Vacation Scheduling (a) With the exception of authorized vacation carryover under Clause 18.6, the scheduling and completion of vacations shall be on a calendar-year basis.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
Shift Scheduling The parties agree that the following shift schedules are examples of the type which will provide the flexibility required to meet the needs expressed above provided the provisions of Article VII Section 4 (b) (i) and (ii) have been met.
Work Scheduling Except at the request of an affected employee, no employee shall have the number of hours they are normally scheduled to work reduced as the result of the use of non-permanent employees such as, but not limited to: seasonal, intermittent, student interns, interns, interim, established term, or temporary employees, due to the performance of such employee’s duties by the nonpermanent employee.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Project Completion Report At the completion of construction and once a Project is placed in service, the Subrecipient must submit a Project Completion Report that includes the total number of units built and leased, affordable units built and leased, DR-MHP units built and leased, an accomplishment narrative, and the tenants names, demographics and income for each DR-MHP unit.
Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.
ARBITRATION - SCHEDULING Timely complaints shall be submitted to and determined by an arbitrator. Each arbitration proceeding shall commence not earlier than ten (10) calendar days and not later than thirty (30) calendar days following the date of filing of the complaint.
Evaluation Schedule CLIENT REFERENCES The Tenderer shall provide details of his performance on each of the previous projects listed in the “Relevant Experience” returnable schedule. “Client Reference Scorecards” will be completed by each of the respective Clients for the projects listed in the “Relevant Experience” returnable schedule. The following are to be completed by the Client and Principal Agent and is to be supported in each case by a letter of award and the works completion certificate. Both Client and Principal Agent must sign and stamp the documents, failure to obtain both signatures and stamps will result in no allocation of points. PROJECT NAME and SCOPE OF WORK: Principal agent: ................................................................................................................................. Client: .. ..............................................................................................................................................
Self Scheduling The Home and the Union may agree to implement a self-scheduling process. Self-scheduling is the mechanism by which employees in a Home create their own work schedules. The purpose of self scheduling is to improve job satisfaction and quality of work life for the participating employees. Self scheduling requires a collaboration of employees and management to ensure proper coverage of the Home and to meet the provisions of the Collective Agreement. It is agreed that self scheduling will be negotiated locally by the Home and the Union and will include a trial period. Each Home must have the majority agreement of the full-time and part-time employees who vote on the issue to agree on a trial period of up to six months. Once the trial period is complete, each Home must have a minimum of 66⅔% agreement of the full-time and part-time employees who vote on the issue to continue with the new schedule on a permanent basis.
