Immunity or Defense Sample Clauses

Immunity or Defense. It is expressly understood and agreed by all Parties that neither the execution of this Agreement, nor any conduct of any Representative, shall be considered to waive, nor shall it be deemed to have waived, any immunity or defense that would otherwise be available to that Party against claims arising in the exercise of its governmental powers and functions, nor shall it be considered a waiver of sovereign immunity to suit. It is understood and agreed that a decision by one Party to waive immunity or to compensate a claim for which immunity would have been a defense and would have operated to prevent payment does not operate as a waiver or decision to compensate by the other Parties; nor will such action by one Party operate to incur any expense or charge to the other Parties.
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
Immunity or Defense. Despite any provision to the contrary in this Agreement, Company expressly acknowledges that the execution of this Agreement and the conduct of any County representative shall not be a waiver or deemed to be a waiver of any immunity or defense that would otherwise be available to County against Claims arising in the exercise of its governmental powers and functions, and shall not be considered a waiver of sovereign immunity to suit or liability. Company and County have all remedies and defenses allowed by law.
Sample 1Sample 2
Immunity or Defense. It is expressly understood and agreed by the Parties that neither the execution of this Agreement, nor any conduct of any representative of either Party relating to this Agreement, shall be considered to waive, nor shall it be deemed to have waived, any immunity or defense that would otherwise be available to that Party against claims arising in the exercise of its governmental powers and functions, nor shall it be considered a waiver of sovereign immunity to suit.
Sample 1
Immunity or Defense. 8.01 It is expressly understood and agreed that, in execution of this Agreement, neither the College nor the County waives, or shall be deemed to have waived, any immunity or defense that would be otherwise available to it against claims arising in the exercise of its governmental power and functions.
Sample 1
Immunity or Defense. It is expressly understood and agreed that, in the execution of this Agreement, neither Austin nor Lakeway waives nor shall be deemed to have waived, any immunity or defense that would otherwise be available to it against claims arising in the exercise of its governmental powers and functions.
Sample 1
Immunity or Defense. It is expressly understood and agreed that, in the execution of this Agreement, neither Austin nor Rollingwood waives nor shall be deemed to have waived, any immunity or defense that would otherwise be available to it against claims arising in the exercise of its governmental powers and functions.
Sample 1
Immunity or Defense. It is expressly understood and agreed that, in the execution of this agreement, neither Party waives, nor shall be deemed hereby to waive, any immunity or defense that would otherwise be available to it against claims arising in the exercise of its governmental powers or functions or pursuant to the Texas Tort Claims Act or other applicable statute, law, rule, or regulation.
Sample 1
AutoNDA by SimpleDocs
Immunity or Defense. 7.01 It is expressly understood and agreed that, in execution of this Agreement, neither the School District nor the County waives, or shall be deemed to have waived, any immunity or defense that would be otherwise be available to it against claims arising in the exercise of its governmental power and functions.
Sample 1

Related to Immunity or Defense

  • Right to Specific Performance THE COMPANY HEREBY ACKNOWLEDGES AND AGREES THAT THE DAMAGES TO BE INCURRED BY PARTICIPANT AS A RESULT OF THE COMPANY’S BREACH OF THIS AGREEMENT WILL BE DIFFICULT, IF NOT IMPOSSIBLE, TO ASCERTAIN, THAT DAMAGES WILL NOT BE AN ADEQUATE REMEDY AND THAT ANY BREACH OR THREATENED BREACH OF ANY OF THE PROVISIONS OF THIS AGREEMENT BY THE COMPANY MAY CAUSE IMMEDIATE IRREPARABLE HARM FOR WHICH THERE MAY BE NO ADEQUATE REMEDY AT LAW. ACCORDINGLY, THE PARTIES AGREE THAT, IN THE EVENT OF ANY SUCH BREACH OR THREATENED BREACH, PARTICIPANT SHALL BE ENTITLED TO IMMEDIATE AND PERMANENT EQUITABLE RELIEF (INCLUDING INJUNCTIVE RELIEF AND SPECIFIC PERFORMANCE OF THE PROVISIONS OF THIS AGREEMENT) FROM A COURT OF COMPETENT JURISDICTION (IN ADDITION TO ANY OTHER REMEDY TO WHICH IT MAY BE ENTITLED AT LAW OR IN EQUITY). THE PARTIES AGREE AND STIPULATE THAT PARTICIPANT SHALL BE ENTITLED TO SUCH EQUITABLE (INCLUDING INJUNCTIVE) RELIEF WITHOUT POSTING A BOND OR OTHER SECURITY AND THE COMPANY FURTHER WAIVES ANY DEFENSE IN ANY SUCH ACTION FOR SPECIFIC PERFORMANCE OR INJUNCTIVE RELIEF THAT A REMEDY AT LAW WOULD BE ADEQUATE AND ANY REQUIREMENT UNDER LAW TO POST SECURITY AS A PREREQUISITE TO OBTAINING EQUITABLE RELIEF. NOTHING CONTAINED IN THIS SECTION SHALL LIMIT THE PARTIES’ RIGHT TO ANY REMEDIES AT LAW, INCLUDING THE RECOVERY OF DAMAGES FOR BREACH OF THIS AGREEMENT.

  • Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR. 16.2 To the furthest extent permitted by California law, Developer shall also defend Indemnitees, at its own expense, including but not limited to attorneys’ fees and costs, against all Claims caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Facilities Lease by Developer, its Subcontractors, vendors, or suppliers. However, without impacting Developer’s obligation to provide an immediate and ongoing defense of Indemnitees, Developer’s defense obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent caused by the sole negligence, active negligence, or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. The District shall have the right to accept or reject any legal representation that Xxxxxxxxx proposes to defend the Indemnitees. If any Indemnitee provides its own defense due to failure to timely respond to tender of defense, rejection of tender of defense, or conflict of interest of proposed counsel, Developer shall reimburse such Indemnitee for any expenditures. Developer’s defense obligation shall not be construed to negate, abridge, or otherwise reduce any right or obligation of defense that would otherwise exist as to any Indemnitee or other person described herein. Developer’s defense obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any provision of law, any failure or alleged failure to timely and properly fulfill all of its obligations under the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developer’s obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR. Developer shall give prompt notice to the District in the event of any Claim(s). 16.3 Without limitation of the provisions herein, if Xxxxxxxxx’s obligation to indemnify and hold harmless the Indemnitees or its obligation to defend Indemnitees as provided herein shall be determined to be void or unenforceable, in whole or in part, it is the intention of the Parties that these circumstances shall not otherwise affect the validity or enforceability of Developer’s agreement to indemnify, defend, and hold harmless the rest of the Indemnitees, as provided herein. Further, Developer shall be and remain fully liable on its agreements and obligations herein to the fullest extent permitted by law.

  • INJURY ON DUTY (a) All employees shall be covered by The Workplace, Health, Safety and Compensation Commission Act, RSNL 1990 Chapter W-11. (b) An employee who is unable to perform the employee’s duties because of a personal injury received in the performance of the employee’s duties shall report the matter to the employee’s Supervisor and submit an account of the accident using the prescribed form as soon as possible. An employee’s claim will not be delayed where the prescribed form is not immediately provided to the employee through the Supervisor. (c) An employee who is unable to perform the employee’s duties because of a personal injury received in the performance of the employee’s duties shall be immediately placed on Injury on Duty Leave and receive compensation in accordance with the provisions of Workplace, Health, Safety and Compensation Commission Act, RSNL 1990 Chapter W-11. If the claim is subsequently denied by the Workers’ Compensation Commission, the employee may access other available benefits including sick leave and annual leave. (a) In the event that the employee dies as a result of an injury received in the performance of the employee’s duties, the employee’s estate shall receive all death benefits owing to the employee in accordance with the provisions of the Workplace, Health, Safety and Compensation Commission Act, RSNL 1990 Chapter W-11, in addition to any benefits the employee would be eligible for under the Public Service Pensions Act. (b) In the event that an employee becomes permanently disabled or incurs a recurring disability as a result of an injury received during the performance of the employee’s duties the employee will receive benefits in accordance with the provisions of The Workplace, Health, Safety and Compensation Commission Act, RSNL 1990 Chapter W-11. (a) An employee confirmed as being unable to perform the regular duties of his/her classification as a result of injury on duty will be employed in other work he/she can do provided a suitable vacancy is available and provided that the employee is qualified and able to perform the duties required. Where a suitable vacancy is available the rate for the new position shall apply. (b) Where a suitable vacancy is not available, the incapacitated employee retains the right to displace a less senior employee in another classification who occupies a position which the incapacitated employee is qualified and able to fill. Where an incapacitated employee advises the permanent head in writing of his/her intention to exercise his/her right to displace a less senior employee, the incapacitated employee will be deemed to have been given notice of layoff effective from the date he/she was confirmed as being unable to perform the regular duties of his/her classification. Accordingly, the right to displace a less senior employee in another classification shall be exercised as per the provisions of Article 35, Layoff, Bumping and Recall. 29.04 In the event that an employee is placed on leave under the provisions of this Article, he/she will not accrue seniority during any period when he/she would normally be laid off. 29.05 The Employer determines whether its employees will be covered directly by the Workers' Compensation Commission or indirectly through a "self-insured" arrangement. Benefits under either arrangement are to be in accordance with the provisions of The Workplace, Health, Safety and Compensation Commission Act, RSNL 1990 Chapter W-11. 29.06 It is agreed and understood by the parties to this Collective Agreement that an employee who is approved for full extended earnings loss (EEL) benefits from the Workplace, Health, Safety and Compensation Commission, after the date of signing of this agreement, shall no longer accumulate benefits under this agreement but shall have his/her position with the employer protected for two (2) calendar years following the date of such approval, immediately following which his/her employment shall be terminated, subject to the Human Rights Act.

