Tenant’s Plans (i) Tenant shall diligently pursue the preparation of all drawings, plans and specifications for Tenant Improvements in accordance with this Paragraph 2(b). All such plans, drawings and specifications shall be performed by an architect and/or engineer (as applicable) reasonably acceptable to Landlord and Tenant, and shall include the following: (i) a space plan for the Premises; (ii) complete architectural, engineering and other plans for the Tenant Improvements; and (iii) a list of tenant improvement building standards for interior design, including a schedule (e.g. color palate, material board and spec sheets) of all interior color and finishes. Items (ii) and (iii) above are collectively referred to herein as “Working Drawings”. The space plan and Working Drawings shall comply with all applicable regulations, laws, ordinances, codes and rules. Tenant shall submit its space plan to Landlord, for review and approval in Landlord’s sole discretion. Within ten (10) business days after such submission, Landlord shall either approve or disapprove the space plan. Tenant shall make any changes necessary in order to correct any item identified by Landlord as grounds for its disapproval, and shall resubmit the correct space plan to Landlord within ten (10) business days after Landlord’s disapproval. Within ten (10) business days after Landlord received the revised space plan, Landlord shall approve or disapprove it. This procedure shall be repeated until the space plan is finally approved by Landlord and written approval has been delivered to Tenant. If Landlord fails to approve or disapprove any submission within the required time period Landlord shall be deemed to have disapproved such submission. Landlord has approved the space plan for Building 2, a copy of which is attached hereto as Schedule 2 (the “Building 2 Space Plan”), subject to Landlord’s right to review and approve the Working Drawings, interior color and finishes, materials, specifications, and other items pursuant to Paragraph 2(b)(ii) and (iii) below, and further subject to compliance and conformance with the Minimum Specifications (as defined in Paragraph 2(b)(iii) below).
(ii) Within twenty-one (21) days after Landlord has finally approved Tenant’s space plan, Tenant shall submit its Working Drawings and a pallet of interior colors and finishes to Landlord for Landlord’s review and approval, in Landlord’s sole discretion. Landlord’s approval or disapproval of such Working Drawings and pallet, and Tenant’s response thereto, shall follow the procedure (including deemed disapproval) described in Subsection (i) above with respect to the space plan. All items finally approved by Landlord pursuant to this Paragraph 2(b) are referred to herein collectively as “Tenant’s Plans”. Once approved by Landlord, no changes shall be made to Tenant’s Plans without the prior written approval of Landlord, in Landlord’s sole discretion.
(iii) Landlord has established a partial list of Minimum Building Specifications for Building 2 (the “Minimum Specifications”) which is attached to this Exhibit as Schedule 1, for use in the design and construction of the Tenant Improvements, provided that the Minimum Specifications is not a complete list of products, specifications and finishes to be used in the construction of the Tenant Improvements and accordingly, Tenant shall cause to be described in the Working Drawings all products, specifications and finishes to be used in the construction of the Tenant Improvements which are not otherwise listed on, or which deviate from, the Minimum Specifications, all of which shall be subject to Landlord’s approval in Landlord’s sole discretion. Unless otherwise expressly agreed to by Landlord, the portion of the Tenant Improvements pertaining to the products, specifications and finishes specified in the Minimum Specifications shall comply with the Minimum Specifications.
Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work.
Section 5.2 Prior to commencing any Tenant’s Work other than purely Cosmetic Alterations, Tenant shall, at Tenant’s expense, deliver to Landlord detailed plans and specifications, for Tenant’s Work, in form reasonably satisfactory to Landlord, prepared, certified, signed and sealed by an architect or engineer licensed to practice in the State of New York, and suitable for filing with the applicable Authority, if filing is required by applicable Laws (such plans and specifications together with revisions thereto, collectively, “Tenant’s Plans”), and obtain Landlord’s approval of Xxxxxx’s Plans. Xxxxxxxx’s approval of Xxxxxx’s Plans shall not be unreasonably withheld or delayed to the extent Xxxxxxxx’s consent to Xxxxxx’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article. Before commencing Tenant’s Work, Tenant shall (a) obtain (and deliver to Landlord copies of) all required permits and authorizations of any Authority for such work, and (b) deliver to Landlord such security as shall be reasonably satisfactory to Landlord, and (c) deliver to Landlord certificates (in form reasonably acceptable to Landlord) evidencing the following insurance coverages from each contractor and subcontractor: (i) worker’s compensation insurance covering all persons to be employed in the performance of any Tenant’s Work, and
Tenant's Improvements If the Lessor is the Insuring Party, the Lessor shall not be required to insure Lessee Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease. If Lessee is the Insuring Party, the policy carried by Lessee under this Paragraph 8.3 shall insure Lessee Owned Alterations and Utility Installations.
