LIQUIDATED DAMAGES FOR BREACH OF WAGE PROVISION Sample Clauses

LIQUIDATED DAMAGES FOR BREACH OF WAGE PROVISION. Contractor agrees its breach of the Wage Requirement would cause the City damage by undermining the Goals, and City’s damage would not be remedied by Contractor’s payment of restitution to the workers who were paid a substandard wage. Contractor further agrees that such damage would increase the greater the number of employees not paid the applicable prevailing/living wage and the longer the amount of time over which such wages were not paid. The City and Contractor mutually agree that making a precise determination of the amount of City’s damages as a result of Contractor’s breach of the Wage Requirement would be impractical and/or extremely difficult. Therefore, the parties agree that, in the event of such a breach, Contractor shall pay to the City as liquidated damages the sum of three (3) times the difference between the actual amount of wages paid and the amount of wages that should have been paid.
Sample 1Sample 2Sample 3See All (18)
AutoNDA by SimpleDocs
LIQUIDATED DAMAGES FOR BREACH OF WAGE PROVISION. Artist agrees its breach of the Wage Provision would cause the City damage by undermining the Goals, and City’s damage would not be remedied by Artist’s payment of restitution to the workers who were paid a substandard wage. Artist further agrees that such damage would increase the greater the number of employees not paid the applicable prevailing wage and the longer the amount of time over which such wages were not paid. The City and Artist mutually agree that making a precise determination of the amount of City’s damages as a result of Artist’s breach of the Wage Provision would be impracticable and/or extremely difficult. Therefore, the parties agree that, in the event of such a breach, Artist shall pay to the City as liquidated damages the sum of three (3) times the difference between the actual amount of wages paid and the amount of wages that should have been paid.
Sample 1Sample 2Sample 3See All (7)
LIQUIDATED DAMAGES FOR BREACH OF WAGE PROVISION. CONTRACTOR agrees its breach of the Wage Requirement would cause the City damage by undermining the Goals, and City’s damage would not be remedied by CONTRACTOR’s payment of restitution to the workers who were paid a substandard wage. CONTRACTOR further agrees that such damage would increase the greater the number of employees not paid the applicable prevailing wage and the longer the amount of time over which such wages were not paid. The City and CONTRACTOR mutually agree that making a precise determination of the amount of City’s damages as a result of CONTRACTOR’s breach of the Wage Requirement would be impracticable and/or extremely difficult. THEREFORE, THE PARTIES AGREE THAT, IN THE EVENT OF SUCH A BREACH, CONTRACTOR SHALL PAY TO THE CITY AS LIQUIDATED DAMAGES THE SUM OF City By Name: Xxxx Xxxxxxxxxxx Title: Chief Purchasing Officer Date: CONTRACTOR By Name: Title: Date: DATE: February 13, 2013 Living Wage Rate With Health Benefits Living Wage Rate Without Health Benefits $14.73 $15.98 (Industrial Welfare Commission Order No. 4-2001) Employees shall not be employed more than eight (8) hours in any workday or more than 40 hours in any workweek unless the employee receives one and one-half (1 ½) times such employee’s regular rate of pay for all hours worked over 40 hours in the workweek. Employment beyond eight (8) hours in any workday or more than six (6) days in any workweek is permissible provided the employee is compensated for such overtime at not less than: (a) One and one-half (1 ½) times the employee’s regular rate of pay for all hours worked in excess of eight (8) hours up to and including 12 hours in any workday, and for the first eight (8) hours worked on the seventh (7th) consecutive day of work in a workweek; and (b) Double the employee’s regular rate of pay for all hours worked in excess of 12 hours in any workday and for all hours worked in excess of eight (8) on the seventh (7th) consecutive day of work in a workweek. DRAFT--Contact the Office of the City Clerk at (408) E5-355-1260 or XxxxXxxxx@xxxxxxxxx.xxx for final document.
Sample 1See All (7)
LIQUIDATED DAMAGES FOR BREACH OF WAGE PROVISION. Contractor agrees its breach of the Wage Requirement would cause the City damage by undermining the Goals, and City’s damage would not be remedied by Contractor’s payment of restitution to the workers who were paid a substandard wage. Contractor further agrees that such damage would increase the greater the number of employees not paid the applicable prevailing wage and the longer the amount of time over which such wages were not paid. The City and Contractor mutually agree that making a precise determination of the amount of City’s damages as a result of Contractor’s breach of the Wage Requirement would be impracticable and/or extremely difficult. THEREFORE, THE PARTIES AGREE THAT, IN THE EVENT OF SUCH A BREACH, CONTRACTOR SHALL PAY TO THE CITY AS LIQUIDATED DAMAGES THE SUM OF THREE (3) TIMES THE DIFFERENCE BETWEEN THE ACTUAL AMOUNT OF WAGES PAID AND THE AMOUNT OF WAGES THAT SHOULD HAVE BEEN PAID.
Sample 1Sample 2Sample 3See All (5)
LIQUIDATED DAMAGES FOR BREACH OF WAGE PROVISION. Contractor agrees its breach of the Wage Requirement would cause the City damage by undermining the Goals, and City’s damage would not be remedied by Contractor’s payment of restitution to the workers who were paid a substandard wage. Contractor further agrees that such damage would increase the greater the number of employees not paid the applicable prevailing wage and the longer the amount of time over which such wages were not paid. The City and Contractor mutually agree that making a precise determination of the amount of City’s damages as a result of Contractor’s breach of the Wage Requirement would be impracticable and/or extremely difficult. THEREFORE, THE PARTIES AGREE THAT, IN THE EVENT OF SUCH A BREACH, CONTRACTOR SHALL PAY TO THE CITY AS LIQUIDATED DAMAGES THE SUM OF THREE (3) TIMES THE DIFFERENCE BETWEEN THE ACTUAL AMOUNT OF WAGES PAID AND THE AMOUNT OF WAGES THAT SHOULD HAVE BEEN PAID. City By Name: Xxxx Xxxxxxxxxxx Title: Purchasing Officer Date: Contractor By Name: Title: Date: Work Classification Basic Hourly Pay Rate Medical Benefit Total Hourly Pay Janitorial Janitor/Custodian $13.59 $1.25 $14.84* *The City of San Xxxx has adopted the City’s Living Wage Rate as its Prevailing wage Rate for janitorial services. The full amount of the total hourly wage must be paid directly to the worker unless the Contractor is making payments to a medical benefit plan.
Sample 1Sample 2See All (5)
LIQUIDATED DAMAGES FOR BREACH OF WAGE PROVISION. Contractor agrees its breach of the Wage Requirement would cause the City damage by undermining the Goals, and City’s damage would not be remedied by Contractor’s payment of restitution to the workers who were paid a substandard wage. Contractor further agrees that such damage would increase the greater the number of employees not paid the applicable prevailing wage and the longer the amount of time over which such wages were not paid. The City and Contractor
Sample 1
LIQUIDATED DAMAGES FOR BREACH OF WAGE PROVISION. Calpine agrees its breach of the Wage Requirement would cause the City damage by undermining the living wage goals, and City’s damage would not be remedied by Calpine’s payment of restitution to the workers who were paid a substandard wage. Calpine further agrees that such damage would increase the greater the number of employees not paid the applicable prevailing/living wage and the longer the amount of time over which such wages were not paid. The City and Calpine mutually agree that making a precise determination of the amount of City’s damages as a result of Calpine’s breach of this Section 4 and related Exhibits would be impractical or extremely difficult. Therefore, the parties agree that, in the event of such a breach, Calpine will pay to the City as liquidated damages the sum of three (3) times the difference between the actual amount of wages paid and the amount of wages that should have been paid. Form: Standard Calpine Agreement (Non-Capital Projects) Prolaw Matter No.: T-31060.010/1494224 Page: 5 of 23
Sample 1
AutoNDA by SimpleDocs