  • Failure to Act Not a Defense The failure of the Company (including its Board of Directors or any committee thereof, independent legal counsel, or stockholders) to make a determination concerning the permissibility of the payment of Indemnifiable Amounts or the advancement of Indemnifiable Expenses under this Agreement shall not be a defense in any action brought under Section 10(a) above, and shall not create a presumption that such payment or advancement is not permissible.

  • Legal Defense The Contractor is expressly obligated to provide for the legal defense and investigation of any claim against the District as an additional insured and for all costs and expense incidental to such defense or investigation.

  • Right to Injunctive Relief Each Party agrees that breaches of this Section 9 may cause irreparable harm to the other Party and shall entitle such other Party, in addition to any other remedies available to it (subject to the terms of this Agreement), the right to seek injunctive relief enjoining such action.

  • Right to Defend Upon receipt of notice of any matter for which indemnification might be claimed by an Indemnified Party, the Indemnifying Party shall be entitled to defend, contest or otherwise protect against any such matter at its own cost and expense, and the Indemnified Party must cooperate in any such defense or other action. The Indemnified Party shall have the right, but not the obligation, to participate at its own expense in defense thereof by counsel of its own choosing, but the Indemnifying Party be entitled to control the defense unless the Indemnified Party has relieved the Indemnifying Party from liability with respect to the particular matter or the Indemnifying Party fails to assume defense of the matter. In the event the Indemnifying Party shall fail to defend, contest or otherwise protect in a timely manner against any matter, the Indemnified Party shall have the right, but not the obligation, thereafter to defend, contest or otherwise protect against the same and make any compromise or settlement thereof and recover the reasonable cost thereof from the Indemnifying Party including, without limitation, reasonable attorneys' fees, disbursements and all amounts paid as a result of such suit, action, investigation, claim or proceeding or the compromise or settlement thereof; provided, however, that the Indemnified Party must send a written notice to the Indemnifying Party of any such proposed settlement or compromise, which settlement or compromise the Indemnifying Party may reject, in its reasonable judgment, within ten (10) days of receipt of such notice. Failure to reject such notice within such ten (10) day period shall be deemed an acceptance of such settlement or compromise. The Indemnified Party shall have the right to effect a settlement or compromise over the objection of the Indemnifying Party; provided, that if (i) the Indemnifying Party is contesting such claim in good faith or (ii) the Indemnifying Party has assumed the defense from the Indemnified Party, the Indemnified Party waives any right to indemnity therefor. If the Indemnifying Party undertakes the defense of such matters, the Indemnified Party shall not, so long as the Indemnifying Party does not abandon the defense thereof, be entitled to recover from the Indemnifying Party any legal or other expenses subsequently incurred by the Indemnified Party in connection with the defense thereof other than the reasonable costs of investigation undertaken by the Indemnified Party with the prior written consent of the Indemnifying Party.

