If a Force Majeure Event prevents Sample Clauses

If a Force Majeure Event prevents the Concessionaire from fulfilling its obligation in relation to the Works, Enhancement Works (if applicable) or Handback Works, the Concessionaire shall be entitled to an extension of time subject to and in accordance with Clause 26.3 (Scheduled Works Completion Date).
Sample 1
AutoNDA by SimpleDocs
If a Force Majeure Event prevents the Concessionaire from fulfilling its obligation in relation to the Airport Services, the Concessionaire shall, subject to Clause 37.2.7, be entitled to relief from its obligations under this Concession Agreement and any rights of the Contracting Authority arising under Clause 41.2 (Termination by the Contracting Authority). (a) as soon as practicable, and in any event within three (3) days after it became aware that the Force Majeure Event has caused or is likely to cause breach of an obligation under this Concession Agreement, give to the Contracting Authority a notice of its claim for relief from its obligations under this Concession Agreement, including full details of the nature of the Force Majeure Event, the date of occurrence and its likely duration; (b) within seven (7) days of receipt by the Contracting Authority of the notice referred to in paragraph (a) above, give full details of the relief claimed; and (c) demonstrate to the reasonable satisfaction of the Contracting Authority that: (i) the Concessionaire and its Sub-Contractors could not have avoided such occurrence or consequences by steps which they might reasonably be expected to have taken without incurring material cost; (ii) the Force Majeure Event directly caused the need for the relief claimed; (iii) the relief claimed could not reasonably be expected to be mitigated by the Concessionaire acting in accordance with Good Industry Practice, including recourse to alternate sources of services, equipment and materials and construction equipment without incurring material cost; and (iv) the Concessionaire is endeavoring to perform its obligations under this Concession Agreement.
Sample 1

Related to If a Force Majeure Event prevents

  • Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following: i) acts of God; ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities; iii) acts of war (whether declared or undeclared), invasion or civil unrest; iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement); v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals; vi) earthquakes, explosions, accidents, landslides; fire; vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality; viii) chemical or radioactive contamination or ionizing radiation; or ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs; x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.

  • Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:— (1) the Office through which such party (which will be the Affected Party) makes and receives payments or deliveries with respect to such Transaction is prevented from performing any absolute or contingent obligation to make a payment or delivery in respect of such Transaction, from receiving a payment or delivery in respect of such Transaction or from complying with any other material provision of this Agreement relating to such Transaction (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such Office so to perform, receive or comply (or it would be impossible or impracticable for such Office so to perform, receive or comply if such payment, delivery or compliance were required on that day); or (2) such party or any Credit Support Provider of such party (which will be the Affected Party) is prevented from performing any absolute or contingent obligation to make a payment or delivery which such party or Credit Support Provider has under any Credit Support Document relating to such Transaction, from receiving a payment or delivery under such Credit Support Document or from complying with any other material provision of such Credit Support Document (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply (or it would be impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply if such payment, delivery or compliance were required on that day), so long as the force majeure or act of state is beyond the control of such Office, such party or such Credit Support Provider, as appropriate, and such Office, party or Credit Support Provider could not, after using all reasonable efforts (which will not require such party or Credit Support Provider to incur a loss, other than immaterial, incidental expenses), overcome such prevention, impossibility or impracticability;

  • Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.

  • Termination Notice for Force Majeure Event If a Force Majeure Event subsists for a period of 180 (one hundred and eighty) days or more within a continuous period of 365 (three hundred and sixty five) days, either Party may in its discretion terminate this Agreement by issuing a Termination Notice to the other Party without being liable in any manner whatsoever, save as provided in this Article 34, and upon issue of such Termination Notice, this Agreement shall, notwithstanding anything to the contrary contained herein, stand terminated forthwith; provided that before issuing such Termination Notice, the Party intending to issue the Termination Notice shall inform the other Party of such intention and grant 15 (fifteen) days time to make a representation, and may after the expiry of such 15 (fifteen) days period, whether or not it is in receipt of such representation, in its sole discretion issue the Termination Notice.

  • Notification of Force Majeure Event 11.5.1 The Affected Party shall give notice to the other Party of any event of Force Majeure as soon as reasonably practicable, but not later than seven (7) days after the date on which such Party knew or should reasonably have known of the commencement of the event of Force Majeure. If an event of Force Majeure results in a breakdown of communications rendering it unreasonable to give notice within the applicable time limit specified herein, then the Party claiming Force Majeure shall give such notice as soon as reasonably practicable after reinstatement of communications, but not later than one (1) day after such reinstatement. Provided that, such notice shall be a pre-condition to the Affected Party’s entitlement to claim relief under this Agreement. Such notice shall include full particulars of the event of Force Majeure, its effects on the Party claiming relief and the remedial measures proposed. The Affected Party shall give the other Party regular reports on the progress of those remedial measures and such other information as the other Party may reasonably request about the Force Majeure. 11.5.2 The Affected Party shall give notice to the other Party of (i) the cessation of the relevant event of Force Majeure; and (ii) the cessation of the effects of such event of Force Majeure on the performance of its rights or obligations/ roles under this Agreement, as soon as practicable after becoming aware of each of these cessations.

  • Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.

  • Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11: (a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event; (b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5; (c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party. (d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.

  • Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.

  • FORCE MAJEURE CIRCUMSTANCES Lithium Hosting, llc CANNOT and WILL NOT be liable for any failure or delay in doing its professional duties resulting from circumstances beyond its physical control. Such circumstances may represent acts of any governmental body, war, rebellion, sabotage, embargo, fire, flood or other natural disaster, strike or other labor disturbances, interruption of or delay in transportation, unavailability of, interruption or delay in telecommunications or third party services (including DNS propagation), failure of third party software or hardware, or inability to obtain raw materials, supplies or power used in or equipment needed for provisioning of the Services.

  • MAJEURE 24.1 Neither Partner shall be entitled to bring a claim for a breach of obligations under this Agreement by the other Partner or incur any liability to the other Partner for any losses or damages incurred by that Partner to the extent that a Force Majeure Event occurs and it is prevented from carrying out its obligations by that Force Majeure Event. 24.2 On the occurrence of a Force Majeure Event, the Affected Partner shall notify the other Partner as soon as practicable. Such notification shall include details of the Force Majeure Event, including evidence of its effect on the obligations of the Affected Partner and any action proposed to mitigate its effect. 24.3 As soon as practicable, following notification as detailed in Clause 24.2, the Partners shall consult with each other in good faith and use all best endeavours to agree appropriate terms to mitigate the effects of the Force Majeure Event and, subject to Clause 24.4, facilitate the continued performance of the Agreement. 24.4 If the Force Majeure Event continues for a period of more than sixty (60) days, either Partner shall have the right to terminate the Agreement by giving fourteen (14) days written notice of termination to the other Partner. For the avoidance of doubt, no compensation shall be payable by either Partner as a direct consequence of this Agreement being terminated in accordance with this Clause.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!