Labor Harmony. The parties acknowledge that it is of the utmost importance to City, Tenant, and all those occupying or to occupy space in the Domestic and International Terminals that there be no interruption in the progress of the construction work. Accordingly, City and Tenant agree as follows:
(a) In any contract or undertaking which Tenant may make with a contractor for work in the Premises, provision shall be made for the dismissal from the job of workmen whose work is unskilled or otherwise objectionable, in the Director’s (and, for this purpose, “the Director” shall include a reference to the Airport’s Architect) reasonable judgment. Tenant shall cause any such workmen to be discharged from the project within twenty-four (24) hours after Director shall give notice to Tenant requiring such discharge.
(b) Tenant shall use, and Tenant shall require its contractor and subcontractors to use, their respective best efforts to prevent work stoppages on the Premises, and/or elsewhere on the Airport, to the extent attributable to work being performed on the Premises, irrespective of the reason of any such stoppage. In the event that the conduct or presence of any employee(s) of Tenant or Tenant’s contractor(s) or subcontractor(s) causes a labor dispute or work stoppage, Tenant shall have such employee(s) immediately removed from the Airport upon Director’s request.
(c) Tenant shall include, and shall cause its contractor to include, the following clause in all contracts with its general contractors and subcontractors: There shall be no manifestations on the project of any dispute between any labor organization and any Tenant contractor or subcontractor, including but not limited to, any area standards picketing against said contractor or subcontractor. Should there be any manifestation of a labor dispute between any Tenant contractor or subcontractor and any union, which results in a stoppage of work on the part of said contractor or subcontractor’s employees or the employees of any other employer or supplier on the project or at the Airport, which in the sole judgment of the Director will cause, or is likely to cause, unreasonable delay in the progress of construction or operation of any business at the Airport, then upon written notice from Director, Tenant shall declare the contractor or subcontractor in default of its contract, and upon such notice, Tenant shall have the right to take such steps as are necessary to finish the uncompleted portion of the work to be perfor...
Labor Harmony. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment, or labor and employment practices that, in Landlord’s good faith judgment, may cause strikes, picketing or boycotts or disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Property.
Labor Harmony. Tenant agrees that any work performed by or on behalf of Tenant or any Tenant Party shall be performed in such manner and by such persons as shall maintain harmonious labor relations at the Project. If labor disharmony arises as a result of non-union labor employed by a subcontractor or other contractor engaged by Tenant or any Tenant Party, and such labor disharmony causes a delay in the construction of the Non-TI Project Improvements or Landlord’s Work, such delay shall be a Tenant Delay under this Work Letter. If labor disharmony arises as a result of a contractor or subcontractor engaged by Tenant or any Tenant Party, or if Landlord reasonably believes that a contractor or subcontractor employed by Tenant or any Tenant Party will cause labor disharmony in the Project, Landlord shall have the right, in addition to other rights and remedies under the Work Letter or Lease, to exclude from the Premises and Project such contractor or subcontractor employed by Tenant or any Tenant Party.
Labor Harmony. The Shareholder shall cause its contractors and subcontractors to undertake the Work, and employ only such laborers, as shall not in any manner interfere or conflict with, or cause any labor disturbances or stoppages with, any of the unions whose members are either employees of the Corporation or employees of any contractor or other third party servicing the Building.
Labor Harmony.
X. Xxxxxxxx maintains a neutral position regarding Project Labor Agreements. This Contract Work does not mandate nor preclude participation in a Project Labor Agreement if said participation promotes the economy and efficiency in Federal procurement ascribed by Executive Order titled, “Use of Project Labor Agreements for Federal Construction Projects,” dated 2/6/09.
B. In accordance with applicable prior labor agreements, laws, regulations, codes and standards, the Contractor shall furnish labor that can work in harmony with all other elements of labor employed or to be employed on the work. Without limiting the generality of the foregoing, Labor Harmony shall include the provision of labor that will not cause, cause to be threatened or give rise to either directly or indirectly, any work disruption, slowdowns or stoppages by employees of other Contractors, while performing any work or activities incidental thereto.
C. Award of any construction Contract is contingent upon the Contractor having an acceptable Plan for harmonizing labor on the Battelle Work site.
D. The Contractor agrees to insert the substance of this clause, including paragraph (c), in every Subcontract issued in performance of this Contract.
Labor Harmony. Tenant shall not, at any time prior to or during the Demised Term, directly or indirectly employ, or permit the employment of, any contractor, mechanic or laborer in the Demised Premises, whether in connection with any Alteration or otherwise, if such employment will interfere or cause any conflict with other contractors, mechanics, or laborers engaged in the construction, maintenance or operation of the Building by Owner, Tenant or others. In the event of any such interference or conflict, Tenant, upon demand of Owner, shall cause all contractors, mechanics or laborers causing such interference or conflict to leave the Building immediately.
Labor Harmony. The Trade Contractor shall only employ labor in connection with the Trade Contractor Work capable of working harmoniously with all trades, crafts, and any other Persons associated with the Project. The Trade Contractor shall also use its best efforts to minimize the likelihood of any strike, work stoppage, or other labor disturbance.
2.6.1 In case the progress of the Trade Contractor Work is affected by any undue delay in furnishing or installing any items or materials or equipment required under the Trade Contract Documents because of a conflict involving any labor agreement or regulation, the Authority may require that other material or equipment of equal kind and quality be provided pursuant to a Contract Revision, Change Order, or Construction Change Directive to maintain the Trade Contractor’s Construction Schedule at no additional cost to the Authority.
Labor Harmony. Tenant shall not use (and upon notice from Landlord shall cease using) contractors, services, workmen, labor, materials or equipment, or labor and employment practices that, in Landlord's good faith judgment, may cause strikes, picketing or boycotts or disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Property.
Labor Harmony. Notwithstanding anything contained herein to the contrary, Tenant shall not use (and upon notice from Landlord shall cease using) contractors, subcontractors, services, workmen, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with the workforce or trades engaged in performing other work, labor or services in or about the Project, Building or the Common Areas and/or that otherwise results in picketing or other labor disturbances at the Project and/or on property adjacent thereto. L&K Engineering
Labor Harmony. Tenant will not, directly or indirectly, knowingly employ or permit the employment of any contractor, shipper, mechanic or laborer or permit any items or materials to be brought into the Premises or the rest of the Project, if it would create any work slow down, sabotage, strike, wild-cat strike, picketing or jurisdictional dispute, or would in any way disturb the peaceful and harmonious operation, management, maintenance, cleaning, security or improvement of the Project or any part thereof (in any case, a “Labor/Disturbance Incident”). Tenant will be solely responsible for all Liabilities resulting from any such Labor/Disturbance Incident, and, without limiting any other rights and remedies of Landlord, upon demand of Landlord Tenant at its cost immediately will cause all contractors, shippers, mechanics, laborers, items or materials that are the subject or cause of such Labor/Disturbance Incident to be removed from the Project
