LIMITATION ON CONSEQUENTIAL, PUNITIVE AND OTHER DAMAGES Sample Clauses

LIMITATION ON CONSEQUENTIAL, PUNITIVE AND OTHER DAMAGES. NOTWITHSTANDING ANY OTHER PROVISIONS OF THIS AGREEMENT TO THE CONTRARY, NEITHER OWNER NOR THE COMMON FACILITIES OWNER, NOR CONTRACTOR, SHALL BE LIABLE TO THE OTHER (OR TO ANY OTHER PERSON CLAIMING THROUGH THEM OR UNDER THIS AGREEMENT) PURSUANT TO THIS AGREEMENT OR UNDER ANY CAUSE OF ACTION RELATED TO THE SUBJECT MATTER OF THIS AGREEMENT, WHETHER IN CONTRACT, TORT (INCLUDING NEGLIGENCE), STRICT LIABILITY, PRODUCTS LIABILITY, PROFESSIONAL LIABILITY, INDEMNITY, CONTRIBUTION, OR ANY OTHER CAUSE OF ACTION FOR (A) SPECIAL, INDIRECT, INCIDENTAL, PUNITIVE OR CONSEQUENTIAL LOSSES OR DAMAGES; OR (B) LOSS OF PROFITS, LOSS OF USE, LOSS OF PRODUCT, LOSS OF PRODUCTIVITY, LOSS OF OPPORTUNITY, LOSS OF REVENUES, LOSS OR COST OF OBTAINING OR MAINTAINING FINANCING, COST OF CAPITAL, LOSS OF OR REDUCTION IN BONDING CAPACITY, LOSS OF GOODWILL, BUSINESS INTERRUPTION OR CLAIMS BY OWNER’S CUSTOMERS, WHETHER OR NOT ANY OF THE FOREGOING ARE CONSIDERED OR CLASSIFIED AS DIRECT, SPECIAL, INDIRECT, INCIDENTAL OR CONSEQUENTIAL DAMAGES, AND OWNER, THE COMMON FACILITIES OWNER AND CONTRACTOR ON BEHALF OF THEMSELVES AND ANY OTHER PERSON CLAIMING THROUGH THEM OR UNDER THIS AGREEMENT, HEREBY WAIVE AND RELEASE EACH OTHER FROM ALL SUCH LOSSES AND DAMAGES. THE WAIVER, RELEASE AND LIMITATION OF LIABILITY SET FORTH IN THIS SECTION 21.2 SHALL NOT APPLY TO THE DELAY LIQUIDATED DAMAGES SET OUT IN SECTION 4.3 OR THE PERFORMANCE LIQUIDATED DAMAGES SET OUT IN SECTION 5.2, OR, IF SUCH LIQUIDATED DAMAGES AMOUNTS ARE FOUND TO BE UNENFORCEABLE DUE TO A CHALLENGE BY CONTRACTOR OR CONTRACTOR’S GUARANTOR, TO ANY ACTUAL DAMAGES PAYABLE IN LIEU OF SUCH LIQUIDATED DAMAGES AMOUNTS. IF CONTRACTOR OR CONTRACTOR GUARANTOR SEEKS AN ORDER FROM A COURT OR A FINDING BY AN ARBITRATOR TO INVALIDATE OR REDUCE ANY OF THE LIQUIDATED DAMAGES AMOUNTS SET FORTH IN THIS AGREEMENT, CONTRACTOR SPECIFICALLY AGREES TO PAY OWNER ALL ACTUAL DAMAGES INCURRED BY OWNER IN CONNECTION WITH THE FAILURE TO ACHIEVE THE APPLICABLE GUARANTEED SUBSTANTIAL COMPLETION DATE OR GUARANTEED PERFORMANCE LEVELS, AS APPLICABLE; PROVIDED, THAT THE FOREGOING SHALL NOT LIMIT CONTRACTOR’S RIGHTS TO DISPUTE WHETHER OR NOT LIQUIDATED DAMAGES ARE ACTUALLY OWED. DAMAGES CLAIMED BY THIRD PARTIES (BUT NOT INCLUDING ANY OWNER INDEMNIFIED PARTIES OR CONTRACTOR INDEMNIFIED PARTIES) FOR WHICH CONTRACTOR OR OWNER HAVE A DUTY TO INDEMNIFY THE OTHER PARTY PURSUANT TO THIS AGREEMENT, SHALL NOT BE SUBJECT TO THE LIMITATIONS SET FORTH IN THIS SECTION 21.2. THE LIMITATIONS SET...
Sample 1
AutoNDA by SimpleDocs

