In Notice Sample Clauses

In Notice. As defined in Section 3.6(a).
Sample 1Sample 2See All (4)
AutoNDA by SimpleDocs
In Notice. Upon giving a Step-In Notice to the SRSS Provider:
Sample 1
In Notice. 11.1 At any time: 11.1.1 on or after any event of default entitling the Lenders to the acceleration of amounts due and owing under the Facility Agreement and/or a notice of enforcement of the security constituted by the Security Agreement over the STS Crane Supply Contract Security Interests until the Revival Date (if any) (and the Contractor may treat the certification of the Security Trustee that such a default or enforcement has occurred as conclusive evidence of its occurrence); or 11.1.2 during any Step-In Decision Period, the Security Trustee may give written notice (a "Step-In Notice") to the Contractor in respect of any one of: (a) the Security Trustee itself; (b) any receiver, manager or administrative receiver of the Borrower appointed under the Security Agreement; (c) a company substantially the whole of whose issued share capital is owned by the Security Trustee and/or any one or more of the Lenders; or, (d) any Eligible Person, (each an "Additional Obligor"), stating that the Additional Obligor is entitled to exercise the rights of the Borrower under the Relevant Document and this Agreement in accordance with the terms hereof. 11.2 For the purposes of this Agreement, "Eligible Person" means a person approved by the Contractor (such approval not to be unreasonably withheld or delayed) to act as an Additional Obligor provided that the Contractor shall only be entitled to withhold its approval if the person proposed in the Step-In Notice as an Eligible Person: 11.2.1 is not of sound financial standing or is not guaranteed by a person or persons of sound financial standing; or 11.2.2 does not have the legal capacity, power and authorisation to become a party to and perform the obligations of the Borrower under the Relevant Document, and, in any case, such approval shall be deemed to have been given, in the absence of a written response from the Contractor, within [seven (7)] days after service of a Step- In Notice by the Security Trustee. Where the Contractor withholds its consent, it shall provide details of its objection in its written response. 11.3 [Notwithstanding anything to the contrary in this Agreement, if in the period immediately prior to the expiry of the Step-In Period, the Security Trustee is in the course of conducting active discussions in good faith with a proposed Substitute then, if agreed between the Contractor and the Security Trustee, the Step-In Period shall not expire but shall continue until a date agreed between the Contr...
Sample 1

Related to In Notice

  • CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.

  • Termination Notice If either Party, having become entitled to do so, decides to terminate this Agreement pursuant to the preceding Clause 8.2 (a) (i) or 8.2 (a) (ii), it shall issue Termination Notice setting out: (i) in sufficient detail the underlying Force Majeure Event; (ii) the Termination Date which shall be a date occurring not earlier than 60 (sixty) days from the date of Termination Notice; (iii) the estimated Termination Payment including the details of computation thereof and; (iv) any other relevant information.

  • Written Notice Any notice, demand, direction or instruction to be given to the Depositor, Evaluator or Supervisor hereunder shall be in writing and shall be duly given if mailed or delivered to the Depositor, 2455 Corporate West Drive, Lisle, Illinois 60532, or at such other adxxxxx xx xxxxx xx xxxxxxxxx xx xxx Xxxxxxxxx xx the other parties hereto in writing. (21) The second paragraph of Section 6.02 is replaced in its entirety as follows: An audit of the accounts of each Trust shall not be conducted unless the Depositor determines that such an audit is required. In the event that the Depositor determines that an audit is required, the accounts of each Trust shall be audited not less than annually by independent public accountants designated from time to time by the Depositor and reports of such accountants shall be furnished by the Trustee, upon request, to Unitholders. The Trustee, however, in connection with any such audits shall not be obligated to use Trust assets to pay for such audits in excess of the amounts, if any, indicated in the Prospectus relating to such Trust. The Trustee shall maintain and provide, upon the request of a Unitholder or the Depositor, the Unitholders' or the Unitholder's designated representative with the cost basis of the Securities represented by the Unitholder's Units. (22) The first paragraph of Section 6.04 is replaced in its entirety as follows:

  • Giving Notice Except as otherwise permitted by Section 2.14 with respect to borrowing notices, all notices and other communications provided to any party hereto under the Agreement or any other Loan Document shall be in writing and addressed or delivered to such party at its address set forth below its signature hereto or at such other address (or to counsel for such party) as may be designated by such party in a notice to the other parties. Any notice, if mailed and properly addressed with postage prepaid, shall be deemed given when received; any notice, if transmitted by facsimile, shall be deemed given when transmitted.

