Packing and Marking All material and equipment to be furnished by the Contractor shall be packed, crated or otherwise suitably protected to withstand shipment undamaged to the destination. Each package, crate or part shall be marked plainly with the name of the consignee, shipping destination, the Owner's order number, and such other markings as are required. Complete packing lists, one copy with each package and two (2) copies by mail to the Owner at time of shipment, shall be supplied showing contents and identity of each package.
Operation and Maintenance Manuals Receipts for transmittal of Operation and Maintenance Manuals, Brochures and Data to the Design Professional (or Commissioning Agent) as required by Section 6.1.1.5.
Maintenance Manual No later than 60 (sixty) days prior to the Project Completion Date, the Contractor shall, in consultation with the Authority’s Engineer, evolve a maintenance manual (the “Maintenance Manual”) for the regular and preventive maintenance of the Project Highway in conformity with the Specifications and Standards, safety requirements and Good Industry Practice, and shall provide 5 (five) copies thereof to the Authority’s Engineer. The Authority’s Engineer shall review the Maintenance Manual within 15 (fifteen) days of its receipt and communicate its comments to the Contractor for necessary modifications, if any.
Filing and Processing A. Filing
Maintenance and Support Services If this Agreement is for IT goods or services, this section applies: Unless otherwise specified in this Agreement: The Contractor shall promptly provide the Court with all Upgrades, including without limitation: (i) all Upgrades generally made available by Contractor to its other customers; (ii) Upgrades as necessary so that the Work complies with the Specifications and Applicable Law (including changes in Applicable Law); (iii) Upgrades as necessary so that the Work operates under new versions or releases of the Court’s operating system or database platform; and (iv) all on-site services necessary for installation of Upgrades. Without limiting any other obligation of Contractor under this Agreement, Contractor represents and warrants that it will maintain services, equipment, software or any other part of the Work so that they operate in accordance with their Specifications and Documentation; and The Contractor shall respond to the Court within four (4) hours after the Court reports a Technical Support Incident (such hours all occurring during Standard M&S Hours) to Contractor. DELIVERY, ACCEPTANCE, AND PAYMENT Delivery. Contractor shall deliver to the Court the Deliverables in accordance with this Agreement, including the Statement of Work. Unless otherwise specified by this Agreement, Contractor will deliver all goods purchased by the Court “Free on Board Destination Freight Prepaid” to the Court at the address and location specified by the Court. Title to all goods purchased by the Court vests in the Court upon payment of the applicable purchase price. Contractor will bear the risk of loss for any Work being delivered until received by the Court at the proper location. All shipments by Contractor or its Subcontractors must include packing sheets identifying: this Agreement number, the Court’s purchase order number, item number, quantity and unit of measure, part number and description of the goods shipped, and appropriate evidence of inspection, if required. Goods for different Agreements shall be listed on separate packing sheets.
Uncovering and Correction of Work 12.1 The Contractor shall promptly correct Work rejected by the Owner or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed, and shall correct any Work found to be not in accordance with the requirements of the Contract Documents within a period of two years from the date of Substantial Completion, or by terms of an applicable special warranty required by the Contract Documents. The provisions of this Article apply to work done by Subcontractors as well as to Work done by direct employees of the Contractor.
12.2 At any time during the progress of the work, or in any case where the nature of the defects shall be such that it is not expedient to have them corrected, the Owner, at their option, shall have the right to deduct such sum, or sums, of money from the amount of the contract as they consider justified to adjust the difference in value between the defective work and that required under contract including any damage to the structure.
Ordering and Provisioning 53.3.1 CenturyLink will provide necessary ordering and provisioning business process support as well as those technical and systems interfaces as may be required to enable CLEC to provide resale services, including the functions, features, and capabilities of such services, and Unbundled Network Elements. If CenturyLink deploys any enhanced electronic capability CenturyLink will notify CLEC of availability and CLEC shall use the processes for performing transaction(s) to the extent practicable and the use of any other interface or process will be discontinued.
