ADDITIONAL SPECIAL CONTRACT CONDITIONS Special Contract Conditions revisions: the corresponding subsections of the Special Contract Conditions referenced below are replaced in their entirety with the following:
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Maximum Annual Operating Expense Limit The Maximum Annual Operating Expense Limit with respect to each Fund shall be the amount specified in Schedule A based on a percentage of the average daily net assets of each Fund.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Indemnity Limitation for TIPS Sales Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.
Maximum Leverage Permit, as of any fiscal quarter end, the ratio of (a) Adjusted Portfolio Equity as of such fiscal quarter end to (b) Funded Debt as of such fiscal quarter end, to be less than 5.00 to 1.00.
Availability of Earnings Statements The Company shall make generally available to holders of its securities as soon as may be practicable but in no event later than the last day of the fifteenth (15th) full calendar month following the calendar quarter in which the most recent effective date occurs in accordance with Rule 158 of the Rules and Regulations, an earnings statement (which need not be audited but shall be in reasonable detail) for a period of twelve (12) months ended commencing after the effective date, and satisfying the provisions of Section 11(a) of the Act (including Rule 158 of the Rules and Regulations).
Asset Coverage Ratio The Borrower will not permit the Asset Coverage Ratio to be less than 1.50 to 1 at any time.
Minimum Consolidated Net Worth The Borrower will not permit its Consolidated Net Worth at any time to be less than the sum of (i) $250,000,000 plus (ii) thirty percent (30%) of the sum of the Consolidated Net Income of the Borrower (with any consolidated net loss during any fiscal quarter counting as zero) for each fiscal quarter of the Borrower commencing with the fiscal quarter of the Borrower ending June 30, 1997.
Minimum Consolidated EBITDA The Borrower will not permit Modified Consolidated EBITDA, for any Test Period ending at the end of any fiscal quarter of the Borrower set forth below, to be less than the amount set forth opposite such fiscal quarter: Fiscal Quarter Amount September 30, 1997 $36,000,000 December 31, 1997 $36,000,000 March 31, 1998 $36,000,000 June 30, 1998 $37,000,000 September 30, 1998 $37,000,000 December 31, 1998 $38,000,000 March 31, 1999 $38,000,000 June 30, 1999 $39,000,000 September 30, 1999 $40,000,000 December 31, 1999 $41,000,000 March 31, 2000 $41,000,000 June 30, 2000 $42,000,000 September 30, 2000 $43,000,000 December 31, 2000 $44,000,000 March 31, 2001 $44,000,000 June 30, 2001 $45,000,000 September 30, 2001 $46,000,000 December 31, 2001 $47,000,000 March 31, 2002 $47,000,000