Tenant Improvements Landlord shall cause the Core and Shell Contractor or another Contractor designated by Landlord and approved by Tenant, such consent not to be unreasonably withheld or delayed (“TI Contractor”, and together with Core and Shell Contractor, “Contractor”) to commence and thereafter diligently prosecute the construction of the tenant improvements in the Premises pursuant to the Work Letter (the “Tenant Improvements”); provided, however, that before performing the Tenant Improvements, Landlord shall prepare in good faith an estimated budget for the construction of the Tenant Improvements and deliver such budget to Tenant for Tenant’s written approval prior the start of construction (the “Budget”). Landlord and Tenant shall work together cooperatively and in good faith to achieve a mutually acceptable Budget. Landlord shall update the Budget for Tenant’s review and approval at reasonable intervals and shall notify Tenant in writing if the Budget is likely to be exceeded. If there is an indication that the Budget is likely to be exceeded, Landlord and Tenant shall work together cooperatively, if required by Tenant, to modify the scope of the Tenant Improvements to bring the same in line with a budget reasonably acceptable to Tenant. The Tenant Improvements shall be performed in a workmanlike manner and shall substantially conform with Applicable Laws and the Approved TI Plans (as defined in the Work Letter). Tenant shall pay all TI Costs, except that Landlord shall pay for TI Costs that do not exceed the TI Allowance. The “TI Allowance” shall mean (a) One Hundred Twenty Five Dollars ($125.00) per rentable square foot of the Premises (the “Initial TI Allowance”), together with (b) the Additional Allowance. The “TI Costs” shall mean all Tenant Core and Shell Costs (as defined in the Work Letter) and all costs and expenses of performing the TI Work, including without limitation the hard and soft costs of (i) construction, (ii) the Construction Management Fee (as such term is defined in the Work Letter) and any Project or construction management fees paid by Tenant to an unaffiliated third party (such fees not to exceed three percent (3%) of the TI Allowance), (iii) space planning, design, architect, engineering, data and phone cabling and other related services, (iv) costs and expenses for labor, material, equipment, data and phone cabling and fixtures (including, without limitation, any of the Attached Property (as defined in Section 18.5), (v) building permits and other taxes, fees, charges and levies by governmental and quasi-governmental agencies for permits or for inspections of the Tenant Improvements, and (vi) the Warm Shell Costs. In no event shall the TI Allowance be used for: (w) the purchase of any furniture, personal property or other non-building system equipment, (x) costs resulting from a Tenant Delay, (y) costs resulting from any default by Tenant of its obligations under this Lease, or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). In the event the estimated total TI Costs (as set forth in the Budget) exceed the TI Allowance, Tenant shall deposit with Landlord such overage (the “TI Allowance Excess”), within five (5) business days of receiving the Budget (the “TI Deposit”). In the event Landlord determines the estimate of the TI Costs set forth in the Budget underestimates the amount of TI Costs so that the TI Deposit will not be sufficient to cover the TI Allowance Excess, then Landlord shall communicate the same to Tenant and, if required by Tenant, the parties shall discuss revisions to the Budget and Tenant may make a TI Tenant Change Order Request to reduce TI Costs, and unless the TI Costs are reduced to be within the Budget and previously paid TI Deposit, Tenant shall promptly pay the additional amount to Landlord, and such additional amount shall be added to the TI Deposit. If the sum of the TI Allowance plus the TI Deposit is not sufficient to cover the TI Costs, Tenant shall reimburse Landlord the difference between (a) the TI Costs and (b) the sum of the TI Allowance and the TI Deposit. However, Landlord shall be solely responsible for any costs related to the Tenant Improvements to the extent the same result from Landlord’s gross negligence, intentional misconduct or breach of Lease. Landlord and Tenant shall work together cooperatively at no cost or risk to Landlord to maximize Tenant’s ability, to the extent reasonably possible, to obtain the benefit of any applicable research and development tax credits with respect to the Tenant Improvements.
