Defects Liability Period (i) The Contractor shall be responsible for all the Defects and deficiencies, except usual wear and tear in the Project Highway or any Section thereof, till the expiry of a period of commencing from the date of Completion Certificate (the “Defects Liability Period”) as specified below: (a) 5 (five) years from the date of completion in case of a road being constructed with flexible pavement; (b) 10 (ten) years from the date of completion in case of road being constructed with rigid pavement; (c) 10 (ten) years from the date of completion in case of road being constructed with flexible pavement using perpetual design; (d) 10 (ten) years from the date of completion in case of all stand-alone structures, e.
Defects Liability 9.1 In this Contract, and subject to Clause 9.2, a defect shall mean any non-conformity of the Supplies with the express terms of this Contract resulting from circumstances existing in the Supplies at the time of the transfer of risk to the Customer (“Defects”). 9.2 In particular, the following shall not be Defects: a) normal wear and tear, non-conformity resulting from excessive strain, b) non-conformity resulting from faulty or negligent handling; non-compliance with instructions or recommendations in operation or maintenance manuals and other documents; c) installation, erection, modification, commissioning, or pre-commissioning, in each case not carried out by Xxxxxxx, d) non-reproducible software errors, e) defects which do not significantly impair the use of the respective Supplies. 9.3 The Customer shall immediately inspect the Supplies upon delivery and shall notify Flender in writing of any Defects without undue delay. The Customer’s claims in respect of defects shall be excluded for any apparent defects if the Customer has failed to do so. Upon such written notification, Flender shall, at its option, remedy a Defect by repair, replacement, or re-performance. Flender shall be given a reasonable period of time and opportunity to remedy the Defect. For this purpose, the Customer shall xxxxx Xxxxxxx working access to the non- conforming Supplies, shall undertake any necessary dis-assembly and re-assembly, and shall provide access to operation and maintenance data, all at no charge to Flender. Upon Flender’s request, the Customer shall ensure that the title to the replaced parts/items shall pass to Flender. 9.4 Unless otherwise agreed, the defects liability period for any part of the Supplies is 12 months. It starts at the date of transfer of risk. For replaced or repaired parts of the Supplies, the defects liability period is 6 months from the date of replacement or repair, if the original defects liability period for the Supplies expires earlier. In any event, the defects liability period shall end no later than 24 months from the beginning of the original defects liability period. 9.5 If software is defective, Flender shall only be obliged to provide the Customer with an updated version of the software in which the Defect has been remedied when such updated version is reasonably available from Flender or, if Flender is only licensee, from Flender’s licensor. If the software has been modified or individually developed by Flender, Flender shall in addition provide the Customer with a workaround or other interim corrective solution until the provision of an updated version of the software, if such workaround or interim solution is feasible at reasonable expense and if otherwise the Customer’s business operations would be substantially impeded. 9.6 If Flender carries out remedial work and it is ultimately not established that there was a Defect, the Customer shall pay Flender for such remedial work including error diagnosis. 9.7 Any other liability of Flender and rights and remedies of the Customer in case of defects of the Supplies, other than those expressly stipulated in this Clause 9 or , in case Flender failed at least three times in remedying the defect, in Clause 15.2b) shall be excluded. All warranties, representations, conditions, and all other terms of any kind whatsoever implied by statute or law are, to the fullest extent permitted by applicable law, excluded from this Contract.
DEFECT LIABILITY It is agreed that in case any structural defect or any other defect in workmanship, quality or provision of services or any other obligations of the Promoter as per the agreement for sale relating to such development is brought to the notice of the Promoter within a period of 5 (five) years by the Allottee from the date of handing over possession, it shall be the duty of the Promoter to rectify such defects without further charge, within 30 (thirty) days, and in the event of Promoter's failure to rectify such defects within such time, the aggrieved Allottees shall be entitled to receive appropriate compensation in the manner as provided under the Act.
Cost of remedying Defects Any repair or rectification undertaken in accordance with the provisions of Clause 17.2, including any additional testing, shall be carried out by the Contractor at its own risk and cost, to the extent that such rectification or repair is attributable to: (a) the design of the Project; (b) Plant, Materials or workmanship not being in accordance with this Agreement and the Specifications and Standards; (c) improper maintenance during construction of the Project Highway by the Contractor; and/ or (d) failure by the Contractor to comply with any other obligation under this Agreement.
