Existing Facilities Each of the Existing Facilities shall be repaid in full and terminated and all collateral security therefor shall be released, and the Administrative Agent shall have received pay-off letters in form and substance satisfactory to it evidencing such repayment, termination and release.
Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Common Facilities “Common Facilities” includes all areas, facilities, utilities, equipment and services provided by Landlord for the common use or benefit of the occupants of the Property, and their employees, agents, customers and other invitees, including without limitation building lobbies, common corridors and hallways, restrooms, pedestrian walkways, driveways and access roads, access facilities for disabled persons (including elevators), truck serviceways, loading docks, garages, driveways, parking lots, landscaped areas, stairways, elevators, retaining walls, all areas required to be maintained under the conditions of governmental approvals for the Property, comfort and first-aid stations, parcel pick-up stations and other generally understood public or common areas. All Common Facilities shall at all times be subject to the exclusive control and management of Landlord. Landlord shall have the right, without liability to Tenant, to relocate, alter, improve, or adjust the size and location of any Common Facilities from time to time, and Landlord shall have the right from time to time to establish, modify and enforce reasonable rules and regulations with respect to the Common Facilities. Landlord shall have the right to construct, maintain and operate lighting facilities on the Common Facilities; to police the same; from time to time to change the area, level, location and arrangement of parking areas and other facilities; to restrict parking by tenants, their officers, agents and employees to employee parking areas; to enforce parking charges (by operation of meters or otherwise), with appropriate provisions for free parking ticket validating by tenants; to close all or any portion of the Common Facilities to such extent as may, in the opinion of Landlord’s counsel, be legally sufficient to prevent a dedication thereof or the accrual of any rights to any person or the public therein; to close temporarily all or any portion of the Common Facilities; to discourage non-customer parking; and to do and perform such other acts in and to the Common Facilities which Landlord shall determine, using good business judgment, to be advisable to improve the convenience and use thereof by tenants, their officers, agents, employees and customers. Subject to the foregoing, Tenant may use all Common Facilities not within the Premises, under a revocable license, on a nonexclusive basis in common with other tenants. If any such license is revoked, or if the amount of such areas is diminished, Landlord shall not be subject to any liability and Tenant shall not be entitled to any compensation or abatement of rent, nor shall such revocation or diminution be deemed constructive or actual eviction.
Additional Facilities If any structural additions or change in use shall be made to the buildings or other improvements included in the Project Facility subsequent to the date hereof (other than the initial construction of the Building contemplated by the Project), or if any additional buildings or improvements shall be constructed on the Land other than the Building (such change of use, new structures, structural additions, buildings and improvements being referred to hereinafter as “Additional Facilities”), the Obligor agrees that its PILOT Obligations hereunder shall be increased by an amount, as determined by the Agency or a tax assessor selected by the Agency, equal to the increased tax payments, if any, that would have been payable on such increase if this Agreement were not in effect. Nothing herein shall constitute the Agency’s consent to the construction of any such additions or additional buildings or improvements or to such change of use.
Parking Facilities The parking facilities appurtenant to the Building include asphalt surface parking for visitor parking and a separate parking structure for monthly parking (“Parking Structure”). Tenant shall be entitled to use commencing on the earlier of the Commencement Date or Tenant’s occupancy of the Premises, eight (8) vehicle parking spaces within the Parking Structure for the monthly parking of Tenant’s employees. Two of such parking spaces shall be for parking in the reserved covered portion of the Parking Structure, four (4) of such parking spaces shall be for parking in the unreserved covered portion of the Parking Structure, and the remaining two (2) parking spaces shall be for parking in the unreserved rooftop, uncovered portion of the Parking Structure. Tenant’s use of the Parking Structure shall be based upon a non-exclusive use in common with Landlord, other tenants of the Building, and their guests and invitees. Tenant shall not use more parking spaces than said number, or any spaces (a) which have been specifically assigned by Landlord to other tenants or for such other uses as visitor parking or (b) which have been designated by governmental entities of competent jurisdiction as being restricted to certain uses. Landlord reserves the right to erect such security and access and egress control devices as it may reasonably deem to be appropriate (including, without limitation card controlled gates) and Tenant agrees to cooperate fully with Landlord in such matters. Tenant shall not permit or allow any vehicles that belong to or are controlled by Tenant or Tenant’s employees, suppliers, shippers, customers, or invitees to be loaded, unloaded, or parked in areas other than those designated by Landlord for such activities. If Tenant permits or allows any of such prohibited activities, then Landlord shall have the right, without notice, in addition to such other rights and remedies that it may have, to remove or tow away the vehicle involved and charge the cost to Tenant, which cost shall be immediately payable upon demand by Landlord.
