Delays during construction Without prejudice to the provisions of Clause 10.3 (ii), in the event the Contractor does not achieve any of the Project Milestones or the Authority’s Engineer shall have reasonably determined that the rate of progress of Works is such that Completion of the Project Highway is not likely to be achieved by the end of the Scheduled Completion Date, it shall notify the same to the Contractor, and the Contractor shall, within 15 (fifteen) days of such notice, by a communication inform the Authority’s Engineer in reasonable detail about the steps it proposes to take to expedite progress and the period within which it shall achieve the Project Completion Date.
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
(ii) Notwithstanding anything to the contrary contained in this Agreement, in the event of default by the Contractor in discharging the obligations specified in Clause 10.4 (i) above, the Authority shall get these maintenance works completed in the manner recommended by the Authority’s Engineer to avoid public inconvenience at the risk and cost of the Contractor in order to keep the road in traffic worthy condition.
During Construction Upon request of the Owner the Contractor shall submit written proposals for unit prices to be applied in the event Change Order Work is authorized by the Owner to be performed under Case (b).
As to Equipment and Inventory Grantor hereby agrees that it shall:
(a) keep all the Equipment and Inventory (other than Inventory in transit and Inventory sold in the ordinary course of business) at the places therefor specified in Section 3.1.1 or, upon 30 days' prior written notice to Agent, at such other places in a jurisdiction where all representations and warranties set forth in Article III (including Section 3.1.6) shall be true and correct, and all action required pursuant to the first sentence of Section 4.1.7 shall have been taken with respect to the Equipment and Inventory;
(b) with respect to any Equipment or Inventory in the possession or control of any Third Party or any of Grantor's agents, notify such Third Party or agent of Agent's security interest in such Equipment or Inventory and, upon Agent's request following the occurrence and during the continuance of an Event of Default, direct such Third Party or agent to hold all such Equipment or Inventory for Agent's account and subject to Agent's instructions;
(c) cause the Equipment to be maintained and preserved in the same condition, repair and working order as when new, ordinary wear and tear excepted, and in accordance with any manufacturer's manual; and forthwith, or in the case of any material loss or damage to any of the Equipment, as quickly as practicable after the occurrence thereof, make or cause to be made all repairs, replacements, and other improvements in connection therewith which are necessary or desirable to such end; and promptly furnish to Agent a statement respecting any loss or damage to any of the Equipment within ten (10) business days after Grantor obtains knowledge of any such loss or damage; and
(d) pay promptly when due all property and other taxes, assessments and governmental charges or levies imposed upon, and all claims (including claims for labor, materials and supplies) against, the Equipment and Inventory, except to the extent the validity thereof is being contested in good faith by appropriate proceedings and for which adequate reserves in accordance with Generally Accepted Accounting Principles have been set aside.
Location of Equipment and Inventory All Equipment and Inventory are (i) located at the locations indicated on Schedule 4 (ii) in transit to such locations or (iii) in transit to a third party purchaser which will become obligated on a Receivable to the Debtor upon receipt. Except for Equipment and Inventory referred to in clauses (ii) and (iii) of the preceding sentence, the Debtor has exclusive possession and control of the Inventory and Equipment.
Inspection of Collateral Lender and Lender's designated representatives and agents shall have the right at all reasonable times to examine and inspect the Collateral wherever located.
Equipment and Inventory With respect to any Equipment and/or Inventory of an Obligor, each such Obligor has exclusive possession and control of such Equipment and Inventory of such Obligor except for (i) Equipment leased by such Obligor as a lessee or (ii) Equipment or Inventory in transit with common carriers. No Inventory of an Obligor is held by a Person other than an Obligor pursuant to consignment, sale or return, sale on approval or similar arrangement.
Merchantable Inventory All Inventory is in all material respects of good and marketable quality, free from all material defects, except for Inventory for which adequate reserves have been made.
Eligible Inventory For purposes of this Agreement, Eligible Inventory shall exclude any Inventory to which any of the exclusionary criteria set forth below applies. The Administrative Agent shall have the right to establish, modify or eliminate Reserves against Eligible Inventory from time to time in its reasonable credit judgment. In addition, the Administrative Agent reserves the right, at any time and from time to time after the Original Closing Date, to adjust any of the criteria set forth below, to establish new criteria and to adjust the applicable advance rate with respect to Eligible Inventory, in its reasonable credit judgment, subject to the approval of the Supermajority Lenders in the case of adjustments, new criteria, changes in the applicable advance rate or the elimination of Reserves which have the effect of making more credit available. Eligible Inventory shall not include any Inventory of Borrower or any Borrowing Base Guarantor that:
(i) the Collateral Agent, on behalf of Secured Parties, does not have a first priority and exclusive perfected Lien on such Inventory;
(ii) is not located on premises in United States or Canada;
(iii) (A) is located on premises leased by Borrower or a Borrowing Base Guarantor, unless (x) at such location the aggregate value of Inventory exceeds $250,000, and (y) either (1) a reasonably satisfactory Landlord Lien Waiver and Access Agreement has been delivered to the Collateral Agent, or (2) Reserves reasonably satisfactory to the Administrative Agent have been established with respect thereto or (B) is stored with a bailee or warehouseman where the aggregate value of Inventory exceeds $250,000 unless either (x) a reasonably satisfactory, acknowledged bailee waiver letter has been received by the Collateral Agent or (y) Reserves reasonably satisfactory to the Administrative Agent have been established with respect thereto, or (C) is located at an owned location subject to a mortgage in favor of a lender other than the Collateral Agent where the aggregate value of Inventory exceeds $250,000 unless either (x) a reasonably satisfactory mortgagee waiver has been delivered to the Collateral Agent or (y) Reserves reasonably satisfactory to the Administrative Agent have been established with respect thereto;
(iv) is placed on consignment (other than Eligible Consigned Inventory);
(v) is covered by a negotiable document of title, unless such document has been delivered to the Collateral Agent with all necessary endorsements, free and clear of all Liens except those in favor of the Collateral Agent and the Lenders and landlords, carriers, bailees and warehousemen if clause (iii) above has been complied with;
(vi) is to be returned to suppliers;
(vii) is obsolete, unsalable, shopworn, seconds, damaged or unfit for sale;
(viii) is slow moving (in excess of 1-year supply);
(ix) consists of display items, samples or packing or shipping materials, manufacturing supplies or replacement parts (it being understood that Eligible Inventory shall not exclude work-in-process Inventory if it is not excluded in accordance with other criteria set forth herein, unless otherwise determined by the Administrative Agent in its reasonable credit judgment);
(x) is not of a type held for sale in the ordinary course of Borrower’s or any Borrowing Base Guarantor’s, as applicable, business;
(xi) breaches any of the representations or warranties pertaining to Inventory set forth in the Loan Documents;
(xii) consists of Hazardous Material or goods that can be transported or sold only with licenses that are not readily available;
(xiii) is not covered by casualty insurance maintained as required by Section 5.04;
(xiv) consists of custom made Inventory which is not saleable to any other customer or in ordinary course;
(xv) is in transit; or
(xvi) is subject to any licensing arrangement the effect of which would be to limit the ability of Collateral Agent, or any Person selling the Inventory on behalf of Collateral Agent, to sell such Inventory in enforcement of the Collateral Agent’s Liens, without further consent or payment to the licensor or other.
Inventory To the extent Inventory held for sale or lease has been produced by any Borrower, it has been and will be produced by such Borrower in accordance with the Federal Fair Labor Standards Act of 1938, as amended, and all rules, regulations and orders thereunder.