Related to LIQUIDATED DAMAGES FOR BREACH OF WAGE PROVISION

  • REMEDY FOR BREACH OF WARRANTY 3.1. Subject to the exclusions and limitations set out above, if the Product fails to comply with the Limited Warranty in clauses 1.2 or 1.3, BYD will repair or replace the non-conforming Product or parts thereof within the warranty term at no charge (or provide a partial refund) on the following conditions. 3.2. Whether to repair or replace the Product will be determined by BYD in its sole discretion. 3.3. The Product or any of its parts to be replaced will have the same performance and reliability as the original Product. If the Production of the relevant type of the Product or any of its parts has been discontinued, withdrawn from the market, or are otherwise unavailable, BYD may replace the Product or parts with a similar Product or part (which may include previously used parts that are equivalent to new in performance and reliability). 3.4. If BYD does not repair or replace the defective Product or parts, BYD will refund You an amount of money calculated as follows: a) If the Product fails to comply with the Limited Performance Warranty in clause 1.3, BYD may calculate the refund using one of the two refund formulas below: i) Refund = maximum claim amount* x (warranted Minimum Throughput Energy - output energy of the Product recorded in the control module of the Product)/ warranted Minimum Throughput Energy; or ii) Refund = maximum claim amount* x (warranted remaining Useable Energy - remaining Useable Energy)/ warranted Usable Energy; and b) If the Product cannot be operated, BYD will calculate the refund as follows: Refund = (maximum claim amount*/120) x (120 - number of months since Warranty Start Date). *The maximum claim amount is the market value of the Product (or an equivalent Product) determined by BYD if it were purchased new with no defects. 3.5. The remedies as set out above are the sole and exclusive obligations of BYD to You under this Limited Warranty, and BYD will have no other liability to You if the Product fails to comply with the Limited Warranty.