Access to Facilities Each of the Company and each of its Subsidiaries will permit any representatives designated by the Purchaser (or any successor of the Purchaser), upon reasonable notice and during normal business hours, at such person's expense and accompanied by a representative of the Company, to: (a) visit and inspect any of the properties of the Company or any of its Subsidiaries; (b) examine the corporate and financial records of the Company or any of its Subsidiaries (unless such examination is not permitted by federal, state or local law or by contract) and make copies thereof or extracts therefrom; and (c) discuss the affairs, finances and accounts of the Company or any of its Subsidiaries with the directors, officers and independent accountants of the Company or any of its Subsidiaries. Notwithstanding the foregoing, neither the Company nor any of its Subsidiaries will provide any material, non-public information to the Purchaser unless the Purchaser signs a confidentiality agreement and otherwise complies with Regulation FD, under the federal securities laws.
Banking Facilities Schedule 3.25 sets forth a complete and correct list of: (a) each bank, savings and loan or similar financial institution in which the Company or any of its Subsidiaries has an account or safety deposit box and the numbers of such accounts or safety deposit boxes maintained thereat; and (b) the names of all persons authorized to draw on each such account or to have access to any such safety deposit box, together with a description of the authority (and conditions thereto, if any) of each person with respect thereto.
Construction of Project 11.1.1 Developer agrees to cause the Project to be developed, constructed, and installed in accordance with the terms hereof and the Construction Provisions set forth in Exhibit D, including those things reasonably inferred from the Contract Documents as being within the scope of the Project and necessary to produce the stated result even though no mention is made in the Contract Documents.
Refinancing Facilities (a) On one or more occasions after the Effective Date, the Borrower may obtain, from any Lender or any other bank, financial institution or other institutional lender or investor that agrees to provide any portion of Refinancing Term Loans pursuant to a Refinancing Amendment in accordance with this Section 2.22 (each, an “Additional Refinancing Lender”) (provided that the Administrative Agent shall have consented (such consent not to be unreasonably withheld, conditioned or delayed) to such Lender’s or Additional Refinancing Lender’s making such Refinancing Term Loans to the extent such consent, if any, would be required under Section 9.04(b) for, and to the extent that such Additional Refinancing Lender is a Purchasing Borrower Party or an Affiliated Lender, the requirements of Section 9.04(g) and 9.04(f), respectively, shall be satisfied as if such Refinancing Term Loan were, an assignment of Term Loans to such Lender or Additional Refinancing Lender), Credit Agreement Refinancing Indebtedness in respect of all or any portion of Term Loans then outstanding under this Agreement, in the form of Refinancing Term Loans or Refinancing Term Commitments pursuant to a Refinancing Amendment; provided that no Lender is obligated hereunder to provide such Credit Agreement Refinancing Indebtedness. (b) The effectiveness of any Refinancing Amendment shall be subject to the satisfaction on the date thereof of each of the conditions set forth in Section 4.02 and, to the extent reasonably requested by the Administrative Agent, receipt by the Administrative Agent of (i) customary legal opinions, board resolutions and officers’ certificates consistent with those delivered on the Effective Date other than changes to such legal opinion resulting from a change in law, change in fact or change to counsel’s form of opinion reasonably satisfactory to the Administrative Agent and (ii) reaffirmation agreements and/or such amendments to the Security Documents as may be reasonably requested by the Administrative Agent in order to ensure that such Credit Agreement Refinancing Indebtedness is provided with the benefit of the applicable Loan Documents. (c) Each issuance of Credit Agreement Refinancing Indebtedness under Section 2.22(a) shall be in an aggregate principal amount that is (x) not less than $50,000,000 and (y) an integral multiple of $10,000,000 in excess thereof. (d) Each of the parties hereto hereby agrees that this Agreement and the other Loan Documents may be amended pursuant to a Refinancing Amendment, without the consent of any other Lenders, to the extent (but only to the extent) necessary to (i) reflect the existence and terms of the Credit Agreement Refinancing Indebtedness incurred pursuant thereto and (ii) effect such other amendments to this Agreement and the other Loan Documents as may be necessary or appropriate, in the reasonable opinion of the Administrative Agent and the Borrower, to effect the provisions of this Section 2.22, including any amendments necessary to treat the applicable Loans and/or Commitments established under the Refinancing Amendment as a new Class of Loans and/or Commitments hereunder, and the Lenders hereby expressly authorize the Administrative Agent to enter into any such Refinancing Amendment. (e) This Section 2.22 shall supersede any provisions in Section 2.17 or Section 9.02 to the contrary solely to the extent provided in this Section 2.22.
