Landlord's Improvements All fixtures, improvements or equipment which are installed, constructed on or attached to the Premises or Common Area by Landlord shall be a part of the realty and belong to Landlord.
LESSEE'S IMPROVEMENTS Since Lessor is the Insuring Party, Lessor shall not be required to insure Lessee-Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease.
Damage or Destruction of Premises If the Premises, the Unit or the Building or any part thereof shall be damaged or destroyed by fire or other casualty (a “casualty”), or ordered to be demolished by the action of any public authority in consequence of a casualty, or taken by any exercise of the right of eminent domain, Tenant shall immediately give notice thereof to Landlord. Unless this Lease is terminated as provided herein, this Lease shall remain in full force and effect and Landlord shall proceed (or shall cause the Primary Board to proceed) with diligence to repair or cause to be repaired such damage so as to restore the Premises, the Building and access thereto, or what may remain thereof (including the Initial Tenant Work but excluding any other Tenant Work), as nearly as practicable to the condition they were in immediately prior to such damage, destruction or taking, subject to then applicable Legal Requirements and Title Matters, but neither Landlord nor the Primary Board shall be required to expend in such repair or rebuilding more than the proceeds of insurance or award of damages, if any, recovered or recoverable with respect to such damage, destruction or taking (plus, in the case of casualty, the amount of any insurance deductibles (which shall be deemed Operating Costs)), less Landlord’s (or the Primary Board’s) reasonable expenses incurred in collecting such proceeds or award, as the case may be, but in the case of damage or destruction only to the extent Landlord was carrying the insurance required to be carried pursuant to this Lease at the time of such damage or destruction. All such repairs made necessary by any negligent act or omission or any willful misconduct of Tenant shall be made by Landlord (or the Primary Board) at Tenant’s expense to the extent that the cost of such repairs is not covered by insurance proceeds available therefor (including the payment by Tenant of any applicable deductible amount). Landlord shall not be liable for delays in the making of any such repairs that are due to Force Majeure, nor shall Landlord be liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting from delays in repairing such damage. All repairs to and replacements of Tenant Property and any Tenant Work other than the Initial Tenant Work shall be made by and at the expense of Tenant, which work Tenant shall promptly commence as soon as practicable and thereafter prosecute diligently to completion.
DAMAGE TO TENANT'S PROPERTY Notwithstanding anything to the contrary in this Lease, Landlord or its agents shall not be liable for (a) any damage to any property entrusted to employees of the Building or its property managers, (b) loss or damage to any property by theft or otherwise, (c) any injury or damage to persons or property resulting from fire, explosion, falling plaster, steam, gas, electricity, water or rain which may leak from any part of the Building or from the pipes, appliances or plumbing work therein or from the roof, street or sub-surface or from any other place or resulting from dampness or any other cause whatsoever, or (d) any damage or loss to the business or occupation of Tenant arising from the acts or neglect of other tenants or occupants of, or invitees to, the Building. Tenant shall give prompt notice to Landlord in case of fire or accident in the Premises or in the Building or of defects therein or in the fixtures or equipment.
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
Landlord Improvements Landlord shall substantially complete the Landlord Improvements prior to Tenant’s taking occupancy of the Expansion Space. Landlord shall use commercially reasonable efforts to complete the Landlord Improvements by May 1, 2014. “Substantial Completion” shall mean the Landlord Improvements have been constructed in material accordance with the above referenced drawing, save and except for minor “punch list” items such that Tenant can occupy the Expansion Space and conduct its business, Landlord has obtained all approvals from the applicable governmental authorities for the legal occupancy of the Expansion Space and Landlord has delivered possession of the Expansion Space to Tenant in the required condition, which date is currently anticipated to be May 1, 2014. Upon Substantial Completion, Landlord shall deliver possession of the Expansion Space to Tenant in good, vacant, broom clean condition, with all building systems in good working order and the roof water-tight, and in compliance with all laws applicable to Landlord or Tenant. In the event that construction of the Landlord Improvements is not substantially completed by May 1, 2014, then the Expansion Space Commencement Date shall be automatically amended to be that date the Expansion Space is delivered to Tenant with the Landlord Improvements substantially complete. Upon Substantial Completion of the Landlord Improvements, Landlord shall give Tenant (i) written notice (“Notice of Completion”) that the Expansion Space are ready for occupancy. Within seven (7) days following Landlord’s giving of the Notice of Completion, Landlord and Tenant shall meet at a mutually convenient time to perform a walk-through of the Expansion Space to inspect the Landlord Improvements and to prepare a punch list of minor items needing correction and Landlord shall promptly cause such items to be corrected.
Landlord Repairs Notwithstanding anything contrary herein, Landlord shall repair, replace and restore the foundation, exterior and interior load-bearing walls, roof structure and roof covering and tuckpointing of the Property; provided, however, that (i) all costs and expenses so incurred by Landlord to repair, replace and restore the above items shall constitute Operating Expenses; provided, however, that with respect to any costs incurred in the replacement context, those costs shall not constitute an Operating Expense except to the extent that such costs so qualify under SECTION 3.1.1(vii); and (ii) notwithstanding (i) above, in the event that any such repair, replacement or restoration is necessitated by any or all of the matters set forth in SECTIONS 13.1(a) through (d) above (collectively, "TENANT NECESSITATED REPAIRS"), then Tenant shall be required to reimburse Landlord for all costs and expenses that Landlord incurs in order to perform such Tenant Necessitated Repairs, and such reimbursement shall be paid, in full, within 10 days after Landlord's delivery of demand therefor. Landlord agrees to commence the repairs, replacements or restoration described in this SECTION 13.2 within a reasonable period of time after receiving from Tenant written notice of the need for such repairs.
Premises and Common Areas 3 3. TERM .................................................................5 4. POSSESSION ...........................................................5 5.
Landlord’s Damages In the event of any condemnation or taking, whether whole or partial, the Tenant shall not be entitled to any part of the award paid for such condemnation and Landlord is to receive the full amount of such award, the Tenant hereby expressly waiving any rights or claim to any part thereof.
Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
