Limitations on Owner's Responsibilities Sample Clauses

Limitations on Owner's Responsibilities. Owner shall not supervise, direct, or have control or authority over, nor be responsible for, Contractor's means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of Contractor to comply with Laws and Regulations applicable to the performance of the Work. Owner will not be responsible for Contractor's failure to perform the Work in accordance with the Contract Documents.
Sample 1Sample 2Sample 3See All (35)
AutoNDA by SimpleDocs
Limitations on Owner's Responsibilities. A. The OWNER shall not supervise, direct, or have control or authority over, nor be responsible for, CONTRACTOR’s means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the performance of the Work. OWNER will not be responsible for CONTRACTOR’s failure to perform the Work in accordance with the Contract Documents.
Sample 1Sample 2Sample 3
Limitations on Owner's Responsibilities. Whenever in the Contract Documents the terms “as ordered”, “as directed”, “as required”, “as allowed”, “as approved” or terms of like effect or import are used or the adjectives “reasonable”, “suitable”, “acceptable”, “proper”, “satisfactory” or adjectives of like effect or import are used to describe requirement, direction, review or judgment of Owner as to the Work, it is intended that such requirement, direction, review or judgment will be solely to evaluate the Work for compliance with the Contract Documents (unless there is a specific statement indicating otherwise). The use of any such term or adjective shall not be effective to assign to Owner any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or authority to undertake responsibility for Design-Builder’s means, methods, techniques, sequences, procedures of construction, or for Design-Builder’s acts or omissions, including the acts or omissions of any of Design Builder’s subcontractors or suppliers.
Sample 1Sample 2
Limitations on Owner's Responsibilities. Owner shall not supervise, direct, or have control or authority over, nor be responsible for, DB Entity’s means, methods, techniques, sequences, or procedures of construction or the safety precautions and programs incident thereto, or for any failure of DB Entity to comply with Laws or Regulations applicable to the furnishing or performance of the Work. Owner will not be responsible for DB Entity’s failure to perform the Work in accordance with the Contract Documents.
Sample 1
Limitations on Owner's Responsibilities. Owner is not responsible for the acts or omissions of Contractor or Contractor’s employees, Subcontractors, manufacturers, fabricators, suppliers, distributors, or any other persons at the site or otherwise performing any of the Work, or their agents or employees.
Sample 1

Related to Limitations on Owner's Responsibilities

  • OWNER’S RESPONSIBILITIES 2.1. The Owner shall designate in writing a project coordinator to act as OWNER's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever: (a) The scope of services to be provided and performed by the CONTRACTOR hereunder; (b) The time the CONTRACTOR is obligated to commence and complete all such services; or (c) The amount of compensation the OWNER is obligated or committed to pay the CONTRACTOR. 2.2. The Project Coordinator shall: (a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement; (b) Arrange for access to and make all provisions for CONTRACTOR to enter the Project site to perform the services to be provided by CONTRACTOR under this Agreement; and (c) Provide notice to CONTRACTOR of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONTRACTOR hereunder. 2.3. CONTRACTOR acknowledges that access to the Project Site, to be arranged by OWNER for CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR. 3.1. Services to be rendered by CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed by December 29, 2006. Time is of the essence with respect to the performance of this Agreement. 3.2. Should CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONTRACTOR shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension. 3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONTRACTOR's services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from OWNER. XXXXXXXXXX's sole remedy against OWNER will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONTRACTOR after expiration of said 18 month period. 3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.

  • Owner Responsibilities The project owner or the engineer or architect of record acting as the owner’s agent shall fund special inspection services.

  • Customer’s Responsibilities 2.1. A properly configured hardware firewall is required for each Customer Location using a persistent connection to the public internet or any private network where there is a potential for unauthorized access. This requirement is Customer’s responsibility. 2.2. Unless you subscribe to the Network and Security Services option known as “Antivirus Service” (or its successor product), Customer will be required to have and maintain in place third party malware and anti-virus protection software, including periodic and routine updates in accordance with the manufacturer’s recommendations, and security for the Customer’s POS System Network, which security includes unique, strong passwords per user, physical security and access control policies. Customer acknowledges and agrees that security and protection of all of its networks, including the Customer POS System Network, and the data and applications on such networks, including protections against unauthorized access, is Customer’s responsibility. Customer acknowledges that, to be effective, malware protection software, system passwords and other security software and hardware components require periodic and routine updates, which Customer must obtain or perform as applicable. Customer agrees to not use or attempt to install remote access software on the Customer POS System Network unless approved by NCR Voyix.

  • PURCHASER's Responsibilities For the duration of the suspension, PURCHASER is responsible to continue maintenance at the operations just as if the operations was in progress. This includes, but is not limited to, protection of completed operations, maintenance of access, protection of stored materials, temporary facilities, and clean-up.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!