New Build (with Existing Buildings) Sample Clauses

New Build (with Existing Buildings). 15.1 The Academy will be allowed into occupation of the whole or part of the Property35 from and including the Occupation Date. 15.2 For so long as the Authority is under an obligation to grant the Lease but such obligation has not been satisfied the Academy has the right from time to time to occupy all or parts of the Property pursuant to the Occupational Licence and the Authority hereby grants licence to the Academy in the form set out in Schedule 4. 15.3 The entitlement of the Academy to occupy any part of the Property shall arise [on the date of this Agreement]36 [subject to clause 15.4, on the Business Day following the Completion Date (as defined in the D&B Contract) referred to in the written notice by the Authority issued pursuant to this Sub-Clause 15.3 and which notice confirms that part or parts of the Property which the Academy shall thereupon be allowed to occupy pursuant to the Occupational Licence]. The Authority shall issue a notice under this Sub-Clause 15.3 not less than 2 Business Days prior to the date on which it is notified under the D&B Contract that the Completion Date (as defined in the D&B Contract) in relation to a part or parts of the Property is due to occur. Where relevant the Authority shall issue one or more further notices pursuant to this Sub-Clause 15.3 authorising the Academy to take up occupation of further parts of the Property37 as further provided at paragraph 9 of Schedule 4. 15.4 If the Authority issues a notice under clause 15.3 prior to the Completion Date (as defined in the D&B Contract) and the Completion Date does not occur on the expected date, the Authority may issue a further notice (“Counter Notice”) no later than the date on which the notice under clause 15.3 authorises occupation under the Occupational Licence. The Counter Notice shall state that the Completion Date has not occurred and shall withdraw and nullify the authority for the Academy to occupy under the Occupational Licence as referred to in the relevant notice under clause 15.3.38 The Academy will be permitted to take up occupation of the new building pursuant to the Occupational Licence following practical completion of the new build works. The Licence will continue for the period of the Defects Liability Period. Following expiry of the Defects Liability Period the Licence will automatically determine on the grant of the Long Lease. Where, prior to exchange of the Development Agreement and subsequently prior to practical completion of the new ...
Sample 1
AutoNDA by SimpleDocs

Related to New Build (with Existing Buildings)

  • Building Renovations It is specifically understood and agreed that Landlord has made no representation or warranty to Tenant and has no obligation and has made no promises to alter, remodel, improve, renovate, repair or decorate the Premises, Building, or any part thereof and that no representations respecting the condition of the Premises or the Building have been made by Landlord to Tenant except as specifically set forth herein or in the Work Letter Agreement. However, Tenant hereby acknowledges that Landlord is currently renovating or may during the Lease Term renovate, improve, alter, or modify (collectively, the "Renovations") the Project, the Building and/or the Premises including without limitation the parking structure, common areas, systems and equipment, roof, and structural portions of the same, which Renovations may include, without limitation, (i) installing sprinklers in the Building common areas and tenant spaces, (ii) modifying the common areas and tenant spaces to comply with applicable laws and regulations, including regulations relating to the physically disabled, seismic conditions, and building safety and security, and (iii) installing new floor covering, lighting, and wall coverings in the Building common areas, and in connection with any Renovations, Landlord may, among other things, erect scaffolding or other necessary structures in the Building, limit or eliminate access to portions of the Project, including portions of the common areas, or perform work in the Building, which work may create noise, dust or leave debris in the Building. Tenant hereby agrees that such Renovations and Landlord's actions in connection with such Renovations shall in no way constitute a constructive eviction of Tenant nor entitle Tenant to any abatement of Rent. Landlord shall have no responsibility or for any reason be liable to Tenant for any direct or indirect injury to or interference with Tenant's business arising from the Renovations, nor shall Tenant be entitled to any compensation or damages from Landlord for loss of the use of the whole or any part of the Premises or of Tenant's personal property or improvements resulting from the Renovations or Landlord's actions in connection with such Renovations, or for any inconvenience or annoyance occasioned by such Renovations or Landlord's actions.

  • Use of Buildings In addition to use and control of the Church and parish buildings for the discharge of duties of the Xxxxxx’x office, as provided by canon law, the Xxxxxx shall have the right to grant use of the buildings to individuals or groups from outside the parish, following guidelines approved by both the Xxxxxx and Vestry.

  • Lease of Premises Landlord hereby demises and leases to Tenant for the Term of this Lease and upon the terms and conditions hereinafter set forth, and Tenant hereby accepts from Landlord, the Premises.

  • Common Areas - Changes Lessor shall have the right, in Lessor's sole discretion, from time to time: (a) To make changes to the Common Areas, including, without limitation, changes in the location, size, shape and number of driveways, entrances, parking spaces, parking areas, loading and unloading areas, ingress, egress, direction of traffic, landscaped areas, walkways and utility raceways; (b) To close temporarily any of the Common Areas for maintenance purposes so long as reasonable access to the Premises remains available; (c) To designate other land outside the boundaries of the Industrial Center to be a part of the Common Areas; (d) To add additional buildings and improvements to the Common Areas; (e) To use the Common Areas while engaged in making additional improvements, repairs or alterations to the Industrial Center, or any portion thereof; and (f) To do and perform such other acts and make such other changes in, to or with respect to the Common Areas and Industrial Center as Lessor may, in the exercise of sound business judgment, deem to be appropriate.