Related to LIMITATION ON CONSEQUENTIAL, PUNITIVE AND OTHER DAMAGES

  • Waiver of Consequential and Other Damages To the fullest extent permitted by applicable law, no Borrower shall assert, and each Borrower hereby waives, any claim against any Indemnitee (as defined below), on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of this Agreement, any other Financing Document or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Loan or the use of the proceeds thereof. No Indemnitee shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Financing Documents or the transactions contemplated hereby or thereby.

  • Limitation on Consequential Damages NEITHER PARTY WILL HAVE ANY OBLIGATION OR LIABILITY (WHETHER IN CONTRACT, WARRANTY, TORT (INCLUDING NEGLIGENCE) OR OTHERWISE, AND NOTWITHSTANDING ANY FAULT, NEGLIGENCE (WHETHER ACTIVE, PASSIVE OR IMPUTED), REPRESENTATION, STRICT LIABILITY OR PRODUCT LIABILITY), FOR COVER OR FOR ANY INCIDENTAL, INDIRECT, CONSEQUENTIAL, MULTIPLIED, PUNITIVE, SPECIAL, OR EXEMPLARY DAMAGES OR LOSS OF REVENUE, PROFIT, SAVINGS OR BUSINESS ARISING FROM OR OTHERWISE RELATED TO THIS AGREEMENT, EVEN IF A PARTY OR ITS REPRESENTATIVES HAVE BEEN ADVISED OF THE POSSIBILITY OF SUCH DAMAGES. THE PARTIES ACKNOWLEDGE THAT THESE EXCLUSIONS OF POTENTIAL DAMAGES WERE AN ESSENTIAL ELEMENT IN SETTING CONSIDERATION UNDER THIS AGREEMENT.

  • Consequential and Other Damages Notwithstanding anything to the contrary contained in the Separation Agreement or this Agreement, the Provider shall not be liable to the Recipient or any of its Affiliates or Representatives, whether in contract, tort (including negligence and strict liability) or otherwise, at law or equity, for any special, indirect, incidental, punitive or consequential damages whatsoever (including lost profits or damages calculated on multiples of earnings approaches), which in any way arise out of, relate to or are a consequence of, the performance or nonperformance by the Provider (including any Affiliates and Representatives of the Provider and any unaffiliated third-party providers, in each case, providing the applicable Services) under this Agreement or the provision of, or failure to provide, any Services under this Agreement, including with respect to loss of profits, business interruptions or claims of customers.

  • Waiver of Consequential Damages, Etc To the fullest extent permitted by applicable law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document or any agreement or instrument contemplated hereby, the transactions contemplated hereby or thereby, any Loan or Letter of Credit or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed to such unintended recipients by such Indemnitee through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • Waiver of Consequential Damages To the fullest extent permitted by applicable Law, the Borrower shall not assert, and hereby waives, any claim against any Indemnitee, on any theory of liability, for special, indirect, consequential or punitive damages (as opposed to direct or actual damages) arising out of, in connection with, or as a result of, this Agreement, any other Loan Document, the Related Documents or any agreement or instrument contemplated hereby or thereby, the transactions contemplated hereby or thereby, any Term Loan or the use of the proceeds thereof. No Indemnitee referred to in subsection (b) above shall be liable for any damages arising from the use by unintended recipients of any information or other materials distributed by it through telecommunications, electronic or other information transmission systems in connection with this Agreement or the other Loan Documents, the Related Documents or the transactions contemplated hereby or thereby other than for direct or actual damages resulting from the gross negligence or willful misconduct of such Indemnitee as determined by a final and nonappealable judgment of a court of competent jurisdiction.

