Laytime Delays Demurrage
Laytime Delays Demurrage Sample Clauses
Related to Laytime Delays Demurrage
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Demurrage If as a result of the Customer's actions and unless permission is granted by the Company, if the Equipment is not returned during or at the end of the term, then for every hour, or portion thereof, from the end of the term to the time when the Equipment is returned to the Company, as required herein, the Customer shall pay a rental rate equal to three (3) times (x) the standard hourly rental rate for such equipment.
Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.
Overtime Scheduling 1. Each employee interested in working overtime may volunteer by requesting, in writing, to be added to the voluntary overtime list within his/her building and/or the district-wide voluntary overtime list. They will also indicate whether they wish to work during their vacation period. Such written request to be added to or deleted from the overtime lists may be made at any time; however, if the employee is requesting to be deleted from the list(s), he/she shall not be allowed to rejoin the list(s) for a ninety (90) calendar day period. Such lists shall be maintained on a yearly basis, from September 1st to August 31st of each year. The employer will serve notice to the employees, by a memo into each work area, that overtime lists are being formulated, by August 15th of each year. 2. The list will be compiled for September with the volunteers listed in seniority order. Overtime shall be rotated among volunteers. The rotation shall be continuous through the year until a new list is compiled the following September. If an employee volunteers who was not on the list he/she shall be placed on the list according to his/her seniority and he/she shall be eligible to work overtime in accordance with the normal rotation. 3. To the extent possible, employees will be notified at least four (4) hours prior to the end of the shift of any overtime for that day and by noon on Friday for any Saturday overtime. Any employee who has volunteered to work overtime and is notified in accordance with this paragraph shall be obligated to work the overtime hours in their building unless excused by the supervisor. 4. Overtime assignments will be on a rotating schedule among the qualified employees within each classification who have expressly volunteered for such overtime work. The employer’s obligation to rotate overtime shall be satisfied by calling employees who are working at the time the overtime determination is made (i.e., not on vacation or other leave of absence) in seniority order and offering them the opportunity to work. 5. If there are insufficient volunteers available for any specific assignment, the employer may require the least senior employee in the division to perform the work. 6. Substantiated errors made in the rotation of overtime (Article XIII Section G.4) will be corrected on the basis of offering the by-passed employee an amount of overtime equal to the time lost due to the error of assignment. Depending on the number of hours involved, it is possible that this may take more than (1) one overtime offer/assignment. Acceptance of the compensatory overtime will not change the employees spot in the overtime rotation, thus the employee will remain eligible for overtime in the same rotation as before the error. The compensatory overtime will not be offered at such a time or in such a manner that would purposefully cause inconvenience or inability to the effected employee to comply. In the event the employee declines the offered overtime work, the employee shall forfeit any future claim to the overtime hours in dispute.
Excusable Delay The parties shall not be obligated to perform and shall not be deemed to be in default hereunder, if the performance of a non-monetary obligation required hereunder is prevented by the occurrence of any of the following, other than as the result of the financial inability of the party obligated to perform: acts of God, strikes, lock-outs, other industrial disturbances, acts of a public enemy, war or war-like action (whether actual, impending or expected and whether de jure or de facto), acts of terrorists, arrest or other restraint of government (civil or military), blockades, insurrections, riots, epidemics, landslides, lightning, earthquakes, fires, hurricanes, storms, floods, washouts, sink holes, civil disturbances, explosions, breakage or accident to equipment or machinery, confiscation or seizure by any government or public authority, nuclear reaction or radiation, radioactive contamination or other causes, whether of the kind herein enumerated or otherwise, that are not reasonably within the control of the party claiming the right to delay performance on account of such occurrence.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.
Act of God Days Act of God" days beyond the allowance by Michigan Law and the Department of Education regulations will be made up by the students and assistants at the end of the school year or at other times as specified by the calendar. Assistants will only receive compensation for the "Act of God" days allowed. When a scheduled day of schoolwork is delayed, association members shall report as near as possible to their regular starting times. Assistants will receive their full day's pay when the school day is shortened due to weather or mechanical problems.
Downtime There may be downtime during the Migration. The duration of the downtime will depend on the amount of data that Agency is migrating. Axon will work with Agency to minimize any downtime. Any VIEVU mobile application will need to be disabled upon Migration.
Outages and Interruptions Outages.