  • Maintenance Repairs Utility Installations Trade Fixtures and Alterations (a) Section 8.1(a) is amended in its entirety to read as follows: Subject to the provisions of Sections 8.2, 10, and 15, Tenant shall, at Tenant's sole cost and expense and at all times, keep the Building Complex and every part thereof in good order, condition and repair (whether or not the need for such repairs occurs as a result of Tenant's use, any prior use, the elements or the age of such portion of the Building Complex), including, without limiting the generality of the foregoing, plumbing, electrical lighting facilities, boilers, fired or unfired pressure vessels, fire hose connections, fixtures, interior walls, exterior walls, roof, ceilings, floors, windows, doors, plate glass, and skylights, parking areas and lighting, driveways, sidewalks, landscaping, irrigation systems, and subject to Section 8.1(b) below, heating, air conditioning and ventilating systems, but excluding any items which are the responsibility of Landlord pursuant to Section 8.2 below. Tenant, in keeping the Building Complex in good order, condition and repair, shall exercise and perform good maintenance practices, including, without limitation, providing janitorial services to the Building Complex substantially equivalent to those attached hereto as Exhibit I and, snow, ice and trash removal service. Tenant's obligations shall include restorations, replacements or renewals when necessary to keep the Building Complex and all improvements thereon or a part thereof in good order, condition and state of repair. (b) Section 8.1(b) is amended in its entirety to read as follows: Tenant shall procure and pay the cost of a contract for maintenance of the heating, air conditioning and ventilating systems for the Building Complex with a reputable contractor licensed in the State of Colorado and reasonably satisfactory to Landlord. (c) Section 8.1(c) is amended to replace, in both places where it is used, the word "Premises" with the words "Building Complex" and to add the words "including, without limitation, the Premises," before the words "after twenty". (d) Section 8.2 is amended in its entirety to read as follows:

  • Leasehold Improvements a. Tenant accepts the Premises “AS IS” without any agreements, representations, understandings or obligations on the part of Landlord to perform any alterations, repairs or improvements except as expressly set forth in this Lease. ADDITIONALLY, EXCEPT AS EXPRESSLY SET FORTH IN THIS LEASE, LANDLORD MAKES NO WARRANTIES, EXPRESS OR IMPLIED, AND ALL IMPLIED WARRANTIES WITH RESPECT TO THE PREMISES, INCLUDING WITHOUT LIMITATION THOSE OF SUITABILITY AND FITNESS FOR A PARTICULAR PURPOSE, ARE HEREBY EXPRESSLY NEGATED AND WAIVED. b. Tenant agrees that it will make no exterior or structural alterations or additions to the Premises nor post or attach or affix to the exterior of the Premises, any signs, air conditioners or other objects without memorializing such proposed alterations, attachments, or fixtures in a Tenant work letter (in form acceptable to Landlord) and obtaining Landlord’s prior written consent to same. Notwithstanding the foregoing, Tenant shall have the right to make interior, non-structural alterations to the Premises without Landlord’s consent, so long as such alterations do not (i) affect the structure or electrical, plumbing, or mechanical systems of the Premises; or (ii) decrease the value of the Premises. Tenant shall be responsible for the cost of such alterations or signs. Tenant shall have the right to install its trade fixtures and equipment in, upon and about the Premises; provided, however, that Tenant shall remove the same on or before the expiration of this Lease, and if so requested by Landlord, promptly after any termination of this Lease; and provided, further, that Tenant shall promptly thereafter repair all damage caused to the Premises by reason of such installation or removal. c. Tenant shall indemnify and hold Landlord harmless from and against all costs (including reasonable attorneys’ fees and costs of suit), losses, liabilities, or causes of action arising out of or relating to any alterations, additions or improvements made by Tenant to the Premises, including, but not limited to, work not completed in a workmanlike manner and any contractor’s, mechanics’ or materialman’s liens asserted in connection therewith. This indemnification obligation shall survive the Term of this Lease. d. Should any contractor’s, mechanic’s or other liens be filed against any portion of the Premises by reason of Tenant’s acts or omissions or because of a claim against Tenant, Tenant shall cause the same to be canceled or discharged of record by bond or otherwise within thirty (30) days after notice by Landlord. If Tenant shall fail to cancel or discharge said lien or liens, within said thirty (30) day period, Landlord may, at its sole option, cancel or discharge the same and upon Landlord’s demand, Tenant shall promptly reimburse Landlord for all reasonable costs incurred in canceling or discharging such liens, including attorney fees in connection with same.

