Continuation of Work During Dispute. Notwithstanding any dispute, it shall be the responsibility of each Party to continue to perform its obligations under this Agreement pending resolution of the dispute.
Continuation of Work During Dispute. Notwithstanding any Dispute, it shall be the responsibility of each Party to continue to perform its obligations under this Agreement pending resolution of Disputes. Owner shall, subject to its right to withhold or offset amounts pursuant to this Agreement, continue to pay Contractor undisputed amounts in accordance with this Agreement and, except as provided in this Agreement, continue to perform all of its obligations under this Agreement; provided, however, in no event shall the occurrence of any negotiation or arbitration prevent or affect Owner from exercising its rights under this Agreement, including Owner’s right to terminate pursuant to Article 16.
Continuation of Work During Dispute. Notwithstanding any Dispute, it shall be the responsibility of Contractor to continue to prosecute all of the Work diligently and in a good and workmanlike manner in conformity with this Agreement. Except to the extent provided in Sections 16.4 or 16.5, Contractor shall have no right to cease performance hereunder or to permit the prosecution of the Work to be delayed. Owner shall, subject to its right to withhold or offset amounts pursuant to this Agreement, continue to pay Contractor undisputed amounts in accordance with this Agreement; provided, however, in no event shall the occurrence of any negotiation or litigation or arbitration prevent or limit either Party from exercising its rights under this Agreement, including either Party’s right to terminate pursuant to ARTICLE 16.
Continuation of Work During Dispute. In the event Consultant has a dispute with XXXXXX during the performance of this Agreement, Consultant shall continue to perform unless SANDAG informs Consultant in writing to cease performance. Consultant shall submit a statement of the grounds for the dispute, including all pertinent dates, names of persons involved, and supporting documentation to the SANDAG Project Manager. The Project Manager and other appropriate SANDAG staff will review the documentation in a timely manner and reply to Consultant within 20 calendar days. Upon receipt of an adverse decision by XXXXXX, Consultant may submit a request for reconsideration to the SANDAG Executive Director. The request for reconsideration must be received within ten calendar days from the postmark date of the SANDAG reply. The Executive Director will respond to the request for reconsideration within ten working days. The decision of the Executive Director will be in writing.
Continuation of Work During Dispute. Subject to Section 2.2 hereof, notwithstanding any Dispute it shall be the responsibility of each Party to continue to perform its obligations under this Agreement pending resolution of Disputes. [Signature page follows]
Continuation of Work During Dispute. Subject to Section 2.2 hereof, notwithstanding any dispute, it shall be the responsibility of each Party to continue to perform its obligations under this Agreement pending resolution of the dispute. AS WITNESS HEREOF, the Parties have caused this Agreement to be executed by their duly authorized representatives on the date herein above mentioned. QUICKSILVER RESOURCES INC. By: /s/ Pxxxxx Xxxx Name: Pxxxxx Xxxx Title: Senior Vice President—Chief Financial Officer QUICKSILVER GAS SERVICES GP LLC By: /s/ Pxxxxx Xxxx Name: Pxxxxx Xxxx Title: Senior Vice President—Chief Financial Officer EXHIBIT A TO THE SERVICES AND SECONDMENT AGREEMENT This Exhibit A is attached the Services and Secondment Agreement (the “Agreement”) dated August 10, 2007 by and between QUICKSILVER RESOURCES INC. and QUICKSILVER GAS SERVICES GP LLC. All defined terms used herein shall have the same meaning as set forth in the Agreement. All information must be filled in for this form to be valid. SECONDED EMPLOYEE SCHEDULE Name of Seconded Employee Title and Job Function Start Date QUICKSILVER RESOURCES INC. QUICKSILVER GAS SERVICES GP LLC By: By: Name: Pxxxxx Xxxx Name: Pxxxxx Xxxx Title: Senior Vice President—Chief Financial Officer Title: Senior Vice President—Chief Financial Officer EXHIBIT B TO THE SERVICES AND SECONDMENT AGREEMENT This Exhibit B is attached the Services and Secondment Agreement (the “Agreement”) dated August 10, 2007 by and between QUICKSILVER RESOURCES INC. and QUICKSILVER GAS SERVICES GP LLC. All defined terms used herein shall have the same meaning as set forth in the Agreement.
Continuation of Work During Dispute. Notwithstanding any Dispute, Contractor shall continue to prosecute all of the Work diligently and in a good and workmanlike manner in conformity with this Agreement. Except to the extent provided in Section 19.4, Contractor shall not cease performance of the Work or its obligations hereunder, or permit the performance of the 216 Work to be delayed. Owner shall, subject to its right to withhold or offset amounts pursuant to this Agreement, continue to pay Contractor amounts not in Dispute in accordance with this Agreement; provided, however, that in no event shall the occurrence of any negotiation or litigation prevent or affect Owner from exercising its rights under this Agreement, including Owner’s right to terminate pursuant to Article 19.
Continuation of Work During Dispute. Notwithstanding any Dispute, it shall be the responsibility of each Party to continue perform its obligations under this Agreement pending resolution of the Dispute. Except to the extent provided in Sections 16.4 or 16.5, Contractor shall have no right to cease performance hereunder or to permit the prosecution of the Work to be delayed. Owner shall, subject to its right to withhold or offset amounts pursuant to this Agreement, continue to pay Contractor undisputed amounts in accordance with this Agreement. In no event shall the occurrence of any negotiation, litigation or arbitration prevent or limit either Party from exercising its rights under this Agreement, including either Party’s right to terminate pursuant to Article 16.
Continuation of Work During Dispute. Notwithstanding any Dispute, it shall be the responsibility of each Party to continue to perform its obligations under this Agreement pending resolution of Disputes, provided Operator shall not be required to continue providing Services if Owner is not paying Operator the Fees under Article IX.
Continuation of Work During Dispute. Notwithstanding any Dispute, the development, design and construction of the Event Centre shall continue, to the extent commercially reasonable to do so in light of the Dispute in question, in accordance with the terms of this Agreement and the Development Management Agreement.
