Limited Permitting Assistance by the County Sample Clauses

Limited Permitting Assistance by the County. The County shall provide reasonable assistance to the Company in connection with the Company's obligation to obtain and maintain the Governmental Approvals which the Company is required to obtain under this Section, including signing permit applications, attending public hearings and meetings of the Governmental Bodies charged with issuing such Governmental Approvals, and providing the Company with existing relevant data and documents that are within its custody or control and which are reasonably required for such purpose; provided, however, that the County's obligation to provide such reasonable assistance shall be limited, in light of the Company's primary role in the permitting and development of the Design/Build Improvements, only to those actions which are legally required to be taken by the County as permittee or which involve providing information which is solely in the possession of the County. The County, however, shall not take any action which seeks to cause the denial or delay of any application for a Governmental Approval. Any agreement by the County to cooperate does not in any way obligate the County with respect to usual and customary County permitting, code compliance and other regulatory reviews as they may relate to the Company or the Company's requirements hereunder. The outcome of any regulatory review or action undertaken by the County involving the Company will be independent of and in no way biased, prejudiced, or predetermined in any way by this Contract. Nothing in this Contract is intended or shall be construed to require that the County exercise its discretionary authority under its regulatory ordinances in a manner favorable to the Company.
Sample 1
AutoNDA by SimpleDocs

Related to Limited Permitting Assistance by the County

  • TERMINATION BY THE CONTRACTOR If the Work is stopped for a period of thirty days under an order of any court or other public authority having jurisdiction, or as a result of an act of government, such as a declaration of a national emergency making materials unavailable, through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing any of the Work under a contract with the Contractor, or if the Work should be stopped for a period of thirty days by the Contractor because the Architect has not issued a Certificate for Payment as provided in Paragraph 9.7 of these General Conditions or because the State has not made payment thereon as provided in Paragraph 9.7, then the Contractor may, upon seven additional days written notice to the State and the Architect, terminate the Contract and recover from the State payment for all Work executed and for any proven loss sustained upon any materials, equipment, tools, construction equipment and machinery, including reasonable profit and damages.

  • Assistance by COUNTY STAFF 1.3.1. County shall assign an appropriate staff member to work with A-E in connection with the work of this Contract. Said staff member's duties will consist of the giving of advice and consultations, assisting A-E in negotiations with other public agencies and private parties, miscellaneous items which in the judgment of A-E or County's staff warrant attention, and all other duties as may be described in Attachment A. 1.3.2. All of the above activities, however, shall be the primary responsibility of A-E to schedule, initiate and carry through to completion.

  • Release by the Contractor The acceptance by the Contractor of final payment shall release NYSERDA from all claims and liability that the Contractor, its representatives and assigns might otherwise have relating to this Agreement.

  • Acceptance by the Company The Company acknowledges that, by signing this Election or arranging for the scanned signature of an authorised representative to appear on this Election, the Company agrees to be bound by the terms of this Election.

  • Termination by the University i) The university may terminate this agreement under the following circumstances:

  • Cooperation by the Company If any Shareholder shall transfer any Registrable Securities pursuant to Rule 144, the Company shall cooperate, to the extent commercially reasonable, with such Shareholder and shall provide to such Shareholder such information as such Shareholder shall reasonably request.