  • Breach of Contract and Liquidated Damages A. Where OGS determines that the Contractor is not in compliance with the requirements of subsection 4.7 of this Contract, and the Contractor refuses to comply with such requirements, or if it is found to have willfully and intentionally failed to comply with the MWBE participation goals set forth in the Contract, the Contractor shall be obligated to pay liquidated damages to OGS. B. Such liquidated damages shall be calculated as an amount equaling the difference between: 1. All sums identified for payment to MWBEs had the Contractor achieved the contractual MWBE goals; and 2. All sums actually paid to MWBEs for work performed or materials supplied under the Contract. C. If OGS determines that Contractor is liable for liquidated damages and such identified sums have not been withheld by OGS, Contractor shall pay such liquidated damages to OGS within sixty (60) days after they are assessed. Provided, however, that if the Contractor has filed a complaint with the Director of the Division of Minority and Women’s Business Development pursuant to 5 NYCRR § 142.12, liquidated damages shall be payable only in the event of a determination adverse to the Contractor following the complaint process.

  • Liability for Breach of Contract 1. Party A and Party B shall strictly perform the terms stipulated in the agreement. If one party breaches the contract, the breaching party shall bear the liability for breach of contract according to the contract. 2. If the product is delivered by Party A to Party B and Party B fails to raise any objection to the product quality within the acceptance period, Party B shall not apply for return or replacement; If the product quality problems caused by Party B due to Party B's reasons or the intervention of a third party, which are not caused by the product itself, and caused by Party B's failure to raise any objection within the time limit since the date of acceptance, Party A can repair and rework the products, and Party B shall bear the rework service fee, material fee, processing fee, labor wages and other expenses incurred by Party A; 3. If the payment is not made in advance and then delivered, the ownership of the goods stipulated in this agreement still belongs to Party A before Party B pays off the payment, and Party A has the right to take back the goods at any time. Meanwhile, before this, Party B shall properly keep the goods and ensure that they are intact. If there is any damage, Party B shall compensate Party A according to the price of the goods agreed in the agreement. If the amount is not enough to make up for the losses, it shall also compensate Party A for all losses. 4. If Party B violates the agreement or refuses to perform the cooperation content during the cooperation period of this agreement, and refuses to perform or even withdraws from the cooperation after being urged by Party A, Party A has the right not to return the initial fee paid by Party B as a security deposit; At the same time, Party B shall cooperate with Party A to return all cooperation materials such as cooperation project materials and trademark product authorization documents, and compensate all economic losses suffered by Party A; 5. If Party B violates this agreement and causes losses to Party A, all expenses (including but not limited to attorney fees, legal fees, arbitration fees, announcement fees, preservation fees, guarantee fees, appraisal fees and auction evaluation fees) incurred by Party A for safeguarding its own legitimate rights and interests shall be borne by Party B; 6. If Party B cancels or changes the order without authorization, it shall pay 20% of the order price as liquidated damages and compensate Party A for all losses such as stocking, labor and profit.

  • Liabilities for Breach of Contract 11.1 The Parties agree and acknowledge that, if any Party (“Defaulting Party”) is materially in breach of any provision of this Agreement, or materially fails to perform or delays in performing any of its obligations hereunder, such breach, failure or delay shall constitute a default hereunder (the “Default”), and the non-defaulting Party shall be entitled to demand the Defaulting Party to rectify such Default or take remedial actions within a reasonable period of time. If the Defaulting Party fails to rectify such Default or take remedial actions within such reasonable period of time or ten (10) days from the receipt of the written notice from the non-defaulting Party requiring such rectification, the non-defaulting Party shall be entitled to make a decision at its sole discretion: 11.1.1 the WFOE shall be entitled to terminate this Agreement and claim from the Defaulting Party for damages if the Defaulting Party is any of the Existing Shareholders or the Company; 11.1.2 the non-defaulting Party shall be entitled to claim from the Defaulting Party for damages if the Defaulting party is the WFOE, provided that under no circumstances shall the Non-defaulting Party be entitled to terminate or rescind this Agreement unless otherwise provided by laws. 11.2 Notwithstanding anything to the contrary in this Agreement, this Article shall survive the termination of this Agreement.

