Lessee Remediation Lessee shall not cause or permit any Hazardous Substance to be spilled or released in, on, under, or about the Premises (including through the plumbing or sanitary sewer system) and shall promptly, at Lessee's expense, take all investigatory and/or remedial action reasonably recommended, whether or not formally ordered or required, for the cleanup of any contamination of, and for the maintenance, security and/or monitoring of the Premises or neighboring properties, that was caused or materially contributed to by Lessee, or pertaining to or involving any Hazardous Substance brought onto the Premises during the term of this Lease, by or for Lessee, or any third party.
Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.
Landlord Work In accordance with the mutually acceptable space plan dated January 4, 2012 prepared by Xxxxxxxx Xxxx Xxxxxxx Architects (the “Approved Plan”) attached hereto, Landlord shall perform the following work (collectively, the “Landlord Work”): · Build out 4 offices · Install a door to connect Suites 205 and 230 · Provide appropriate surfaces and air handling · Investigate the addition of an 8’ hood in lab Landlord shall cause the Landlord Landlord shall use commercially reasonable efforts to cause the Landlord Work to be constructed in a good and workmanlike manner, substantially in accordance with the Approved Plan and in compliance with applicable laws and covenants, conditions and restrictions in effect as of the date of such completion, and in good condition and working order. The Landlord Work shall be performed by Landlord, at Landlord’s sole cost and expense. Tenant shall have the right, on not less than two (2) business days’ advance written notice to Landlord, and, if specified by Landlord at Landlord’s option, accompanied by a representative of Landlord, to inspect the construction of the Landlord Work; provided that no such inspections shall interfere with or otherwise delay Landlord’s completion of the Landlord Work. Tenant shall have the right to submit to Landlord a list of incomplete or defective items within sixty (60) days after Substantial Completion, and Landlord shall diligently repair or replace such items at Landlord’s sole cost and expense. Landlord shall use commercially reasonable efforts to cause its construction contract for the Landlord Work to contain a minimum one (1) year warranty period. EXHIBIT C ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE THIS ACKNOWLEDGEMENT OF TERM COMMENCEMENT DATE AND TERM EXPIRATION DATE is entered into as of [ ], 2012, with reference to that certain Lease dated as of August 24, 2007, as amended by that certain First Amendment to Lease dated as of March 30, 2008, that certain Second Amendment to Lease (“Second Amendment”) dated as of May 11, 2009, which Second Amendment was amended and restated pursuant to that certain Amended and Restated Second Amendment to Lease dated as of September 15, 2009, and that certain Third Amendment to Lease dated as of December [ ], 2011 (“Third Amendment”) (collectively, and as the same may have been further amended, amended and restated, supplemented or modified from time to time, the “Lease”), by RECEPTOS, INC., a Delaware corporation (“Tenant”), in favor of BMR-10835 ROAD TO THE CURE LLC, a Delaware limited liability company (“Landlord”). All capitalized terms used herein without definition shall have the meanings ascribed to them in the Lease. Tenant hereby confirms the following:
Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant as described in Section 12.01 of the Lease or any default by Tenant under this Work Letter (which, for purposes hereof, shall include, without limitation, the delivery by Tenant to Landlord of any oral or written, including electronic, notice instructing Landlord to cease the design and/or construction of the Tenant Improvements and/or that Tenant does not intend to occupy the Premises, and/or any other anticipatory breach of the Lease) has occurred at any time on or before the Substantial Completion of the Premises, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to withhold payment of all or any portion of the Tenant Improvement Allowance and/or Landlord may cause Contractor to cease the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 5.01 above), and (ii) all other obligations of Landlord under the terms of this Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to an event of default by Tenant as described in Section 12.01 of the Lease or under this Work Letter (including, without limitation, any anticipatory breach described above in this Section 6.05), then (A) Tenant shall be liable to Landlord for all damages available to Landlord pursuant to the Lease and otherwise available to Landlord at law and/or in equity by reason of a default by Tenant under the Lease or this Work Letter, and (B) Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) Business Days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord (including any portion of the Tenant Improvement Allowance disbursed by Landlord) and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Rental Abatement Provided that any damage to either or both of the Property and the Premises is not caused by, or is not the result of acts or omissions by, any or all of Tenant and Tenant’s Parties, if (a) the Property is damaged by fire or other casualty thereby causing the Premises to be inaccessible or (b) the Premises are partially damaged by fire or other casualty, the Rent shall be proportionally abated to the extent of any actual loss of use of the Premises by Tenant.