  • Disclaimer of Consequential Damages Notwithstanding any provision to the contrary, in no event shall any Party be liable to another Party for any incidental, consequential, special, exemplary or indirect damages, lost business profits or lost data arising out of or in any way related to the Contract Documents.

  • Limitation of Consequential Damages EXCEPT FOR (A) THIRD PARTY CLAIMS THAT ARE SUBJECT TO INDEMNIFICATION UNDER THIS ARTICLE 10, (B) CLAIMS ARISING OUT OF A PARTY’S WILLFUL MISCONDUCT OR FRAUD UNDER THIS AGREEMENT, (C) A PARTY’S BREACH OF ARTICLE 4, (D) NOVARTIS’ BREACH OF SECTION 6.5, OR (E) CLAIMS ARISING OUT OF A PARTY’S BREACH OF ITS CONFIDENTIALITY OBLIGATIONS UNDER THIS AGREEMENT, NEITHER PARTY NOR ANY OF ITS AFFILIATES WILL BE LIABLE TO THE OTHER PARTY TO THIS AGREEMENT OR ITS AFFILIATES FOR ANY INCIDENTAL, CONSEQUENTIAL, SPECIAL, PUNITIVE OR OTHER INDIRECT DAMAGES OR LOST OR IMPUTED PROFITS OR ROYALTIES, LOST DATA OR COST OF PROCUREMENT OF SUBSTITUTE GOODS OR SERVICES, WHETHER LIABILITY IS ASSERTED IN CONTRACT, TORT (INCLUDING NEGLIGENCE AND STRICT PRODUCT LIABILITY), INDEMNITY OR CONTRIBUTION, AND IRRESPECTIVE OF WHETHER THAT PARTY OR ANY REPRESENTATIVE OF THAT PARTY HAS BEEN ADVISED OF, OR OTHERWISE MIGHT HAVE ANTICIPATED THE POSSIBILITY OF, ANY SUCH LOSS OR DAMAGE.

  • Exclusion of Consequential Damages ‌ Notwithstanding anything contained herein to the contrary, neither Party will be liable under this Agreement or under any cause of action relating to the subject matter of this Agreement for any special, indirect, incidental, punitive, exemplary or consequential damages, including loss of profits, loss of use of any property or claims of customers or contractors of the Parties for any such damages.

  • Waiver of Punitive Damages Notwithstanding anything to the contrary contained in this Agreement, the Borrower hereby agrees that it shall not seek from the Lenders or the Administrative Agent punitive, consequential, or indirect damages relating to any such matters under any theory of liability.

  • Limitation on Direct Damages Except for Unlimited Liability above and Partner’s obligations to pay for the Offerings, Partner’s violation of the restrictions on use of Products and Services or Dell or its Affiliates’ intellectual property rights, and to the extent permitted by the applicable local law, Dell’s (including its suppliers’) total liability arising out of any Dispute or any matter under the Agreement, is limited to the lower amount of either (a) the amount Partner paid to Dell during the 12 months before the date that the matter or Dispute arose for the Product, Services or both that are the subject of the Dispute; or (b) $1,000,000 USD (or equivalent in local currency) (“Liability Cap”). This excludes amounts received as reimbursement of expenses or payment of taxes. The existence of more than one claim will not increase or otherwise alter these limitations on Dell’s liability. Notwithstanding anything otherwise set forth above, Dell (and its suppliers) shall have no liability for any direct damages resulting from Partner’s use or attempted use of Third-Party Software, Free Software or Development Tools (all defined in the XXXX), or Third Party Products.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!