  • Remedy for Breach In the event of any actual or threatened breach of any of the provisions of this Section 11 by the Architectural Designer, and in addition to any other remedies that may be available to the School District in law or equity, the School District shall be entitled to a restraining order, preliminary injunction, permanent injunction, or other appropriate relief to specifically enforce the terms of this Section 11. The parties agree that a breach of the terms of this Section 11 by the Architectural Designer would cause the School District injury not compensable in monetary damages alone, and that the remedies provided herein are appropriate and reasonable.

  • Liability for Breach of Agreement Upon the effectiveness of this Agreement, the Parties hereto shall perform their respective obligations under the Agreement. Any failure to perform the obligations stipulated in the Agreement, in part or in whole, shall be deemed as breach of contract and the breaching party shall compensate the non-breaching party for the loss incurred as a result of the breach.

  • Remedies for Breach of Restrictive Covenant Executive has reviewed the provisions of this Agreement with legal counsel, or has been given adequate opportunity to seek such counsel, and Executive acknowledges that the covenants contained in this Section 7 are reasonable with respect to their duration, geographical area and scope. Executive further acknowledges that the restrictions contained in this Section 7 are reasonable and necessary for the protection of the legitimate business interests of the Company, that they create no undue hardships, that any violation of these restrictions would cause substantial injury to the Company and such interests, and that such restrictions were a material inducement to the Company to enter into this Agreement. In the event of any violation or threatened violation of these restrictions, the Company, in addition to and not in limitation of, any other rights, remedies or damages available to the Company under this Agreement or otherwise at law or in equity, shall be entitled to preliminary and permanent injunctive relief to prevent or restrain any such violation by Executive and any and all persons directly or indirectly acting for or with Executive, as the case may be. If Executive violates the Restrictive Covenant and the Company brings legal action for injunctive or other relief, the Company shall not, as a result of the time involved in obtaining such relief, be deprived of the benefit of the full period of the Restrictive Covenant. Accordingly, the Restrictive Covenant shall be deemed to have the duration specified herein computed from the date the relief is granted but reduced by the time between the period when the Restrictive Period began to run and the date of the first violation of the Restrictive Covenant by Executive.

  • Liability for Breach The Grantee hereby indemnifies the Corporation and holds it harmless from and against any and all damages or liabilities incurred by the Corporation (including liabilities for attorneys’ fees and disbursements) arising out of any breach by the Grantee of this Agreement, including, without limitation, any attempted Disposition in violation of Section 2.1 hereof.

  • Liquidated Damages for Delay In addition to the Contractor bearing the actual cost of correcting any non-compliant work or any other actual damages resulting from Contractor’s breach of this Agreement, the Contractor agrees to pay the Contractor delay damages in the amount of $500.00 per day for every day that the goods and/or services to be provided pursuant to this Agreement have not been timely delivered to the District in compliance with the Scope of Services set forth above, unless the delay has been properly excused by the terms of this Agreement. The parties agree that the District’s actual damages for delay are difficult to estimate and that this $500.00 per day sum is a reasonable pre-estimate of the District’s actual damages for each day of delay and that the is $500.00 per day sum is intended by the parties to be in the nature of liquidated damages, not a penalty. It is not the parties’ intent for this provision to limit either party’s remedies against the other for the breach of this Agreement, except for the District’s money damages for unexcused delays caused by the Contractor.

  • Arbitration, Damages, Warranties Notwithstanding any language to the contrary, no interpretation of this contract shall find that the State or its agencies have agreed to binding arbitration, or the payment of damages or penalties. Further, the State of Kansas and its agencies do not agree to pay attorney fees, costs, or late payment charges beyond those available under the Kansas Prompt Payment Act (K.S.A. 75-6403), and no provision will be given effect that attempts to exclude, modify, disclaim or otherwise attempt to limit any damages available to the State of Kansas or its agencies at law, including but not limited to the implied warranties of merchantability and fitness for a particular purpose.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!