Invoices; Invoice Review/Dispute Process Sample Clauses

Invoices; Invoice Review/Dispute Process. Authorized Purchaser will pay Contractor not more than once each month upon Contractor’s submission of a detailed invoice that sets forth the Services performed and Deliverables Accepted by Authorized Purchaser. Such invoices must comply with the requirements of this Section 3.3 and this Contract, identify the Deliverables completed and Accepted for which Contractor seeks compensation, and itemize and explain all authorized expenses for which reimbursement is claimed. Contractor shall submit invoices to Authorized Purchaser’s Authorized Representative. Authorized Purchaser shall review each such invoice for compliance with the requirements of this section or any other relevant provisions of this Contract. If an error or dispute arises concerning the amount charged in an invoice, Authorized Purchaser will notify Contractor of the disputed charge. Upon notification of dispute, Contractor shall submit to Authorized Purchaser all Documentation Authorized Purchaser requires to substantiate the amount charged. Authorized Purchaser, in its sole discretion, will determine if the supporting Documentation provides sufficient substantiation for the disputed charges. If Authorized Purchaser determines that the supporting Documentation is sufficient, Authorized Purchaser will notify Contractor and pay Contractor the amount charged in the invoice. If Authorized Purchaser determines the supporting Documentation supports payment of an amount less than originally invoiced, Authorized Purchaser will notify Contractor of the amount Authorized Purchaser believes is due under the invoice, and Authorized Purchaser will pay the invoice in that lesser amount.
Sample 1
AutoNDA by SimpleDocs

Related to Invoices; Invoice Review/Dispute Process

  • Invoice Disputes If you believe any delivered software or service does not conform to the warranties in this Agreement, you will provide us with written notice within thirty (30) days of your receipt of the applicable invoice. The written notice must contain reasonable detail of the issues you contend are in dispute so that we can confirm the issue and respond to your notice with either a justification of the invoice, an adjustment to the invoice, or a proposal addressing the issues presented in your notice. We will work with you as may be necessary to develop an action plan that outlines reasonable steps to be taken by each of us to resolve any issues presented in your notice. You may withhold payment of the amount(s) actually in dispute, and only those amounts, until we complete the action items outlined in the plan. If we are unable to complete the action items outlined in the action plan because of your failure to complete the items agreed to be done by you, then you will remit full payment of the invoice. We reserve the right to suspend delivery of all SaaS Services, including maintenance and support services, if you fail to pay an invoice not disputed as described above within fifteen (15) days of notice of our intent to do so.

  • Disputed Invoices If the Trader or the Distributor disputes a Tax Invoice (which includes a Revision Invoice) issued under this clause 9, the party disputing the invoice ("Disputing Party") must notify the other party ("Non-disputing Party") in writing and provide details as to the reasons why the Disputing Party disputes that invoice within 18 months of the date of the first Tax Invoice issued in respect of the Distribution Services charges the subject of the disputed Tax Invoice ("Invoice Dispute"). On receiving an Invoice Dispute notice, the Non-disputing Party must: (a) if the Non-disputing Party agrees with the matters set out in the Invoice Dispute notice and: (i) the Disputing Party has not paid the disputed Tax Invoice, promptly issue a Credit Note for the disputed amount, and any remaining amount owed must be paid by the Disputing Party within 6 Working Days of receipt of the Credit Note, but need not pay prior to the time set out in clause 9.4 or 9.5; or (ii) the Disputing Party has paid the disputed invoice, calculate the amount that the Disputing Party has over paid and promptly issue a Credit Note to the Disputing Party for the amount over paid, which must include a Use of Money Adjustment. Any amount owed must be paid by the Non-disputing Party within 6 Working Days of issuing the Credit Note. A Use of Money Adjustment must apply for the period commencing on the date the original Tax Invoice was paid and ending when re-payment is made, but the amount need not be settled prior to the time set out in clauses 9.4 or 9.5; or (b) if the Non-disputing Party disagrees with the matters set out in the Invoice Dispute notice, either party may raise a Dispute in accordance with clause 23 and if the Disputing Party has not paid the disputed Tax Invoice, it must pay the undisputed amount of the disputed Tax Invoice issued in accordance with clauses 9.4 or 9.5; and (c) on the resolution of a Dispute under clause 23, any amount owed must be paid by the relevant party within 6 Working Days. Default Interest is payable for the period commencing on the date the disputed amount would have been due for payment under this clause 9, and ending when payment is made. To the extent the Tax Invoice is held not to be payable, the Non-disputing Party must issue a Credit Note to the Disputing Party.