53.3.2 The Parties agree that orders for services under this Agreement will not be submitted or accepted until thirty (30) Days after the completion of all account establishment activities, including but not limited to, the documents and information subscribed in Section 45.1, unless the Parties mutually agree upon a different date based on the specific circumstances of the Parties’ relationship.
53.3.3 Except as specifically provided otherwise in this Agreement, pre- ordering, ordering and provisioning of resold services shall be governed in accordance with CenturyLink’s Standard Practices.
53.3.4 CenturyLink will provide provisioning intervals and procedures for design and complex services on a nondiscriminatory basis. Complex Service Order charges pursuant to Tariff terms may apply.
53.3.5 Where Technically Feasible, the NEAC will coordinate support for all designed and/or complex services provided to CLEC.
53.3.6 To the extent required by Applicable Law, and upon request from CLEC, employing CenturyLink’s LSR, CenturyLink will provide blocking of 700, 900, and 976 services, or other services of similar type as may now exist or be developed in the future, and shall provide Billed Number Screening (BNS), including required LIDB updates, or equivalent service for blocking completion of bill-to-third party and collect calls, on a line, PBX, or individual service basis. Blocking shall be provided to the extent (a) it is an available option for the Telecommunications Service resold by CLEC, or (b) it is Technically Feasible when requested by CLEC as a function of Unbundled Network Elements.
53.3.7 When ordering a resale service via an LSR Service Order, CLEC may order separate interLATA and IintraLATA service providers (i.e., two PICs) on a line or trunk basis, and CLEC agrees to pay the applicable Service Order and PIC charges associated with such order. CenturyLink will accept PIC change orders for IntraLATA toll and long distance services through the service provisioning process.
53.3.8 The standard Service Order charges as listed in the Table 1 of this Agreement shall apply to all orders.
Servicing and Maintenance Standards On behalf of the Issuer, the Servicer shall (a) manage, service, administer, bill, collect and calculate Securitized Utility Tariff Charges in accordance with the Securitization Law and post collections in respect of the Securitized Utility Tariff Property with reasonable care and in material compliance with applicable Requirements of Law, including all applicable MPSC Regulations and guidelines, using the same degree of care and diligence that the Servicer exercises with respect to similar assets for its own account and, if applicable, for others; (b) follow customary standards, policies and procedures for the industry in Missouri in performing its duties as Servicer; (c) use all reasonable efforts, consistent with its customary servicing procedures, to enforce, and maintain rights in respect of, the Securitized Utility Tariff Property and to bill and collect the Securitized Utility Tariff Charges; (d) comply with all Requirements of Law, including all applicable MPSC Regulations and guidelines, applicable to and binding on it relating to the Securitized Utility Tariff Property; (e) file all MPSC notices described in the Securitization Law and file and maintain the effectiveness of UCC financing statements with respect to the property transferred under the Sale Agreement, and (f) take such other action on behalf of the Issuer to ensure that the Lien of the Indenture Trustee on the Securitized Utility Tariff Collateral remains perfected and of first priority. The Servicer shall follow such customary and usual practices and procedures as it shall deem necessary or advisable in its servicing of all or any portion of the Securitized Utility Tariff Property, which, in the Servicer’s judgment, may include the taking of legal action, at the Issuer’s expense but subject to the priority of payments set forth in Section 8.02(e) of the Indenture.
Ordering and Maintenance CBB shall use Verizon’s electronic Operations Support System access platforms to submit Orders and requests for maintenance and repair of Services, and to engage in other pre-ordering, ordering, provisioning, maintenance and repair transactions. If Verizon has not yet deployed an electronic capability for CBB to perform a pre-ordering, ordering, provisioning, maintenance or repair, transaction offered by Verizon, CBB shall use such other processes as Verizon has made available for performing such transaction (including, but not limited, to submission of Orders by telephonic facsimile transmission and placing trouble reports by voice telephone transmission).
Secure Information Handling and Transfers 7.1 Physical and electronic handling, processing and transferring of DWP Data, including secure access to systems and the use of encryption where appropriate.
