Tenant’s Lease Default Notwithstanding any provision to the contrary contained in the Lease, if an event of default by Tenant of this Tenant Work Letter or the Lease has occurred at any time on or before the Substantial Completion of the Premises and remains after the expiration of applicable notice and cure periods, then (i) in addition to all other rights and remedies granted to Landlord pursuant to the Lease, at law and/or in equity, Landlord shall have the right to cause the Contractor to suspend the construction of the Premises (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such work stoppage as a Tenant Delay as set forth in Section 4.2 above), and (ii) all other obligations of Landlord under the terms of this Tenant Work Letter shall be forgiven until such time as such default is cured pursuant to the terms of the Lease (in which case, Tenant shall be responsible for any delay in the Substantial Completion of the Premises caused by such inaction by Landlord as a Tenant Delay). In addition, if the Lease is terminated prior to the Lease Commencement Date, for any reason due to a default by Tenant as described in Section 19.1 of the Lease or under this Tenant Work Letter, in addition to any other remedies available to Landlord under the Lease, at law and/or in equity, Tenant shall pay to Landlord, as Additional Rent under the Lease, within five (5) business days after Tenant’s receipt of a statement therefor, any and all costs incurred by Landlord and not reimbursed or otherwise paid by Tenant through the date of such termination in connection with the Tenant Improvements to the extent planned, installed and/or constructed as of such date of termination, including, but not limited to, any costs related to the removal of all or any portion of the Tenant Improvements and restoration costs related thereto.
Owner Default Failure of the Owner, which has not been remedied or waived, to pay the Contractor as required under the Construction Contract or to perform and complete or comply with the other material terms of the Construction Contract.
Occupancy of the Mortgaged Property As of the related Closing Date the Mortgaged Property is lawfully occupied under applicable law. All inspections, licenses and certificates required to be made or issued with respect to all occupied portions of the Mortgaged Property and, with respect to the use and occupancy of the same, including but not limited to certificates of occupancy and fire underwriting certificates, have been made or obtained from the appropriate authorities. The Mortgagor represented at the time of origination of the Mortgage Loan that the Mortgagor would occupy the Mortgaged Property as the Mortgagor's primary residence;
Landlord’s Default Subject to Landlord's right to dispute its obligation in accordance with Section 5.1.5(b), if Landlord shall default in the performance or observance of any of its covenants or obligations set forth in this Agreement, and any such default shall continue for a period of ten (10) days after Notice thereof with respect to monetary defaults, and thirty (30) days after Notice thereof with respect to non-monetary defaults, from Tenant to Landlord and, subject to Section 19.3, any applicable Facility Mortgagee, or such additional period as may be reasonably required to correct such non-monetary defaults, Tenant may declare the occurrence of a "Landlord Default" under this Agreement by giving Notice of such declaration to Landlord and to such Facility Mortgagee. Thereafter, Tenant may (but shall have no obligation to) cure the same and, subject to the provisions of the following paragraph, invoice Landlord for costs and expenses (including reasonable attorneys' fees, paralegals' fees and court costs) incurred by Tenant in curing the same. If any such costs and expenses have not been reimbursed to Tenant as of the fifth (5th) day after the Landlord receives Tenant's Notice therefor, Landlord shall pay to Tenant, a late charge computed at the Overdue Rate on the amount of such reimbursement from the expiration of the applicable cure period to the date of payment thereof. Except as otherwise expressly provided herein to the contrary, Tenant shall have no right to terminate this Agreement for any default by Landlord hereunder or under the Other Leases and no right, for any such default, to offset or counterclaim against any Rent or other charges due hereunder. If Landlord shall in good faith dispute the occurrence of any Landlord Default and Landlord, before the expiration of the applicable cure period, shall give Notice thereof to Tenant, setting forth, in reasonable detail, the basis therefor, no Landlord Default shall be deemed to have occurred and Landlord shall have no obligation with respect thereto until final adverse determination thereof; provided, however, that in the event of any such adverse determination, Landlord shall pay to Tenant interest on any disputed funds at the Disbursement Rate, from the date demand for such funds was made by Tenant until the date of final adverse determination and, thereafter, at the Overdue Rate until paid. During the term of the Operating Agreement, Landlord shall indemnify and hold Tenant harmless against all claims, costs and expenses (including reasonable attorneys' fees and paralegals' fees) arising from a Landlord Default under the terms and conditions of this Agreement which shall cause an Event of Default under Section 16.01 of the Operating Agreement or a breach by Landlord of its obligations under the Owner Agreement or the Pooling Agreement. The provisions of this Section 14.2 shall survive the termination, expiration or cancellation of this Agreement for a period of five (5) years.
