Indirect Construction Costs Sample Clauses

Indirect Construction Costs. Taxes and fees Taxes or fees, other than sales tax, are not included. Sales tax is included at a rate of 8.00% for Napa, CA. Bonds Payment and performance bonds are included.
Sample 1
AutoNDA by SimpleDocs
Indirect Construction Costs. Bonds One hundred percent Payment and one hundred percent performance bonds are included. Bid bond is not included in proposal. Insurance Insurance requirements in excess of Provider's standard limits and coverages are not included. Provider shall procure and maintain the following insurances; installation or builders’ risk insurance covering the System and all materials from the time delivered to the Site for their full replacement cost value on an all risk or special cause of loss form from the Commencement Date through the Commissioning Date. Proposal assumes there no Owner Controlled Insurance Program (OCIP) in place for this project. Permits and Regulatory Fees An allowance for County of Napa building permits and approval requirements is included. All other permits/approvals are excluded including, but not limited to: conditional use permit, environmental control, storm water, soil erosion and sediment control, air quality, tree removal review and permitting, environmental impact report, state environmental regulatory agency and legislative act compliance, Army Corps of engineers, wetlands, water quality, archeological, endangered species, water rights, mineral rights, redevelopment, etc. If additional work is required, permits/approvals in support of the installation of the solar electric system, such as conditional use permits, environmental impact reports, dust control permits, etc., any associated added costs are not included. Provider includes durations for procuring permit and regulatory approvals in the Project Schedule as the basis of this proposal. See permitting durations assumed in the attached proposed master schedule. Provider will not be responsible for construction delays caused by permit and approval requirements from local jurisdictions or regulatory review bodies. Any delays in procuring permits will entitle Provider a time extension change order to the contract as a day for day extension to our plan for obtaining required permits and/or approvals, as defined above or in the proposal schedule. CEQA allowance = $55,726.00, timing to completion is scheduled for September 2, 2015. If the results cause modifications to proposed array layout we may need to adjust to align expectations, schedule and costs accordingly. Title Report allowance = $1000.00 – per RFP. Document Handling Additional design or construction administration work to change Provider design, construction administration, or record documentation standards to meet client's u...
Sample 1

Related to Indirect Construction Costs

  • DIRECT CONSTRUCTION COST Direct Construction Cost means the sum of the amounts that Contractor actually and necessarily incurs constructing the Project in strict compliance with the Construction Documents. Direct Construction Cost includes only the cost categories set forth in this Article and does not include the Pre-Construction Phase Fees or the Construction Phase Fees unless specifically noted. References in the UGSC to adjustments in “cost” or “costs” mean the Direct Construction Cost.

  • Construction Costs Under no circumstances shall the Consultant be liable for extra costs or other consequences due to unknown conditions or related to the failure of contractors to perform work in accordance with the plans and specifications. Consultant shall have no liability whatsoever for any costs arising out of the Client’s decision to obtain bids or proceed with construction before the Consultant has issued final, fully-approved plans and specifications. The Client acknowledges that all preliminary plans are subject to substantial revision until plans are fully approved and all permits obtained.

  • Project Construction The Contractor agrees to provide continuous on-site supervision on each Job Order, while progress on the project is being accomplished. The Contractor’s Project Manager will ensure:

  • Project Construction Budget The project construction cost allowance specifically stated in writing as the ‘revised’ or ‘current’ ‘Project Construction Budget’ by the Trustees at each applicable phase of plan development.

  • Construction Cost 3.1. Construction Cost does not include the fees of the ARCHITECT/ENGINEER and consultants, the cost of the land, rights- of-way, or other costs, which is the responsibility of the State as provided in Paragraphs 2.2 through 2.3. or any of the contingencies available for the project unless specifically stated otherwise.

  • Construction Cost Estimate At 50% completion of the contract documents, the design team will present and submit copies of the project plans and manual. The Construction Administrator will prepare and issue the fourth of five construction cost estimates. The estimate shall be derived from actual takeoffs, subcontractor and vendor input, and material and labor cost data. All quantitative systems information shall be provided in detail.

  • PRE-CONSTRUCTION PHASE FEE The Pre-Construction Phase Fee is the total compensation payable to Contractor for the performance of Pre-Construction Phase Services, except for Additional Pre-Construction Phase Services approved in advance and in writing by Owner. The Pre-Construction Phase Fee shall be a lump sum amount based on the AACC established in this Agreement.

  • RESPONSIBILITY FOR CONSTRUCTION COST 5.2.1 Evaluations of the Owner's Project budget, preliminary estimates of Construction Cost and detailed estimates of Construction Cost prepared by the Design Professional represent the Design Professional's best judgment as a design professional familiar with the construction industry. It is recognized, however, that neither the Design Professional nor the Owner has control over the cost of labor, materials or equipment, over the Contractor's methods of determining bid prices, or over competitive bidding or market conditions. Accordingly, the Design Professional cannot and does not warrant or represent that bids or cost proposals will not vary from the Owner's Project budget or from any estimate of Construction Cost or evaluation prepared or agreed to by the Design Professional.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

  • Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted during and at the end of the design phase in accordance with this Agreement and the Agreement for Architectural Services. The Construction Cost Budget does not include the compensation of the Project Design Team, the Program Manager (if any), the Construction Manager and any subconsultants, the cost of the land, rights-of-way, or financing which are the responsibility of the District.

Time is Money Join Law Insider Premium to draft better contracts faster.