No Liens or Claims Filed Sample Clauses

No Liens or Claims Filed. Subcontractor will not directly or indirectly file, record, claim, assert, or create or suffer to be created any lien on or affecting the Project or the Project Site, except to the extent of TRC’s unexcused failure to pay any portion of the Subcontract Price if and when due under the terms of this Subcontract to Subcontractor for the Subcontract Work performed by Subcontractor or LTEs (“Permissible Liens”). Except for Permissible Liens, Subcontractor must immediately discharge, vacate, release and remove of record any and all liens on or affecting the Project or Project Site by agreement with the claimant or by posting sufficient security or bond to substitute for the lien. Upon the failure of Subcontractor to comply with the requirements of the preceding sentence, TRC will have the right to cause the release of such claim, lien, or attachment by payment or otherwise and upon such payment, discharge or posting of security therefor, TRC will be entitled to immediately recover from Subcontractor all costs and expenses incurred by TRC, including attorneys’ fees, court costs, and all other expenses, in connection with such payment, discharge or posting, or set off of all such amounts against any sums owed by TRC to Subcontractor. By acceptance of payment, Subcontractor represents and warrants that Subcontractor has paid in full (or will pay in full via proceeds from such pay application) for all labor, services, and materials and all LTEs engaged by Subcontractor in connection with this Subcontract.
Sample 1
AutoNDA by SimpleDocs

Related to No Liens or Claims Filed

  • No Liens or Encumbrances Company's title to and ownership of Company-Owned Interconnection Facilities that were designed and constructed by Seller and/or its Contractors shall be free and clear of liens and encumbrances.

  • No Liens To the knowledge of the Seller, no liens or claims shall have been filed, including liens for work, labor or materials relating to a Financed Vehicle, that shall be liens prior to, or equal or coordinate with, the security interest in such Financed Vehicle granted by the related Receivable.

  • LIENS, CLAIMS AND ENCUMBRANCES The Contractor warrants and represents that all materials, equipment or services delivered herein are free and clear of all liens, claims, or encumbrances of any kind.

  • Other Liens Not to create, assume, or allow any security interest or lien (including judicial liens) on property the Borrower now or later owns, except:

  • Mechanic’s Liens Tenant shall not suffer or permit any mechanic's lien or other lien to be filed against the Premises, or any portion thereof, by reason of work, labor, skill, services, equipment or materials supplied or claimed to have been supplied to the Premises at the request of Tenant, or of anyone holding the Premises, or any portion thereof, by, through or under Tenant. If any such mechanic's lien or other lien at any time shall be filed against the Premises or any portion thereof, Tenant, within thirty (30) days after the date Tenant first becomes aware of the filing of the same, at Tenant's election, shall cause said lien either to be discharged of record or to be bonded over in a manner which is reasonably acceptable to Landlord. If Tenant shall fail to discharge such mechanic's lien or other lien or to bond over the same within such period, then Landlord may, but shall not be obligated to, discharge the same by paying to the claimant the amount claimed to be due or by procuring the discharge of such lien as to the Premises by deposit of a cash sum or a bond or other security, or in such other manner as is now or may in the future be provided by present or future law for the discharge of such lien as a lien against the Premises. Any amount paid by Landlord, or the value of any deposit so made by Landlord, together with all costs, fees and expenses in connection therewith (including reasonable attorneys' fees), together with interest thereon at the Maximum Rate of Interest, shall be repaid by Tenant to Landlord within thirty (30) days after demand therefor. Tenant shall indemnify, defend and hold harmless Landlord and the Premises from all losses, costs, damages, expenses, liabilities, suits, penalties, claims, demands and obligations, including, without limitation, reasonable attorneys' fees, resulting from the assertion, filing, foreclosure or other legal proceedings with respect to any such mechanic's lien or other lien.

  • Adverse Claims Borrower will promptly advise Lender in writing of any litigation, Liens or claims affecting the Mortgaged Property and of all complaints and charges made by any Governmental Authority that may delay or adversely affect the Repairs or Capital Replacements.

  • Claims relating to Intellectual Property Rights 29.1. The Contractor must not infringe any Intellectual Property Rights of any third party in providing the Services or otherwise performing its obligations under the Framework Agreement and must ensure that the provision of the Services and the use or possession of the Deliverables does not infringe such Intellectual Property Rights.

  • Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.

  • Liens Create, incur, assume or suffer to exist any Lien upon any of its property, assets or revenues, whether now owned or hereafter acquired, other than the following:

  • FALSE CLAIMS Contractor warrants that it shall not, with respect to this Contract, make or present any claim upon or against the Government of the Virgin Islands, or any officer, department, board, commission, or other agency thereof, knowing such claim to be false, fictitious or fraudulent. Contractor acknowledges that making such a false, fictitious, or fraudulent claim is an offense under Virgin Islands law.

Time is Money Join Law Insider Premium to draft better contracts faster.