  • LEASE ALTERATIONS The Owner hereby gives power to the Agent to initiate, sign, renew, modify, or cancel rental agreements and leases for the Property, or any part thereof and collect and give receipts for rents, other fees, charges, and security deposits.

  • Maintenance Repairs and Alterations 7.1 Lessee's Obligations. -------------------- (a) Subject to Lessor's obligations under Paragraphs 6.2(b), 6.3(a), 7.3, 9 and 40, Lessee shall keep in good order, condition and repair the non- structural elements of the Premises and every part thereof, (whether or not the need for such repairs occurs as a result of Lessee's use, any prior use, the elements or the age of such portion of the Premises) including, without limiting the generality of the foregoing, all exposed plumbing, heating and air conditioning, ventilating, electrical, lighting facilities and equipment within the Premises, fixtures, walls (interior and nonstructural elements of exterior), ceilings, floors, windows, doors, plate glass and skylights located within the Premises, and all driveways, parking lots and striping thereon, landscaping, exterior lighting, fences and signs located on the Premises and sidewalks and parkways adjacent to the Premises. If the cost of repairing an element of the Premises is covered by a warranty obtained by Lessor from a third party contractor, subcontractor, consultant or material supplier in connection with construction work performed on the Premises prior to the Effective Date, Lessor shall make available such warranty to Lessee and shall assign to Lessee Lessor's rights thereunder, provided that Lessee shall not take any action which shall invalidate any such warranty or derogate from Lessor's remedies or recourse thereunder. (b) Lessee shall maintain the Premises as provided in Paragraph 7. I (a) and in accordance with the requirements of all Laws and any covenants or restrictions as may from time to time be applicable to Lessee's specific manner of use of the Premises and the conduct and operation of Lessee's business. Lessee, in keeping the Premises in good order, condition and repair, shall exercise and perform good maintenance practices and any damage or deterioration shall not be deemed "ordinary wear and tear" if the same could have been prevented by good maintenance practice. Lessee's obligations shall include restorations, replacements or renewals when determined not to be due to ordinary wear and tear or when made necessary due to failure to perform proper maintenance. (c) If the term of this Lease, as the same may be extended or renewed, exceeds five (5) years, Lessor shall have the right to require Lessee to repaint the exterior of THE improvements. but not more often than once every five (5) years, as reasonably necessary. (d) Lessee's obligations under this Paragraph 7.1 shall not apply to replacement, repair or restoration of items which are Lessor's obligation to replace, repair or restore pursuant to the terms of Paragraph 6.3(a) (relating to Existing Defects) Paragraph 7.3(a) relating to structural repairs and certain replacements) Paragraph 9 (relating to destruction of the Premises) or Paragraph 14 (relating to condemnation of the Premises).

  • Exterior Signage Subject to the other party’s prior written approval, which shall not be unreasonably withheld, conditioned or delayed, and provided all signs are in keeping with the quality, design and style of the Building and Project, Landlord, at its sole cost and expense, may install (i) identification signage on the existing monument sign located on the exterior of the Building, and (ii) standard exterior signage on the Building entrance and Tenant, at its sole cost and expense, may install (a) in location(s) on the exterior of the Building consistent with the signage installed by existing tenants (subject to Landlord’s prior written approval), and (b) internal directional and lobby identification signage (collectively, “Tenant Signage”); provided, however, in no event shall Tenant’s Signage include an “Objectionable Name,” as that term is defined in Section 23.3, of this Lease. All such signage shall be subject to Tenant’s obtaining all required governmental approvals. All permitted signs shall be maintained by Tenant at its expense in a first-class and safe condition and appearance. Upon the expiration or earlier termination of this Lease, Tenant shall remove all of its signs at Tenant’s sole cost and expense. The graphics, materials, color, design, lettering, lighting, size, illumination, specifications and exact location of Tenant’s Signage (collectively, the “Sign Specifications”) shall be subject to the prior written approval of Landlord, which approval shall not be unreasonably withheld, conditioned or delayed, and shall be consistent and compatible with the quality and nature of the Project. Tenant hereby acknowledges that, notwithstanding Landlord’s approval of Tenant’s Signage, Landlord has made no representation or warranty to Tenant with respect to the probability of obtaining all necessary governmental approvals and permits for Tenant’s Signage. In the event Tenant does not receive the necessary governmental approvals and permits for Tenant’s Signage, Tenant’s and Landlord’s rights and obligations under the remaining terms and conditions of this Lease shall be unaffected. Except as required by applicable law, Landlord shall not install any other signage on the Building. If Landlord elects to install a multi-tenant identification sign at the entrance to the Project, Tenant shall be entitled to install its name on such sign (subject to availability on a pro-rata basis based on the relative square footages leased by the tenants of the Project), at Tenant’s sole cost and expense. Landlord shall remove or cause to be removed all existing tenant signage from the Building and surrounding area on or before the Lease Commencement Date.

  • Lease Amendments To Agent, within two (2) Business Days after receipt thereof, copies of all material amendments to real estate leases.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!