  • Final Invoice Within six months after completion of the construction of the Connecting Transmission Owner’s Attachment Facilities and the System Upgrade Facilities and System Deliverability Upgrades, Connecting Transmission Owner shall provide an invoice of the final cost of the construction of the Connecting Transmission Owner’s Attachment Facilities and the System Upgrade Facilities and System Deliverability Upgrades, determined in accordance with Attachment S to the NYISO OATT, and shall set forth such costs in sufficient detail to enable Developer to compare the actual costs with the estimates and to ascertain deviations, if any, from the cost estimates. Connecting Transmission Owner shall refund to Developer any amount by which the actual payment by Developer for estimated costs exceeds the actual costs of construction within thirty (30) Calendar Days of the issuance of such final construction invoice.

  • Invoice Submission All invoices submitted by Contractor shall include the City Contract Number, an assigned Invoice Number, and an Invoice Date. Contractor shall be provided with a cover sheet for invoicing. This cover sheet must be filled out correctly and submitted with each invoice. Contractor shall submit the original invoice through the responsible City Project Manager at: City of Ocala Engineer’s Office, Attn: Xxxxx Xxxxxxxxxx, 0000 XX 00xx Xxxxxx, Xxxxxxxx 000, Xxxxx, Xxxxxxx 00000, E-Mail: xxxxxxxxxxx@xxxxxxx.xxx.

  • Dispute Procedure (1) Unless otherwise provided in the Council's Constitution or in this Collective Agreement, any dispute within the registered scope of the Council shall be resolved as set out below: (a) The General Secretary of the Council shall, after consultation with the Secretary of any relevant Regional Chamber, decide whether any dispute referred to the Council must be dealt with by the Council or the Regional Chamber. (b) The Council shall, from time to time, adopt, by resolution, guidelines for the General Secretary of the Council to follow in the allocation of such disputes. (c) When any dispute is allocated to a Regional Chamber in terms of this clause, then such Regional Chamber shall have the same rights, powers and obligations as the Council.

  • PURCHASE ORDERS AND INVOICING All invoices shall at a minimum, include the items listed below and any additional information identified in the Authorized User RFQ and resulting Authorized User Agreement:  Contract Number;  Contractor/Reseller Name;  NYS Vendor ID;  Manufacturer Part Number (SKU);  Product Name;  Product Description;  Quantity;  NYS Net Price for each Product;  Specific designation of special price(s) which may be better than the NYS Net Contract Price; and  Invoice Total.

  • Invoice The original and duplicate invoices covering each and every shipment made against this order showing Contract number, Vendor number, and other essential particulars, must be forwarded promptly to the ordering agency concerned by the Vendor to whom the order is issued. Delays in receiving invoice and also errors and omissions on statements will be considered just cause for withholding settlement without losing discount privileges. All accounts are to be carried in the name of the agency or institution receiving the goods, and not in the name of the Division of Purchases.