  • Notification and Defense of Claims The Indemnitee agrees promptly to notify the Indemnitors in writing upon being served with any summons, citation, subpoena, complaint, indictment, information, or other document relating to any Proceeding or matter which may be subject to indemnification or advancement of Expenses covered hereunder, but the failure so to notify the Indemnitors will not relieve the Indemnitors from any liability that the Indemnitors may have to Indemnitee under this Agreement unless the Indemnitors are materially prejudiced thereby. With respect to any such Proceeding as to which Indemnitee notifies the Indemnitors of the commencement thereof: (A) The Indemnitors will be entitled to participate therein at their own expense. (B) Except as otherwise provided below, the Indemnitors will be entitled to assume the defense thereof, with counsel reasonably satisfactory to Indemnitee. After notice from the Indemnitors to Indemnitee of the Indemnitors’ election so to assume the defense thereof, the Indemnitors will not be liable to Indemnitee under this Agreement for any legal or other expenses subsequently incurred by Indemnitee in connection with the defense thereof other than reasonable costs of investigation or as otherwise provided below. Indemnitee shall have the right to employ Indemnitee’s own counsel in such Proceeding, but the fees and disbursements of such counsel incurred after notice from the Indemnitors of the Indemnitors’ assumption of the defense thereof shall be at the expense of Indemnitee unless (a) the employment by counsel by Indemnitee has been authorized by the Indemnitors, (b) the Indemnitee shall have reasonably concluded that there may be a conflict of interest between the Indemnitors and the Indemnitee in the conduct of the defense of such action, (c) such Proceeding seeks penalties or other relief against the Indemnitee with respect to which the Indemnitors could not provide monetary indemnification to the Indemnitee (such as injunctive relief or incarceration) or (d) the Indemnitors shall not in fact have employed counsel to assume the defense of such action, in each of which cases the fees and disbursements of counsel shall be at the expense of the Indemnitors. The Indemnitors shall not be entitled to assume the defense of any Proceeding brought by or on behalf of the Indemnitors, or as to which Indemnitee shall have reached the conclusion specified in clause (b) above, or which involves penalties or other relief against Indemnitee of the type referred to in clause (c) above. (C) The Indemnitors shall not be liable to indemnify Indemnitee under this Agreement for any amounts paid in settlement of any action or claim effected without the Indemnitors’ written consent. The Indemnitors shall not settle any action or claim in any manner that would impose any penalty or limitation on Indemnitee without Indemnitee’s written consent. Neither the Indemnitors nor Indemnitee will unreasonably withhold or delay consent to any proposed settlement.

  • Notification and Defense of Claim Promptly after receipt by Indemnitee of notice of the commencement of any action, suit or proceeding, Indemnitee shall, if a claim in respect thereof is to be made against the Company under this Agreement, notify the Company of the commencement thereof; but the omission so to notify the Company shall not relieve it from any liability which it may have to Indemnitee. With respect to any such action, suit or proceeding as to which Indemnitee notifies the Company of the commencement thereof: (a) the Company shall be entitled to participate therein at its own expense; (b) except as otherwise provided below, to the extent that it may wish, the Company jointly with any other indemnifying party similarly notified shall be entitled to assume the defense thereof, with counsel reasonably satisfactory to Indemnitee. After notice from the Company to Indemnitee of its election so to assume the defense thereof, the Company shall not be liable to Indemnitee under this Agreement for any legal or other expenses subsequently incurred by Indemnitee in connection with the defense thereof other than reasonable costs of investigation or as otherwise provided below. Indemnitee shall have the right to employ his own chosen counsel in such action, suit or proceeding but the fees and expenses of such counsel incurred after notice from the Company of its assumption of the defense thereof shall be at the expense of Indemnitee, unless (i) the employment of such counsel by Indemnitee has been authorized by the Company, (ii) Indemnitee shall have reasonably concluded that there may be a conflict of interest between the Company and Indemnitee in the conduct of the defense of such action, suit or proceeding or (iii) the Company shall not in fact have employed its counsel to assume the defense of such action, in each of which cases the fees and expenses of Indemnitee’s counsel shall be at the expense of the Company. The Company shall not be entitled to assume the defense of any action, suit or proceeding brought by or on behalf of the Company or as to which Indemnitee shall have made the conclusion described in (ii) of this Section 7(b); and (c) the Company shall not be liable to indemnify Indemnitee under this Agreement for any amounts paid in settlement of any action or claim effected without the Company’s written consent. The Company shall not settle any action or claim in any manner which would impose any penalty, equitable remedy or injunctive or other relief or limitation on Indemnitee without Indemnitee’s written consent. Neither the Company nor Indemnitee shall unreasonably withhold their consent to any proposed settlement.

  • REMEDIES, OTHER OBLIGATIONS, BREACHES AND INJUNCTIVE RELIEF The remedies provided in this Warrant shall be cumulative and in addition to all other remedies available under this Warrant and the other Transaction Documents, at law or in equity (including a decree of specific performance and/or other injunctive relief), and nothing herein shall limit the right of the Holder to pursue actual damages for any failure by the Company to comply with the terms of this Warrant. The Company acknowledges that a breach by it of its obligations hereunder will cause irreparable harm to the Holder and that the remedy at law for any such breach may be inadequate. The Company therefore agrees that, in the event of any such breach or threatened breach, the holder of this Warrant shall be entitled, in addition to all other available remedies, to an injunction restraining any breach, without the necessity of showing economic loss and without any bond or other security being required.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!