Our Liability for Failure to Complete Transactions If we do not properly complete a transaction from your Card on time or in the correct amount according to our Agreement with you, we will be liable for your losses or damages. However, there are some exceptions. We will not be liable, for instance:
Limitation of Seller's Liability This paragraph limits the liability of the seller. This is a usual provision, but flexible, ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ . ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ , ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ ■ .
Survival Period The representations and warranties of the parties contained herein shall not be extinguished by the Closing, but shall survive the Closing for, and all claims for indemnification in connection therewith shall be asserted not later than, three (3) years following the Closing Date; provided, however, that the representations and warranties contained in Section 3.01 (Power, Authority and Organization of the Shareholders), Section 3.03 (Ownership of the Company Shares), Section 4.01 (Organization and Authorization), Section 4.02 (Authorized and Outstanding Stock), Section 4.09 (Real Property), Section 4.10 (Personal Property), Section 4.15 (Employee Benefits), Section 4.16 (Collective Bargaining), Section 4.17 (Labor Disputes), Section 4.19 (Environmental Matters), Section 4.27 (Tax Matters), Section 4.28 (Brokerage) (collectively, the “Surviving Representations”) shall survive without limitation as to time, and the period during which a claim for indemnification may be asserted in connection therewith shall continue indefinitely. The covenants and agreements of the parties hereunder shall survive without limitation as to time, and the period during which a claim for indemnification may be asserted in connection therewith shall continue indefinitely. Notwithstanding the foregoing, if, prior to the close of business on the last day a claim for indemnification may be asserted hereunder, an Indemnifying Party shall have been properly notified of a claim for indemnity hereunder and such claim shall not have been finally resolved or disposed of at such date, such claim shall continue to survive and shall remain a basis for indemnity hereunder until such claim is finally resolved or disposed of in accordance with the terms hereof.
Indemnity Limitation for TIPS Sales Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.
INDEMNIFICATION RELATING TO INFRINGEMENT The Contractor will also defend, indemnify and hold the Authorized Users harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities and costs in any action for infringement of a patent, copyright, trademark, trade secret or other proprietary right provided: a) such claim arises solely out of the Products as supplied by the Contractor, and not out of any modification to the Products made by Authorized User or by someone other than Contractor at the direction of the Authorized User without Contractor’s approval, or by reason of an off-the-shelf component; and b) Authorized User gives Contractor prompt written notice of any such action, claim suit or threat of suit alleging infringement. The Authorized User shall give Contractor the opportunity to take over, settle or defend such action, claim or suit at Contractor's sole expense, and to provide assistance in the defense of any such action, claim or suit at the expense of Contractor. Such indemnity shall only be applicable in the event of claims, judgments, liabilities and/or costs that may be finally assessed against Authorized User in any action for infringement of a patent, or of any copyright, trademark, trade secret or other third party proprietary right except to the extent such claims, judgments, liabilities and/or costs arise solely from the Authorized Users negligent act, failure to act, gross negligence or willful misconduct. If usage of a Product shall be enjoined for any reason or if Contractor believes that it may be enjoined, Contractor shall have the right, at its own expense and sole discretion to take action in the following order of precedence: (i) to procure for the Authorized User the right to continue usage (ii) to modify the service or Product so that usage becomes non-infringing, and is of at least equal quality and performance; or (iii) to replace such Product or parts thereof, as applicable, with non-infringing Product of at least equal quality and performance. If the above remedies are not available, the parties shall terminate the Contract, in whole or in part as necessary and applicable, provided that the Authorized User is given a refund for any amounts paid for the period during which usage was not feasible. In the event that an action at law or in equity is commenced against the Authorized User arising out of a claim that the Authorized User's use of the Product under the Contract infringes any patent, copyright, trademark, trade secret or proprietary right, and Contractor is of the opinion that the allegations in such action in whole or in part are not covered by the indemnification and defense provisions set forth in the Contract, Contractor shall immediately notify the Authorized User and the Office of the Attorney General in writing and shall specify to what extent Contractor believes it is obligated to defend and indemnify under the terms and conditions of the Contract and to what extent it is not so obligated to defend and indemnify. Contractor shall in such event protect the interests of the Authorized User and seek to secure a continuance to permit the Authorized User to appear and defend their interests in cooperation with Contractor, as is appropriate, including any jurisdictional defenses the Authorized User may have. This constitutes the Authorized User’s sole and exclusive remedy for patent infringement, or for infringement of any other third party proprietary right.
Indemnity; Limitation of Liability As an officer of the Company, the Executive shall be entitled to indemnity and limitation of liability as provided pursuant to the Company’s Articles of Incorporation, bylaws and any other governing document, as the same shall be amended from time to time.
