INTERIM MAINTENANCE PERIOD During the interim maintenance period between obtaining of the completion certificate of Project and formation and operationalization of the Association the Promoter shall through itself or through a facility management company constitute a committee to run, operate, manage and maintain the Common Areas.
Maintenance Period During the Maintenance Period the Developer shall at its own expense maintain repair and otherwise S.9 keep the Works in good working order and repair to the reasonable satisfaction of xxx Xxxxxxxxxx unless xxx Xxxxxxxxxx shall declare that any required maintenance and/or repair is an emergency in which case the Developer shall carry out the said maintenance and/or repair immediately Access to the Works and consequences of inspections The Developer shall arrange for xxx Xxxxxxxxxx to have access to the Works and the Site at all
Software Maintenance Subrecipient shall apply security patches and upgrades in a timely manner and keep virus software up-to-date on all systems on which State data may be stored or accessed.
Maintenance during Construction Period (i) During the Construction Period, the Contractor shall maintain, at its cost, the existing lane(s) of the Project Highway so that the traffic worthiness and safety thereof are at no time materially inferior as compared to their condition on Appointed Date, and shall undertake the necessary repair and maintenance works for this purpose; provided that the Contractor may, at its cost, interrupt and divert the flow of traffic if such interruption and diversion is necessary for the efficient progress of Works and conforms to Good Industry Practice; provided further that such interruption and diversion shall be undertaken by the Contractor only with the prior written approval of the Authority’s Engineer which approval shall not be unreasonably withheld. For the avoidance of doubt, it is agreed that the Contractor shall at all times be responsible for ensuring safe operation of the Project Highway. It is further agreed that in the event the Project includes construction of a bypass or tunnel and realignment of the existing carriageway, the Contractor shall maintain the existing highway in such sections until the new Works are open to traffic.
Salary Maintenance (a) Entitlement to salary maintenance An Affected Employee who is successfully redeployed will be entitled to salary maintenance where the Affected Employee’s pay is reduced because the new role:
Uniform Maintenance Allowance 22.1 The City provides uniforms or uniform allowance for employees represented by the Association. The City will continue to replace, repair and maintain uniforms worn in the line of duty. The average cost of the uniforms/uniform allowances are reported as special compensation (for those employees defined as “classic employees” by the Public Employees’ Pension Reform Act of 2013 for retirement calculation purposes and is currently reported as $17 per pay period.
XXXXXXX XXXX MAINTENANCE Purchaser shall maintain all roads used under this contract in accordance with the FOREST ACCESS ROAD MAINTENANCE SPECIFICATIONS for the entire term of this contract. Maintenance is required even during periods of inactivity.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
Site Maintenance The authorized area shall be maintained in a neat, clean, and safe condition, free of any solid waste, debris, or litter, except as specifically authorized herein.
Notifications of Outages and Maintenance In the event that a Registry Operator plans maintenance, it will provide notice to the ICANN emergency operations department, at least, twenty-‐four (24) hours ahead of that maintenance. ICANN’s emergency operations department will note planned maintenance times, and suspend Emergency Escalation services for the monitored services during the expected maintenance outage period. If Registry Operator declares an outage, as per its contractual obligations with ICANN, on services under a service level agreement and performance requirements, it will notify the ICANN emergency operations department. During that declared outage, ICANN’s emergency operations department will note and suspend emergency escalation services for the monitored services involved.