  • Dispute Procedures Contact Think with any questions concerning this Agreement or the Services by calling 0- 000-000-0000 (toll-free), Monday - Friday 8AM – 8PM ET (note these hours may change); by sending a letter to Think, P. O. Box 1288, Greens Farms, Connecticut 06838; or by sending an email to: xxxx@xxxxxxxxxxx.xxx. Think will refer all complaints and inquiries to a representative who will attempt to reach a mutually satisfactory resolution. If your complaint or inquiry is not resolved after you have called Think and/or the EDC, or for general information, you may contact the DPU for assistance toll-free at (000) 000-0000, or at XXXXxxxxxxx.Xxxxxxxxxx@xxxx.xxx, or by sending a letter to the DPU at: 0 Xxxxx Xxxxxxx, 0xx Xxxxx Xxxxxx, XX 00000. You have a right to make a formal or informal complaint to the DPU or any regulatory body with authority to review your complaint. In addition, mediation is available for disputes greater than $100. Nothing in the Arbitration, Waiver of Jury Trial, and Class Action Waiver Section below is intended to bar your right to make a complaint or request mediation. ARBITRATION. Think’s Arbitration and Class Action Wavier Policy Addendum, which is available and provided to you during the enrollment process is incorporated herein and made a part hereof, contains additional details and a complete description of the terms and conditions of the Arbitration and Class Action Waiver Policy, including your ability to opt out. Warranties. THINK MAKES NO EXPRESS REPRESENTATION OR WARRANTIES WITH REGARD TO THE PROVISION OF ELECTRIC SERVICE AND DISCLAIMS ANY AND ALL WARRANTIES, EXPRESSED OR IMPLIED, OR ARISING OUT OF ANY COURSE OF DEALING OR USAGE OF TRADE EXCEPT WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR PURPOSE. Limitation of Liability. You will be deemed to be in exclusive control (and responsible for any damages or injury caused thereby) of the electric power after receipt at the delivery point(s). TO THE FULLEST EXTENT PERMITTED BY LAW, THINK WILL NOT BE LIABLE FOR CONSEQUENTIAL, INCIDENTAL, SPECIAL, PUNITIVE, EXEMPLARY, OR INDIRECT DAMAGES (INCLUDING LOST PROFITS OR OTHER BUSINESS INTERRUPTION DAMAGES), WHETHER BY STATUTE, IN CONTRACT OR TORT, EVEN IF THE RESULT OF NEGLIGENCE (WHETHER SOLE, JOINT, CONCURRENT, ACTIVE, OR PASSIVE). ALL OTHER LIABILITY WILL BE LIMITED TO DIRECT ACTUAL DAMAGES ONLY, AND SUCH DIRECT ACTUAL DAMAGES WILL BE THE SOLE AND EXCLUSIVE REMEDY. YOU HEREBY WAIVE ALL OTHER REMEDIES AT LAW OR IN EQUITY. THERE ARE NO THIRD-PARTY BENEFICIARIES TO THIS AGREEMENT. To the extent any damages required to be paid hereunder are liquidated, the Parties acknowledge that the damages are not intended and shall not be construed as a penalty, such damages are difficult or impossible to determine, that otherwise obtaining an adequate remedy is inconvenient or impossible, and that the liquidated damages constitute a reasonable approximation of the harm or loss.

  • CONTRACTOR INVOICE Contractor shall submit to Purchaser’s designated invoicing contact properly itemized invoices. Such invoices shall itemize the following: (a) Master Contract No. 02120 (b) Contractor name, address, telephone number, and email address for billing issues (i.e., Contractor Customer Service Representative) (c) Contractor’s Federal Tax Identification Number (d) Date(s) of delivery (e) Invoice amount; and (f) Payment terms, including any available prompt payment discounts. Contractor’s invoices for payment shall reflect accurate Master Contract prices. Invoices will not be processed for payment until receipt of a complete invoice as specified herein.

  • CONTRACT INVOICING a. Invoicing. Contractor and the dealers/distributors/resellers designated by the Contractor, if any, shall provide complete and accurate billing invoices to each Authorized User in order to receive payment. Billing invoices submitted to an Authorized User must contain all information required by the Contract and the State Comptroller or other appropriate fiscal officer. Submission of an invoice and payment thereof shall not preclude the Commissioner from requesting reimbursement or demanding a price adjustment in any case where the Product delivered is found to deviate from the terms and conditions of the Contract or where the billing was inaccurate. b. Payment of Contract Purchases made by an Authorized User when the State Comptroller is responsible for issuing such payment. The Authorized User and Contractor agree that payments for invoices submitted by the Contractor shall only be rendered electronically unless payment by paper check is expressly authorized by the Commissioner, in the Commissioner’s sole discretion, due to extenuating circumstances. Such electronic payments shall be made in accordance with ordinary State procedures and practices. The Contractor shall comply with the State Comptroller’s procedures to authorize electronic payments. Authorization forms are available at the State Comptroller website at xxx.xxx.xxxxx.xx.xx, by e-mail at xxxxxx@xxx.xxxxx.xx.xx, or by telephone at 000-000-0000. Contractor acknowledges that it will not receive payment on any invoices submitted under this Contract that are payable by the State Comptroller if it does not comply with the State Comptroller’s electronic payment procedures, except where the Commissioner has expressly authorized payment by paper check as set forth above. c. Payment of Contract Purchases made by an Authorized User when the State Comptroller is not responsible for issuing such payment The Authorized User and Contractor agree that payments for such Contract purchases shall be billed directly by Contractor on invoices/vouchers, together with complete and accurate supporting documentation as required by the Authorized User. Such payments shall be as mandated by the appropriate governing law from the receipt of a proper invoice. Such Authorized User and Contractor are strongly encouraged to establish electronic payments.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!