  • Response to Notice Within ten business days of receiving the Claim Notice, the Respondent must notify the Claimant of its representative to negotiate the dispute.

  • Notice to the Holder Whenever the Conversion Price is adjusted pursuant to any provision of this Section 5, the Company shall deliver to each Holder within two (2) Business Days a notice setting forth the Conversion Price after such adjustment and setting forth a brief statement of the facts requiring such adjustment.

  • Delivery Notice Notice of the Aircraft's Delivery Date, given by the Lessee as provided in Section 3.01 of the Participation Agreement and including any notice with respect to a postponed Delivery Date given by the Lessee pursuant to Section 3.05(c) of the Participation Agreement.

  • Notice of Claim Promptly after receipt by an Investor Indemnitee or Company Indemnitee of notice of the commencement of any action or proceeding (including any governmental action or proceeding) involving an Indemnified Liability, such Investor Indemnitee or Company Indemnitee, as applicable, shall, if a claim for an Indemnified Liability in respect thereof is to be made against any indemnifying party under this Article V, deliver to the indemnifying party a written notice of the commencement thereof; but the failure to so notify the indemnifying party will not relieve it of liability under this Article V except to the extent the indemnifying party is prejudiced by such failure. The indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume control of the defense thereof with counsel mutually reasonably satisfactory to the indemnifying party and the Investor Indemnitee or Company Indemnitee, as the case may be; provided, however, that an Investor Indemnitee or Company Indemnitee shall have the right to retain its own counsel with the actual and reasonable third party fees and expenses of not more than one counsel for such Investor Indemnitee or Company Indemnitee to be paid by the indemnifying party, if, in the reasonable opinion of counsel retained by the indemnifying party, the representation by such counsel of the Investor Indemnitee or Company Indemnitee and the indemnifying party would be inappropriate due to actual or potential differing interests between such Investor Indemnitee or Company Indemnitee and any other party represented by such counsel in such proceeding. The Investor Indemnitee or Company Indemnitee shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the Investor Indemnitee or Company Indemnitee which relates to such action or claim. The indemnifying party shall keep the Investor Indemnitee or Company Indemnitee reasonably apprised as to the status of the defense or any settlement negotiations with respect thereto. No indemnifying party shall be liable for any settlement of any action, claim or proceeding effected without its prior written consent, provided, however, that the indemnifying party shall not unreasonably withhold, delay or condition its consent. No indemnifying party shall, without the prior written consent of the Investor Indemnitee or Company Indemnitee, consent to entry of any judgment or enter into any settlement or other compromise which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Investor Indemnitee or Company Indemnitee of a release from all liability in respect to such claim or litigation. Following indemnification as provided for hereunder, the indemnifying party shall be subrogated to all rights of the Investor Indemnitee or Company Indemnitee with respect to all third parties, firms or corporations relating to the matter for which indemnification has been made. The indemnification required by this Article V shall be made by periodic payments of the amount thereof during the course of the investigation or defense, as and when bills are received and payment therefor is due.

  • Notice Any notice required or permitted to be given by either party to the other shall be deemed sufficient if sent by registered or certified mail, postage prepaid, addressed by the party giving notice to the other party at the last address furnished by the other party to the party giving notice: if to the Issuer, at 00 Xxxxxxxxxx Xxxxxx, Xxxxxx, Xxxxxxxxxxxxx, and if to Distributors, at 00 Xxxxxxxxxx Xxxxxx, Xxxxxx, Xxxxxxxxxxxxx.

  • Irrevocable Notice Each Notice of Pro Rata Borrowing of any Borrower shall be irrevocable and binding on such Borrower. In the case of any Pro Rata Borrowing that the related Notice of Pro Rata Borrowing specifies is to be comprised of LIBO Rate Advances, the Borrower requesting such Pro Rata Borrowing shall indemnify each Lender against any loss, cost or expense incurred by such Lender as a result of any failure to fulfill on or before the date specified in such Notice of Pro Rata Borrowing for such Pro Rata Borrowing the applicable conditions set forth in Article III, including, without limitation, any loss (excluding loss of anticipated profits), cost or expense incurred by reason of the liquidation or reemployment of deposits or other funds acquired by such Lender to fund the Pro Rata Advance to be made by such Lender as part of such Pro Rata Borrowing when such Pro Rata Advance, as a result of such failure, is not made on such date.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!