Identification/Substitution of Personnel Sample Clauses

Identification/Substitution of Personnel. The personnel identified or described in Contractor’s proposal shall perform the services provided for State under this Contract. Contractor agrees that any personnel substituted during the term of this Contract must be able to conduct the required work to industry standards and be equally or better qualified than the personnel originally assigned. State reserves the right to approve Contractor personnel assigned to work under this Contract and any changes or substitutions to such personnel. State’s approval of a substitution will not be unreasonably withheld. This approval or disapproval shall not relieve Contractor to perform and be responsible for its obligations under this Contract. State reserves the right to require Contractor personnel replacement. If Contractor personnel become unavailable, Contractor shall provide an equally qualified replacement in time to avoid delays to the work plan.

See All (57)

Identification/Substitution of Personnel. The personnel identified or described in Licensor's proposal shall perform the services provided for State under this Agreement. Licensor agrees that any personnel substituted during the term of this Agreement must be able to conduct the required work to industry standards and be equally or better qualified than the personnel originally assigned. State reserves the right to approve Licensor personnel assigned to work under this Agreement and any changes or substitutions to such personnel. State's approval of a substitution will not be unreasonably withheld. This approval or disapproval shall not relieve Licensor to perform and be responsible for its obligations under this Agreement. State reserves the right to require Licensor personnel replacement. If Licensor personnel become unavailable, Licensor shall provide an equally qualified replacement in time to avoid delays to the work plan.

Identification/Substitution of Personnel. The personnel identified or described in Contractor's proposal shall perform the services provided for the Department under this contract. Contractor agrees that any personnel substituted during the term of this contract must be able to conduct the required work to industry standards and be equally or better qualified than the personnel originally assigned. The Department reserves the right to approve Contractor personnel assigned to work under this contract and any changes or substitutions to such personnel. The Department's approval of a substitution will not be unreasonably withheld. This approval or disapproval shall not relieve Contractor to perform and be responsible for its obligations under this contract. The Department reserves the right to require Contractor personnel replacement. If Contractor personnel become unavailable, Contractor shall provide an equally qualified replacement in time to avoid delays to the work plan. DocuSign Envelope ID: A7BDDE59-432F-48AA-8F43-B8C0503543C2

Identification/Substitution of Personnel. Optional depending on project

Identification/Substitution of Personnel. The personnel identified or described in Contractor’s proposal shall perform the services provided for State under this Contract. Contractor agrees that any DocuSign Envelope ID: BF48DF44-ABB5-4740-BB08-431200DDE88B personnelsubstituted during the term of this Contract must be able to conduct the required work to industry standards andbe equally or better qualified than the personnel originally assigned. State reserves the right to approve Contractor personnel assigned to work under this Contract and any changes or substitutions to such personnel. State’s approval of a substitution will not be unreasonably withheld. This approval or disapproval shall not relieve Contractor to perform and be responsible for its obligations under this Contract. State reserves the right to require Contractor personnel replacement. If Contractor personnel become unavailable, Contractor shall provide an equally qualified replacement in time to avoid delays to the work plan.

Identification/Substitution of Personnel. Contractor agrees that any personnel substituted during the term of this Contract must be able to conduct the required work to industry standards and be equally or better qualified than the personnel originally assigned. MPERB reserves the right to approve Contractor personnel assigned to work under this Contract and any changes or substitutions to such personnel. MPERB’s approval of a substitution will not be unreasonably withheld. This approval or disapproval shall not relieve Contractor to perform and be responsible for its obligations under this Contract. MPERB reserves the right to require Contractor personnel replacement. If Contractor personnel become unavailable, Contractor shall provide an equally qualified replacement in time to avoid delays to the work plan.

Identification/Substitution of Personnel. The personnel identified or described in Contractor's proposal shall perform the services provided for MPERB under this Contract. Contractor agrees that any personnel substituted during the term of this Contract must be able to conduct the required work to industry standards and be equally or better qualified than the personnel originally assigned. MPERB reserves the right to approve Contractor personnel assigned to work under this Contract and any changes or substitutions to such personnel. MPERB's approval of a substitution will not be unreasonably withheld. This approval or disapproval shall not relieve Contractor to perform and be responsible for its obligations under this Contract. MPERB reserves the right to require Contractor personnel replacement. If Contractor personnel become unavailable, Contractor shall provide an equally qualified replacement in time to avoid delays to the work plan.

Identification/Substitution of Personnel. The personnel identified or described in the Contractor's Bid shall perform the services provided for the County under this contract. The Contractor agrees that any personnel substituted during the term of this contract must be able to conduct the required work to industry standards and be equally or better qualified than the personnel originally assigned. The County reserves the right to approve the Contractor personnel assigned to work under this contract, and any changes or substitutions to such personnel. The County's approval of a substitution will not be unreasonably withheld. This approval or disapproval shall not relieve the Contractor to perform and be responsible for its obligations under this contract. The County reserves the right to require Contractor personnel replacement. In the event that Contractor personnel become unavailable, it will be the Contractor's responsibility to provide an equally qualified replacement in time to avoid delays to the work plan.