Performance of Landlords Work (a) Definition of Landlord’s Work. As used herein, “
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
Tenant’s Compliance With Landlord’s Fire and Casualty Insurance Tenant shall, at Tenant’s expense, comply with all insurance company requirements pertaining to the use of the Premises. If Tenant’s conduct or use of the Premises causes any increase in the premium for such insurance policies then Tenant shall reimburse Landlord for any such increase. Tenant, at Tenant’s expense, shall comply with all rules, orders, regulations or requirements of the American Insurance Association (formerly the National Board of Fire Underwriters) and with any similar body.
Tenant Allowance Landlord shall provide Tenant an allowance for each Building in an amount not to exceed the sum set forth in the Basic Lease Information for the Tenant Allowance for the applicable Building (collectively, the “Tenant Allowance”), to be applied toward the cost of the following items in respect of the Tenant Improvements in the applicable Building: Architectural and engineering fees, space planning, building permits or other governmental fees, and the cost of labor, materials, contractors fees and overhead, and other charges included in the construction contract for construction of Tenant Improvements, including the contractor’s fee, overhead and general conditions, sales and use taxes, the cost of the builder’s risk insurance during construction and all testing and inspection costs. If Landlord elects to itself construct the Restroom Improvements, Landlord shall make payments to its contractor for the Restroom Improvements as and when such costs are incurred and deduct the amount of such payments from the Tenant Allowance for Building 2 up to the maximum amount stated in Paragraph I of this Work Letter. Landlord shall not be obligated to disburse any remaining portion of the Tenant Allowance attributable to a Building until such time as (i) the Commencement Date for the applicable Building has occurred and Tenant has accepted delivery of the Building and made the initial prepayment of Rent with respect to the applicable portion of the Premises; and (ii) Tenant has delivered to Landlord and Landlord has approved, in Landlord’s reasonable discretion, all of the following: (A) invoices, paid receipts and/or related evidence reasonably acceptable to Landlord establishing that Tenant has paid an amount equal to that portion of the Tenant Allowance requested by Tenant to third parties in connection with the Tenant Improvements in the applicable Building; (B) executed unconditional final mechanics’ lien releases, in statutory form, from Tenant’s contractor and all subcontractors, laborers, materialmen and suppliers used by Tenant with respect to all work in and to the Premises located in the applicable Building; (C) a certificate from Tenant’s architect or space planner, in a form reasonably acceptable to Landlord, certifying that the construction of the Tenant Improvements in the applicable Building has been substantially completed and meets all applicable building codes; (D) a copy of the certificate of occupancy (or similar governmental authorization) for the applicable Building; (E) “as-built” drawings for the Tenant Improvements in the applicable Building, signed by either Tenant’s architect, space planner or contractor, and electronic CAD files from Tenant’s Contractor and all subcontractors; and (F) a final punch list signed off by both Tenant and Landlord and/or their architects. Thereafter, Landlord shall deliver, within fifteen (15) days following Tenant’s delivery of the materials and information required for disbursement thereof in the preceding sentence, a check payable to Tenant in the amount of that portion of the Tenant Allowance requested by Tenant and paid to third parties in connection with the Tenant Improvements for the applicable Building (which amount shall not exceed the portion of the Tenant Allowance provided for such Building as specified in the Basic Lease Information). Landlord’s payment of any portion of the Tenant Allowance shall not be deemed Landlord’s approval any of the Tenant Improvements absent Landlord’s prior approval pursuant to this Work Letter. Landlord’s obligation to disburse the Tenant Allowance for each Building under this Paragraph 9(b) shall expire six (6) months after the Delivery Date for the applicable Building, subject to extension due to Force Majeure, such that Landlord shall not be obligated to provide to Tenant any undisbursed portion of the Tenant Allowance for a Building unless Tenant has delivered to Landlord all documents required above within nine (9) months after the Delivery Date of such Building.
