms of this DPA and are provided with any training on all applicable state and federal laws and regulations that protect the confidentiality of PII before being provided access to PII. If disclosure of PII is required by law or court order, the Contractor shall notify the BOCES and New York State Education Department no later than the time the PII disclosure is required unless such notice is expressly prohibited by law or the court order.

  • Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.

  • SERVICE PROVIDER’S PERSONNEL 10.1 The Service Provider’s Personnel shall be regarded at all times as employees, agents or Subcontractors of the Service Provider and no relationship of employer and employee shall arise between Transnet and any Service Provider Personnel under any circumstances regardless of the degree of supervision that may be exercised over the Personnel by Transnet. 10.2 The Service Provider warrants that all its Personnel will be entitled to work in South Africa or any other country in which the Services are to be performed. 10.3 The Service Provider will ensure that its Personnel comply with all reasonable requirements made known to the Service Provider by Transnet concerning conduct at any Transnet premises or any other premises upon which the Services are to be performed [including but not limited to security regulations, policy standards and codes of practice and health and safety requirements]. The Service Provider will ensure that such Personnel at all times act in a lawful and proper manner in accordance with these requirements. 10.4 Transnet reserves the right to refuse to admit or to remove from any premises occupied by or on behalf of it, any Service Provider Personnel whose admission or presence would, in the reasonable opinion of Transnet, be undesirable or who represents a threat to confidentiality or security or whose presence would be in breach of any rules and regulations governing Transnet's Personnel, provided that Transnet notifies the Service Provider of any such refusal [with reasons why]. The reasonable exclusion of any such individual from such premises shall not relieve the Service Provider from the performance of its obligations under this Agreement. 10.5 The Service Provider agrees to use all reasonable endeavours to ensure the continuity of its Personnel assigned to perform the Services. If any re-assignment by the Service Provider of those Personnel is necessary, or if Transnet advises that any such Personnel assigned are in any respect unsatisfactory, including where any such Personnel are, or are expected to be or have been absent for any period, then the Service Provider will promptly supply a replacement of equivalent calibre and experience, and any such replacement shall be approved by Transnet prior to commencing provision of the Services, such approval not to be unreasonably withheld or delayed.

  • Contractor’s Personnel The Contractor shall employ only personnel who are appropriately qualified, skilled and experienced in their respective trades or occupations. The Authority may require the Contractor to remove any personnel engaged for the Works, who in the opinion of the Authority: (a) has engaged in any misconduct; (b) is incompetent or negligent in the performance of his duties; (c) fails to conform with any provisions of the Contract; (d) engages in any conduct which is prejudicial to safety, health, or the protection of the environment; or (e) makes errors in the discharge of his functions. If appropriate and required by the Employer, the Contractor shall then appoint (or cause to be appointed) a suitable replacement person.

  • Agreements with Employees and Subcontractors Grantee shall have written, binding agreements with its employees and subcontractors that include provisions sufficient to give effect to and enable Grantee’s compliance with Grantee’s obligations under this Article VI, Intellectual Property.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!