  • Termination by ICANN (a) ICANN may, upon notice to Registry Operator, terminate this Agreement if: (i) Registry Operator fails to cure (A) any fundamental and material breach of Registry Operator’s representations and warranties set forth in Article 1 or covenants set forth in Article 2, or (B) any breach of Registry Operator’s payment obligations set forth in Article 6 of this Agreement, each within thirty (30) calendar days after ICANN gives Registry Operator notice of such breach, which notice will include with specificity the details of the alleged breach, (ii) an arbitrator or court of competent jurisdiction has finally determined that Registry Operator is in fundamental and material breach of such covenant(s) or in breach of its payment obligations, and (iii) Registry Operator fails to comply with such determination and cure such breach within ten (10) calendar days or such other time period as may be determined by the arbitrator or court of competent jurisdiction. (b) ICANN may, upon notice to Registry Operator, terminate this Agreement if Registry Operator fails to complete all testing and procedures (identified by ICANN in writing to Registry Operator prior to the date hereof) for delegation of the TLD into the root zone within twelve (12) months of the Effective Date. Registry Operator may request an extension for up to additional twelve (12) months for delegation if it can demonstrate, to ICANN’s reasonable satisfaction, that Registry Operator is working diligently and in good faith toward successfully completing the steps necessary for delegation of the TLD. Any fees paid by Registry Operator to ICANN prior to such termination date shall be retained by ICANN in full. (c) ICANN may, upon notice to Registry Operator, terminate this Agreement if (i) Registry Operator fails to cure a material breach of Registry Operator’s obligations set forth in Section 2.12 of this Agreement within thirty (30) calendar days of delivery of notice of such breach by ICANN, or if the Continued Operations Instrument is not in effect for greater than sixty (60) consecutive calendar days at any time following the Effective Date, (ii) an arbitrator or court of competent jurisdiction has finally determined that Registry Operator is in material breach of such covenant, and (iii) Registry Operator fails to cure such breach within ten (10) calendar days or such other time period as may be determined by the arbitrator or court of competent jurisdiction. (d) ICANN may, upon notice to Registry Operator, terminate this Agreement if (i) Registry Operator makes an assignment for the benefit of creditors or similar act, (ii) attachment, garnishment or similar proceedings are commenced against Registry Operator, which proceedings are a material threat to Registry Operator’s ability to operate the registry for the TLD, and are not dismissed within sixty (60) calendar days of their commencement, (iii) a trustee, receiver, liquidator or equivalent is appointed in place of Registry Operator or maintains control over any of Registry Operator’s property, (iv) execution is levied upon any material property of Registry Operator, (v) proceedings are instituted by or against Registry Operator under any bankruptcy, insolvency, reorganization or other laws relating to the relief of debtors and such proceedings are not dismissed within sixty (60) calendar days of their commencement, or (vi) Registry Operator files for protection under the United States Bankruptcy Code, 11 U.S.C. Section 101, et seq., or a foreign equivalent or liquidates, dissolves or otherwise discontinues its operations or the operation of the TLD. (e) ICANN may, upon thirty (30) calendar days’ notice to Registry Operator, terminate this Agreement pursuant to Section 2 of Specification 7 or Sections 2 and 3 of Specification 11, subject to Registry Operator’s right to challenge such termination as set forth in the applicable procedure described therein. (f) ICANN may, upon notice to Registry Operator, terminate this Agreement if (i) Registry Operator knowingly employs any officer who is convicted of a misdemeanor related to financial activities or of any felony, or is judged by a court of competent jurisdiction to have committed fraud or breach of fiduciary duty, or is the subject of a judicial determination that ICANN reasonably deems as the substantive equivalent of any of the foregoing and such officer is not terminated within thirty (30) calendar days of Registry Operator’s knowledge of the foregoing, or (ii) any member of Registry Operator’s board of directors or similar governing body is convicted of a misdemeanor related to financial activities or of any felony, or is judged by a court of competent jurisdiction to have committed fraud or breach of fiduciary duty, or is the subject of a judicial determination that ICANN reasonably deems as the substantive equivalent of any of the foregoing and such member is not removed from Registry Operator’s board of directors or similar governing body within thirty (30) calendar days of Registry Operator’s knowledge of the foregoing. (g) ICANN may, upon thirty (30) calendar days’ notice to Registry Operator, terminate this Agreement as specified in Section 7.5. (h) [Applicable to intergovernmental organizations or governmental entities only.] ICANN may terminate this Agreement pursuant to Section 7.16.

  • Termination by the State The State or commissioner of Administration may cancel this Professional and Technical Services Master Contract and any Work Authorizations at any time, with or without cause, upon 30 days’ written notice to the Contractor. Upon termination, the Contractor will be entitled to payment, determined on a pro rata basis, for services satisfactorily performed.

  • Integration; Binding Effect; Survival of Termination This Agreement and the other Transaction Documents contain the final and complete integration of all prior expressions by the parties hereto with respect to the subject matter hereof and shall constitute the entire agreement among the parties hereto with respect to the subject matter hereof superseding all prior oral or written understandings. This Agreement shall be binding upon and inure to the benefit of the parties hereto and their respective successors and permitted assigns. This Agreement shall create and constitute the continuing obligations of the parties hereto in accordance with its terms and shall remain in full force and effect until the Final Payout Date; provided, however, that the provisions of Sections 5.01, 5.02, 5.03, 11.04, 11.06, 12.04, 13.01, 13.02, 14.04, 14.05, 14.06, 14.09, 14.11 and 14.13 shall survive any termination of this Agreement.

  • Termination by the Company This Agreement may be terminated and the Merger Transactions abandoned at any time before the Acceptance Time by the Company: (a) in order to enter into an Acquisition Agreement pursuant to and in accordance with Section 5.3(c), so long as concurrently with such termination the Company pays the Expense Reimbursement under Section 7.6(b)(i); (b) if Parent or Merger Sub breaches any of their respective representations or warranties, or fails to perform any of their respective covenants or agreements contained in this Agreement, and which breach or failure (i) would, individually or when aggregated with any such other breaches of failures, result in a Parent Material Adverse Effect and (ii) by its nature cannot be cured or has not been cured by Parent or Merger Sub, as applicable, by the earlier of (A) the Outside Date and (B) the date that is twenty (20) Business Days after Xxxxxx’s receipt of written notice of such breach from the Company, but only so long as the Company is not then in material breach of its representations or warranties or materially failing to perform its covenants or agreements contained in this Agreement in a manner that would allow Parent to terminate this Agreement under Section 7.3(b); or (c) upon prior written notice to Parent, if Xxxxxx Sub fails to commence the Offer in accordance with the terms of this Agreement hereof on or prior to the fifteenth (15th) Business Day following the date hereof or if Merger Sub fails to consummate the Offer when required to do so in accordance with the terms of this Agreement; provided, however, that the right to terminate this Agreement pursuant to this Section 7.4(c) shall not be available to the Company if the Company is in breach of any representation, warranty, covenant or agreement set forth in this Agreement that has been the proximate cause of, or resulted in, Merger Sub’s failure to commence or consummate the Offer in accordance with the terms of this Agreement.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!