Default by Lessor Lessor shall not be in default unless Lessor fails to perform obligations required of Lessor within a reasonable time, but in no event later than thirty (30) days after written notice by Lessee to Lessor and to the holder of any first mortgage or deed of trust covering the Premises whose name and address shall have theretofore been furnished to Lessee in writing, specifying wherein Lessor has failed to perform such obligation; provided, however, that if the nature of Lessor's obligation is such that more than thirty (30) days are required for performance then Lessor shall not be in default if Lessor commences performance within such 30-day period and thereafter diligently prosecutes the same to completion.
Leasehold Mortgage Tenant shall not be permitted to encumber the fee simple title in the Land, Building or Premises or any of the structures, improvements, fixtures or any other portion of the Premises, including without limitation any Addition. Tenant shall only be permitted to mortgage Tenant's interest under this Lease, which such mortgage shall in no manner alter the terms and conditions of this Lease, nor impact Landlord's rights as the owner of the Premises. In no event shall the Landlord's fee simple title in the Land, Building or the Premises or any of the structures, improvements, fixtures or any other portion of the Premises, including without limitation any Addition, be encumbered by any such leasehold mortgage. In the event Tenant desires to obtain a leasehold mortgage, Tenant shall present and Landlord shall have the right to review and approve of any leasehold mortgage and any other documents to be recorded in relation to such leasehold mortgage prior to their record to confirm that such documents do not encumber Landlord's fee simple title in the Land, Building or the Premises. Landlord agrees, upon the request of a leasehold mortgagee, to provide to such leasehold mortgagee a copy of all notices of default made by Landlord upon Tenant under this Lease, to permit such leasehold mortgagee an opportunity to cure any such defaults, which in no event shall exceed sixty (60) business days and to recognize such mortgagee or any purchaser of Tenant's leasehold interest in the Premises in foreclosure as the tenant under this Lease, provided that such mortgagee or purchaser in foreclosure complies with each and every term and provision of this Lease and that all outstanding obligations of the Tenant have been paid in full. Tenant shall reimburse Landlord's reasonable out-of-pocket costs, including attorneys fees, to review such documents.
Borrower Default Unless the Administrative Agent shall have received notice from Borrower prior to the date on which any payment is due to the Administrative Agent for the account of the Lenders or the Issuing Bank hereunder that Borrower will not make such payment, the Administrative Agent may assume that Borrower has made such payment on such date in accordance herewith and may, in reliance upon such assumption, distribute to the Lenders or the Issuing Bank, as the case may be, the amount due. In such event, if Borrower has not in fact made such payment, then each of the Lenders or the Issuing Bank, as the case may be, severally agrees to repay to the Administrative Agent forthwith on demand the amount so distributed to such Lender or the Issuing Bank with interest thereon, for each day from and including the date such amount is distributed to it to but excluding the date of payment to the Administrative Agent, at the greater of the Federal Funds Effective Rate and a rate determined by the Administrative Agent in accordance with banking industry rules on interbank compensation.
TENANT’S DEFAULTS In addition to any other event of default set forth in this Lease, the occurrence of any one or more of the following events shall constitute a default by Tenant:
(a) The failure by Tenant to make any payment of rent or additional rent required to be made by Tenant, as amid when due, where the failure continues for a period of five (5) days after written notice from Landlord to Tenant; provided, however, that any such notice shall be in lieu of, and not in addition to, any notice required under California Code of Civil Procedure Section 1161 and 1161(a) as amended. For purposes of these default and remedies provisions, the term “additional rent” shall be deemed to include all amounts of any type whatsoever other than Basic Rent to be paid by Tenant pursuant to the terms of this Lease.
(b) Assignment, sublease, encumbrance or other transfer of the Lease by Tenant, either voluntarily or by operation of law, whether by judgment, execution, transfer by intestacy or testacy, or other means, without the prior written consent of Landlord.
(c) The discovery by Landlord that any financial statement provided by Tenant, or by any affiliate, successor or guarantor of Tenant, was materially false.
