Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.
Force Majeure Event After giving effect to any applicable provision, disruption fallback or remedy specified in, or pursuant to, the relevant Confirmation or elsewhere in this Agreement, by reason of force majeure or act of state occurring after a Transaction is entered into, on any day:—
(1) the Office through which such party (which will be the Affected Party) makes and receives payments or deliveries with respect to such Transaction is prevented from performing any absolute or contingent obligation to make a payment or delivery in respect of such Transaction, from receiving a payment or delivery in respect of such Transaction or from complying with any other material provision of this Agreement relating to such Transaction (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such Office so to perform, receive or comply (or it would be impossible or impracticable for such Office so to perform, receive or comply if such payment, delivery or compliance were required on that day); or
(2) such party or any Credit Support Provider of such party (which will be the Affected Party) is prevented from performing any absolute or contingent obligation to make a payment or delivery which such party or Credit Support Provider has under any Credit Support Document relating to such Transaction, from receiving a payment or delivery under such Credit Support Document or from complying with any other material provision of such Credit Support Document (or would be so prevented if such payment, delivery or compliance were required on that day), or it becomes impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply (or it would be impossible or impracticable for such party or Credit Support Provider so to perform, receive or comply if such payment, delivery or compliance were required on that day), so long as the force majeure or act of state is beyond the control of such Office, such party or such Credit Support Provider, as appropriate, and such Office, party or Credit Support Provider could not, after using all reasonable efforts (which will not require such party or Credit Support Provider to incur a loss, other than immaterial, incidental expenses), overcome such prevention, impossibility or impracticability;
Force Majeur In case the Show Facility is damaged or destroyed, or in case of war, government regulations or any other circumstances whatsoever which will make it impossible or impractical for Show Management to permit Exhibitor to occupy the exhibit space described in this Agreement, this Agreement will terminate and Exhibitor will waive any claim for damages for compensation except the pro rata return of the amount paid for space rented, diminished only by a pro rata portion of the amounts expended to produce the Show.
Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:
i) acts of God;
ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities;
iii) acts of war (whether declared or undeclared), invasion or civil unrest;
iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement);
v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals;
vi) earthquakes, explosions, accidents, landslides; fire;
vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality;
viii) chemical or radioactive contamination or ionizing radiation; or
ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs;
x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.
MAJEURE 24.1 Neither Partner shall be entitled to bring a claim for a breach of obligations under this Agreement by the other Partner or incur any liability to the other Partner for any losses or damages incurred by that Partner to the extent that a Force Majeure Event occurs and it is prevented from carrying out its obligations by that Force Majeure Event.
24.2 On the occurrence of a Force Majeure Event, the Affected Partner shall notify the other Partner as soon as practicable. Such notification shall include details of the Force Majeure Event, including evidence of its effect on the obligations of the Affected Partner and any action proposed to mitigate its effect.
24.3 As soon as practicable, following notification as detailed in Clause 24.2, the Partners shall consult with each other in good faith and use all best endeavours to agree appropriate terms to mitigate the effects of the Force Majeure Event and, subject to Clause 24.4, facilitate the continued performance of the Agreement.
24.4 If the Force Majeure Event continues for a period of more than sixty (60) days, either Partner shall have the right to terminate the Agreement by giving fourteen (14) days written notice of termination to the other Partner. For the avoidance of doubt, no compensation shall be payable by either Partner as a direct consequence of this Agreement being terminated in accordance with this Clause.
Available Relief for a Force Majeure Event 11.7.1 Subject to this Article 11:
(a) no Party shall be in breach of its obligations pursuant to this Agreement except to the extent that the performance of its obligations was prevented, hindered or delayed due to a Force Majeure Event;
(b) every Party shall be entitled to claim relief in relation to a Force Majeure Event in regard to its obligations, including but not limited to those specified under Article 4.5;
(c) For avoidance of doubt, neither Party’s obligation to make payments of money due and payable prior to occurrence of Force Majeure events under this Agreement shall be suspended or excused due to the occurrence of a Force Majeure Event in respect of such Party.
(d) Provided that no payments shall be made by either Party affected by a Force Majeure Event for the period of such event on account of its inability to perform its obligations due to such Force Majeure Event.
Epidemic Failure “Epidemic Failure” for any particular Product shall mean a failure resulting from defects in material, workmanship, and manufacturing process, including but not limited to the use of Components with known defects. The Epidemic Failure clause shall be invoked [***]. The failure rate may be calculated [***], as determined by BUYER. Epidemic failures do not supersede the requirements of any expressed or implied warranty defined herein. In the case of an epidemic failure, SUPPLIER’s obligation is to propose an action plan to fix the failure of any affected Product within seventy-two (72) hours of discovery. SUPPLIER shall implement this action plan upon BUYER’s acceptance thereof. If the action plan is not acceptable to BUYER, BUYER can require SUPPLIER to repair or replace, at BUYER’s option, the affected Product. In addition to bearing the costs associated therewith, if requested by BUYER, SUPPLIER shall support and provide at SUPPLIER’s expense a sufficient number of units of the Product to permit the field exchange or “hot swap” of Products at customer sites. The parties agree to make all reasonable efforts to complete the repair or replacement of all affected Products within eight (8) Business Days after written notice of epidemic failure by BUYER to SUPPLIER. SUPPLIER also agrees that BUYER will be supported with accelerated shipments of replacement Product to cover BUYER’s supply requirements. If an Epidemic Failure is caused by (i) a design, including a BUYER-provided test process, as required by the Specifications or (ii) a failure by a Component required by the Specifications, (iii) misuse or damage during transit or damage by a third party at no fault of SUPPLIER, SUPPLIER shall perform the obligations in this Section 10.5 and BUYER shall pay to SUPPLIER the fees mutually agreed upon by the parties in writing. If an Epidemic Failure is caused by any other reason other than as set forth in the immediately preceding sentence, SUPPLIER shall perform the obligations set forth in this Section free of charge. Confidential treatment is being requested for portions of this document. This copy of the document filed as an exhibit omits the confidential information subject to the confidentiality request. Omissions are designated by the symbol [***]. A complete version of this document has been filed separately with the Securities and Exchange Commission.
Force Majeure Notice In relation to any Relevant Force Majeure Event:
(a) as soon as reasonably practicable after the Affected Party becomes aware, or ought reasonably to have become aware, that such Force Majeure Event qualifies for relief under this Clause 17 (and, in any event, within 72 hours of becoming aware of such circumstances), the Affected Party shall give a Force Majeure Notice; and
(b) the Force Majeure Notice shall include detailed particulars (to the extent available) of the Relevant Force Majeure Event and its consequences, its effects on the Affected Party, the Relevant Obligations, the likely duration of such consequences and effects and the remedial measures proposed by the Affected Party to avoid or remove the Relevant Force Majeure Event or to mitigate its consequences and effects.
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