Tenant’s Reimbursement Except as may be specifically provided to the contrary in this Lease, Tenant shall pay to Landlord, upon delivery by Landlord to Tenant of statements therefor: (i) sums equal to expenditures reasonably made and obligations incurred by Landlord in connection with the remedying by Landlord of Tenant’s defaults pursuant to the provisions of Section 26.1; (ii) sums equal to all losses, costs, liabilities, damages and expenses referred to in Article 10 of this Lease; and (iii) sums equal to all expenditures made and obligations incurred by Landlord in collecting or attempting to collect the Rent or in enforcing or attempting to enforce any rights of Landlord under this Lease or pursuant to law, including, without limitation, all reasonable legal fees and other amounts so expended. Tenant’s obligations under this Section 26.2 shall survive the expiration or sooner termination of the Lease Term.
Landlord’s Election Tenant’s request for consent to any Transfer shall he accompanied by a written statement setting forth the details of the proposed Transfer, including the name, business and financial condition of the prospective Transferee, financial details of the proposed Transfer (e.g., the term and the rent and security deposit payable), and any other related information that Landlord may reasonably require. Landlord shall have the right: (a) to withhold consent to the Transfer, if reasonable, (b) to grant consent, (c) to terminate this Lease as to the portion of the Premises affected by any proposed Transfer, in which event Landlord may enter into a lease directly with the proposed Transferee, or (d) to consent on the condition that Landlord be paid, as Additional Rent hereunder, fifty percent (50%) of all subrent or other consideration to be paid to Tenant under the terms of the Transfer in excess of the total rent due hereunder (including, if such Transfer is an assignment or if such Transfer is to occur directly or indirectly in connection with the sale of any assets of Tenant, fifty percent (50%) of the amount of the consideration attributable to the Transfer of the Lease, as reasonably determined by Landlord). The grounds on which Landlord may reasonably withhold its consent to any requested Transfer include, without limitation, that: (i) the proposed Transferee’s contemplated use of the Premises following the proposed Transfer is reasonably similar to the use of the Premises permitted hereunder, (ii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient business reputation or experience to operate a successful business of the type and quality permitted under this Lease, (iii) in Landlord’s reasonable business judgment, the proposed Transferee lacks sufficient net worth, working capital, anticipated cash flow and other indications of financial strength to meet all of its obligations under this Lease, (iv) the proposed Transfer would breach any covenant of Landlord respecting a radius restriction, location, use or exclusivity in any other lease, financing agreement, or other agreement relating to the Property, and (v) in Landlord’s reasonable business judgment, the possibility of a release of Hazardous Materials is materially increased as a result of the Transfer or if Landlord does not receive sufficient assurances that the proposed Transferee has the experience and financial ability to remedy a violation of Hazardous Materials and to fulfill its obligations under Articles 13 and 14. Landlord need only respond to any request by Tenant hereunder within a reasonable time of not less than ten (10) business days alter receipt of all information and other submission required in connection with such request.
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”):
2.2.1.1 Payment of the fees of the “Architect” and the “Engineers,” as those terms are defined in Section 3.1 of this Tenant Work Letter, the costs of Tenant’s project manager (if any) and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction Drawings,” as that term is defined in Section 3.1 of this Tenant Work Letter;
2.2.1.2 The payment of plan check, permit and license fees relating to construction of the Tenant Improvements;
2.2.1.3 The cost of construction of the Tenant Improvements, including, without limitation, contractors’ fees and general conditions, testing and inspection costs, costs of utilities, trash removal, parking and hoists, and the costs of after-hours freight elevator usage.
2.2.1.4 The cost of any changes in the Base, Shell and Core work when such changes are required by the Construction Drawings (including if such changes are due to the fact that such work is prepared on an unoccupied basis), such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith;
2.2.1.5 The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”);
2.2.1.6 Sales and use taxes;
2.2.1.7 The “Coordination Fee,” as that term is defined in Section 4.2.2.2 of this Tenant Work Letter; and
2.2.1.8 All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