Related to Identification/Substitution of Personnel

Removal of Personnel The CONSULTANT agrees, within thirty (30) calendar days of receipt of a written request from the COUNTY, to promptly remove and replace the CONSULTANT'S Project Director, or any other personnel employed or retained by the CONSULTANT, or personnel of the sub-consultants or subcontractors engaged by the CONSULTANT to provide and/or perform services and/or work pursuant to the requirements of this Agreement, who the COUNTY shall request, in writing, be removed, which request may be made by the COUNTY with or without cause. However, if day thirty

Substitution of Key Personnel Consultant has represented to City that certain key personnel will perform and coordinate the Services under this Agreement. Should one or more of such personnel become unavailable, Consultant may substitute other personnel of at least equal competence upon written approval of City. In the event that City and Consultant cannot agree as to the substitution of key personnel, City shall be entitled to terminate this Agreement for cause. As discussed below, any personnel who fail or refuse to perform the Services in a manner acceptable to the City, or who are determined by the City to be uncooperative, incompetent, a threat to the adequate or timely completion of the Project or a threat to the safety of persons or property, shall be promptly removed from the Project by the Consultant at the request of the City. The key personnel for performance of this Agreement are as follows: Xxxxx Xxxxx.

RETURN AND DELETION OF PERSONAL DATA 7.1 We shall return to You and, to the extent allowed by applicable law, delete Your Personal Data as set out in the Agreement. We are obliged to ensure that any Sub-processors adhere to the same obligation

Identification of Goods Identification of the goods shall not be deemed to have been made until both Buyer and Seller have agreed that the goods in question are to be appropriate to the performance of this Agreement.

Entry and Sojourn of Personnel A Contracting Party shall, subject to its laws applicable from time to time relating to the entry and sojourn of non-citizens, permit natural persons of the other Contracting Party and personnel employed by companies of the other Contracting Party to enter and remain in its territory for the purpose of engaging in activities connected with investments.

Types of Personal Data Contact Information, the extent of which is determined and controlled by the Customer in its sole discretion, and other Personal Data such as navigational data (including website usage information), email data, system usage data, application integration data, and other electronic data submitted, stored, sent, or received by end users via the Subscription Service.

Contents of Personnel File A. Adverse statements prepared by the County shall not be included in an employee's official personnel file unless a copy is provided to the employee. B. An employee shall have the right to inspect and review the contents of his or her official personnel file at reasonable intervals. C. In addition, an employee shall have the right to inspect and review the contents of his or her official personnel file in any case where the employee has a grievance related to performance; to a performance evaluation; or is contesting his or her suspension or discharge from County service. D. Letters of reference and reports concerning criminal investigations concerning the employee shall be excluded from the provisions of B. and C., above. E. An employee shall have the right to respond in writing or personal interview to any information contained in his or her official personnel file, such reply to become a permanent part of such employee's official personnel file. F. Any contents of an employee's official personnel file may be destroyed pursuant to an agreement between the Chief of Employee Relations and the employee concerned or by an order of an arbitrator, court or impartial hearing officer unless the particular item is otherwise required by law to be kept.

Protection of Personal Data 25.1 The Parties agree that they may obtain and have access to personal data for the duration of the Agreement for the fulfilment of the rights and obligations contained herein. In performing the obligations as set out in this Agreement, the Parties shall at all times ensure that: a) they process data only for the express purpose for which it was obtained; b) once processed for the purposes for which it was obtained, all data will be destroyed to an extent that it cannot be reconstructed to its original form; c) data is provided only to authorised personnel who strictly require the personal data to carry out the Parties’ respective obligations under this Agreement; d) they do not disclose personal data of the other Party, other than in terms of this Agreement; e) they have all reasonable technical and organisational measures in place to protect all personal data from unauthorised access and/or use; f) they have appropriate technical and organisational measures in place to safeguard the security, integrity and authenticity of all data in its possession or under its control in terms of this Agreement; g) such personal data is protected against unauthorised or unlawful processing, accidental loss, destruction or damage, alteration, disclosure or access. 25.2 The Parties agree that if personal data will be processed for additional purposes beyond the original purpose for which it was obtained, explicit consent must be obtained beforehand from those persons whose information will be subject to further processing. 25.3 Should it be necessary for either Party to disclose or otherwise make available the personal data to any third party (including sub-contractors and employees), it may do so only with the prior written permission of the other Party. The Party requiring such permission shall require of all such third parties, appropriate written undertakings to be provided, containing similar terms to that set forth in this clause 25, and dealing with that third party's obligations in respect of its processing of the personal data. Following approval by the other Party, the Party requiring permission agrees that the provisions of this clause 25 shall mutatis mutandis apply to all authorised third parties who process personal data. 25.4 The Parties shall ensure that any persons authorized to process data on their behalf (including employees and third parties) will safeguard the security, integrity and authenticity of all data. Where necessary to meet this requirement, the Parties shall keep all personal data and any analyses, profiles, or documents derived therefrom logically separated from all other data and documentation held by it. 25.5 The Parties shall carry out regular assessments to identify all reasonably foreseeable internal and external risks to the personal data in its possession or under its control. The Parties shall implement and maintain appropriate safeguards against the risks which it identifies and shall also regularly verify that the safeguards which it has in place has been effectively implemented. 25.6 The Parties agree that they will promptly return or destroy any personal data in their possession or control which belongs to the other Party once it no longer serves the purpose for which it was collected in relation to this Agreement, subject to any legal retention requirements. This may be at the request of the other Party and includes circumstances where a person has requested the Parties to delete all instances of their personal data. The information will be destroyed in such a manner that it cannot be reconstructed to its original form, linking it to any particular individual or organisation.

Assignment of Personnel The Contractor shall not substitute any personnel for those specifically named in its proposal unless personnel with substantially equal or better qualifications and experience are provided, acceptable to County, as is evidenced in writing.

Type and Jurisdiction of Organization, Organizational and Identification Numbers The type of entity of such Grantor, its state of organization, the organizational number issued to it by its state of organization and its federal employer identification number are set forth on Exhibit A.

Filter & Search

Related Clauses

Parent Clauses

Sub-Clauses

Related to Identification/Substitution of Personnel

Most Referenced Clauses

Most Referenced Definitions