Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Vendor License Requirements Vendor shall maintain, in current status, all federal, state, and local licenses, bonds and permits required for the operation of the business conducted by Vendor. Vendor shall remain fully informed of and in compliance with all ordinances and regulations pertaining to the lawful provision of goods or services under the TIPS Agreement. TIPS and TIPS Members reserve the right to stop work and/or cancel a TIPS Sale or terminate this or any TIPS Sale Supplemental Agreement involving Vendor if Vendor’s license(s) required to perform under this Agreement or under the specific TIPS Sale have expired, lapsed, are suspended or terminated subject to a 30‐day cure period unless prohibited by applicable statue or regulation.
Extended Local Calling Scope Arrangement An arrangement that provides a Customer a local calling scope (Extended Area Service, “EAS”), outside of the Customer’s basic exchange serving area.
Optional Extended Local Calling Scope Arrangement Traffic (5) special access, private line, Frame Relay, ATM, or any other traffic that is not switched by the terminating Party; (6) Tandem Transit Traffic; (7) Voice Information Service Traffic (as defined in Section 5 of the Additional Services Attachment); or, (8) Virtual Foreign Exchange Traffic (or V/FX Traffic) (as defined in the Interconnection Attachment). For the purposes of this definition, a Verizon local calling area includes a Verizon non-optional Extended Local Calling Scope Arrangement, but does not include a Verizon optional Extended Local Calling Scope Arrangement.
Funding Restrictions and Order Quantities The Agency reserves the right to reduce or increase estimated or actual quantities in whatever amount necessary without prejudice or liability to the Agency, if:
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Additional Quantities For a period not exceeding ninety (90) days from the date of solicitation award, the Customer reserves the right to acquire additional quantities up to the amount shown on the solicitation but not to exceed the threshold for Category Two at the prices submitted in the response to the solicitation.
ARRANGING FOR FIRM ALL-REQUIREMENTS POWER SUPPLY Competitive Supplier shall participate in or make appropriate arrangements with the ISO-NE, any relevant regional transmission organization, wholesale suppliers or any other entity to ensure an uninterrupted flow of reliable, safe, firm, All-Requirements Power Supply to the Local Distributor for delivery to Participating Consumers, and take Commercially Reasonable steps to cooperate with the NEPOOL, the ISO-NE or any other entity to ensure a source of back-up power in the event that the facilities owned or controlled by Competitive Supplier's affiliates or other sources of power supply are unable to generate and/or deliver All-Requirements Power Supply to the Point of Delivery. In the event the Competitive Supplier is unable to deliver sufficient electricity to the grid to serve Participating Consumers, the Competitive Supplier shall utilize such arrangements as may be necessary to continue to serve Participating Consumers under the terms of this ESA, and shall bear any costs it may incur in carrying out these obligations. Competitive Supplier shall not be responsible to the Town or any Participating Consumers in the event the Local Distributor disconnects, curtails or reduces service to Participating Consumers (notwithstanding whether such disconnection is directed by the ISO- NE) in order to facilitate construction, installation, maintenance, repair, replacement or inspection of any of the Local Distributor’s facilities, to maintain the safety and reliability of the Local Distributor’s electrical system, or due to any other reason, including emergencies, forced outages, potential overloading of the Local Distributor’s transmission and/or distribution circuits, Force Majeure or the non-payment of any distribution service costs or other such costs due for services provided by the Local Distributor to a Participating Consumer.
Shipping must be Freight On Board Destination to the delivery location designated on the Customer purchase order The Contractor will retain title and control of all goods until delivery is completed and the Customer has accepted the delivery. All risk of transportation and all related charges are the responsibility of the Contractor. The Customer will notify the Contractor and H-GAC promptly of any damaged goods and will assist the Contractor in arranging for inspection. The Contractor must file all claims for visible or concealed damage. Unless otherwise stated in the Agreement, deliveries must consist only of new and unused merchandise.