(d) The failure of Tenant to timely and fully provide any subordination agreement, estoppel certificate or financial statements in accordance with the requirements of Article XIII.
(e) The failure or inability by Tenant to observe or perform any of the express or implied covenants or provisions of this Lease to be observed or performed by Tenant, other than as specified in any other subsection of this Section, where the failure continues for a period of thirty (30) days after written notice from Landlord to Tenant or such shorter period as is specified in any other provision of this Lease; provided, however, that any such notice shall be in lieu of, and not in addition to, any notice required under California Code of Civil Procedure Section 1161 and 1161(a) as amended. However, if the nature of the failure is such that more than thirty (30) days are reasonably required for its cure, then Tenant shall not be deemed to be in default if Tenant commences the cure within thirty (30) days, and thereafter diligently pursues the cure to completion.
(i) The making by Tenant of any general assignment for the benefit of creditors; (ii) the filing by or against Tenant of a petition to have Tenant adjudged a Chapter 7 debtor under the Bankruptcy Code or to have debts discharged or a petition for reorganization or arrangement under any law relating to bankruptcy (unless, in the case of a petition filed against Tenant, the same is dismissed within thirty (30) days); (iii) the appointment of a trustee or receiver to take possession of substantially all of Tenant’s assets located at the Premises or of Tenant’s interest in this Lease, if possession is not restored to Tenant within thirty (30) days; (iv) the attachment, execution or other judicial seizure of substantially all of Tenant’s assets located at the Premises or of Tenant’s interest in this Lease, where the seizure is not discharged within thirty (30) days; or (v) Tenant’s convening of a meeting of its creditors for the purpose of effecting a moratorium upon or composition of its debts. Landlord shall not be deemed to have knowledge of any event described in this subsection unless notification in writing is received by Landlord, nor shall there be any presumption attributable to Landlord of Tenant’s insolvency. In the event that any provision of this subsection is contrary to applicable law, the provision shall be of no force or effect.
Pledge, Mortgage or Charge as Collateral for a Loan
Default by Lessee If Lessee fails to make payment of any Monthly Rental within five days of delivery by Lessor of notice of any Monthly Rental that is past due, or fails to cure any other default under this Agreement within ten days of delivery by Lessor of such default, then a “Lessee Event of Default” shall exist and Lessor shall have the following remedies, which shall be cumulative rather than exclusive:
(a) the right to terminate this Agreement, and the grant of the Lease hereunder, which termination right may be exercised by written notice by Lessor to Lessee, and which termination shall be effective as of the date of such notice;
(b) the right to immediately enter upon and repossess the Designated Boat Slip and all appurtenances thereto, by forcible entry and detainer suit, or otherwise;
(c) the right to remove Lessee’s Craft (and any personal property then inside Lessee’s Craft from its mooring, and to store Lessee’s Craft (and such personal property), with all risk of loss belonging solely to Lessee, and with no liability whatsoever to Lessor, and with all costs of storage being deemed to be including among the past due Monthly Rental under this Agreement;
(d) the right to make any required repairs to the Designated Boat Slip, or to expend any other sums required to cure any defaults by Lessee under this Agreement, with all such sums expended being deemed to be included among the past due Monthly Rental under this Agreement;
(e) the right to terminate Lessee’s rights of possession with regard to the Designated Boat Slip and all appurtenances thereto, without demand or notice of any kind and without terminating this Agreement, in which event Lessor may, but shall be under no obligation to, relet all or any part of the Designated Boat Slip for credit to Lessee’s account, on such terms and conditions as Lessor in its sole discretion shall deem appropriate; and
(f) the right to exercise Lessor’s rights under the Texas Uniform Commercial Code with regard to the security interest granted to Lessor in the Secured Property. In the event of any Lessee Event of Default, Lessor shall have the right to recover from Lessee, whether by way of sale of the Secured Property, or by means of execution and levy on a judgment, or by means of voluntary payment by Lessee, or by some combination thereof: (a) all Monthly Rental that is past due, including any late payment fees due in connection therewith, (b) all Monthly Rental to come due during the remainder of the Term (assuming that Lessor has not terminated this Agreement and the Lease hereunder), (c) Lessor’s reasonable and necessary attorneys’ fees and costs of court, (d) pre-judgment at the lesser of 8% per annum or the maximum allowed by law, and (e) post-judgment interest at lesser of 10% per annum or the maximum allowed by law.
