Working and Labor Synergies The Contractor shall be responsible for maintaining a tranquil working relationship between the Contractor work force, the Contractor Parties and their work force, State employees, and any other contractors present at the work site. The Contractor shall quickly resolve all labor disputes which result from the Contractor's or Contractor Parties’ presence at the work site, or other action under their control. Labor disputes shall not be deemed to be sufficient cause to allow the Contractor to make any claim for additional compensation for cost, expenses or any other loss or damage, nor shall those disputes be deemed to be sufficient reason to relieve the Contractor from any of its obligations under the Contract.
Labor Harmony The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows:
(a) In any contract or undertaking which Tenant may make with a contractor for work in the Premises, provision shall be made for the dismissal from the job of workmen whose work is unskilled or otherwise objectionable, in the Director’s (and, for this purpose, “the Director” shall include a reference to the Airport’s Architect) reasonable judgment. Tenant shall cause any such workmen to be discharged from the project within twenty-four (24) hours after Director shall give notice to Tenant requiring such discharge.
(b) Tenant shall use, and Tenant shall require its contractor and subcontractors to use, their respective best efforts to prevent work stoppages on the Premises, and/or elsewhere on the Airport, to the extent attributable to work being performed on the Premises, irrespective of the reason of any such stoppage. In the event that the conduct or presence of any employee(s) of Tenant or Tenant’s contractor(s) or subcontractor(s) causes a labor dispute or work stoppage, Tenant shall have such employee(s) immediately removed from the Airport upon Director’s request.
(c) Tenant shall include, and shall cause its contractor to include, the following clause in all contracts with its general contractors and subcontractors: There shall be no manifestations on the project of any dispute between any labor organization and any Tenant contractor or subcontractor, including but not limited to, any area standards picketing against said contractor or subcontractor. Should there be any manifestation of a labor dispute between any Tenant contractor or subcontractor and any union, which results in a stoppage of work on the part of said contractor or subcontractor’s employees or the employees of any other employer or supplier on the project or at the Airport, which in the sole judgment of the Director will cause, or is likely to cause, unreasonable delay in the progress of construction or operation of any business at the Airport, then upon written notice from Director, Tenant shall declare the contractor or subcontractor in default of its contract, and upon such notice, Tenant shall have the right to take such steps as are necessary to finish the uncompleted portion of the work to be performed by the contractor or subcontractor.
(d) Without limiting the generality of indemnities elsewhere in this Lease, Tenant shall indemnify, defend, and hold harmless City and each City Entity for any and all Losses which arise from the actions taken pursuant to this Section 7.9.
PREVAILING WAGE RATES - PUBLIC WORKS AND BUILDING SERVICES CONTRACTS If any portion of work being Bid is subject to the prevailing wage rate provisions of the Labor Law, the following shall apply:
Policy Grievance – Employer Grievance The Employer may institute a grievance alleging a general misinterpretation or violation by the Union or any employee by filing a written grievance with the Bargaining Unit President, with a copy to the Labour Relations Officer within twenty (20) days after the circumstances have occurred. A meeting will be held between the parties within ten (10) days. The Union shall reply within ten (10) days after the meeting, and failing settlement, the matter may be referred to arbitration.
(a) Where a difference arises between the parties relating to the interpretation, application or administration of this Agreement, including any questions as to whether a matter is arbitrable, or where an allegation is made that this Agreement has been violated, either of the parties may, after exhausting the grievance procedure established by this Agreement, notify the other party in writing of its decision to submit the difference or allegation to arbitration, and the notice shall contain the name of the first party's appointee to an Arbitration Board. The recipient of the notice shall, within ten (10) days, inform the other party of the name of its appointee to the Arbitration Board. The two appointees so selected shall within ten (10) days of the appointment of the second of them, appoint a third person who shall be the Chairperson. If the recipient of the notice fails to appoint a nominee, or if the two nominees fail to agree upon a Chairperson within the time limit, the appointment shall be made by the Minister of Labour for Ontario upon the request of either party.
(b) Within thirty (30) calendar days of the receipt of notice referred to in Article 8.12(a) above, either party may require a process for a sole arbitrator where the grievance concerns:
i) a job posting ii) a short term layoff
Trade Union Training Leave Subject to all qualifications in this clause, an employee appointed or elected as an accredited representative of the union to which he/she belongs will, upon application in writing to the Enterprise, be granted up to 5 days leave with pay each calendar year non-cumulative to attend courses conducted or approved by the Union.
CONTRACT WORK HOURS AND SAFETY STANDARDS As per the Contract Work Hours and Safety Standards Act (40 U.S.C. 3701-3708), where applicable, all Customer Purchase Orders in excess of ,000 that involve the employment of mechanics or laborers must include a provision for compliance with 40 U.S.C. 3702 and 3704, as supplemented by Department of Labor regulations (29 CFR Part 5). Under 40 U.S.C. 3702 of the Act, each contractor must be required to compute the wages of every mechanic and laborer on the basis of a standard work week of 40 hours. Work in excess of the standard work week is permissible provided that the worker is compensated at a rate of not less than one and a half times the basic rate of pay for all hours worked in excess of 40 hours in the work week. The requirements of 40 U.S.C. 3704 are applicable to construction work and provide that no laborer or mechanic must be required to work in surroundings or under working conditions which are unsanitary, hazardous or dangerous. These requirements do not apply to the purchases of supplies or materials or articles ordinarily available on the open market, or contracts for transportation or transmission of intelligence.
Contract Work Hours and Safety Standards Act The following clauses apply to any Federal-aid construction contract in an amount in excess of $100,000 and subject to the overtime provisions of the Contract Work Hours and Safety Standards Act. These clauses shall be inserted in addition to the clauses required by 29 CFR 5.5(a) or 29 CFR 4.6. As used in this paragraph, the terms laborers and mechanics include watchmen and guards.
System Protection Facilities The Interconnection Customer shall, at its expense, install, operate and maintain System Protection Facilities as a part of the Large Generating Facility or the Interconnection Customer’s Interconnection Facilities. The Participating TO shall install at the Interconnection Customer's expense any System Protection Facilities that may be required on the Participating TO’s Interconnection Facilities or the Participating TO’s Transmission System as a result of the interconnection of the Large Generating Facility and the Interconnection Customer’s Interconnection Facilities.
Labor Disputes and Acts of God Neither the business nor the properties of the Borrower or any Subsidiary or any Guarantor are affected by any fire, explosion, accident, strike, lockout, or other labor dispute, drought, storm, hail, earthquake, embargo, act of God or of the public enemy, or other casualty (whether or not covered by insurance), materially and adversely affecting such business or properties or the operation of the Borrower or such Subsidiary or such Guarantor.
CHILD LABOUR The Supplier represents and warrants that neither it nor any of its affiliates is engaged in any practice inconsistent with the rights set forth in the Convention on the Rights of the Child, including Article 32 thereof, which, inter alia, requires that a child shall be protected from performing any work that is likely to be hazardous or to interfere with the child's education, or to be harmful to the child's health or physical, mental, spiritual, moral or social development. Any breach of this representation and warranty shall entitle UNDP to terminate this Purchase Order immediately upon notice to the Supplier, without any liability for termination charges or any other liability of any kind of UNDP.
