STRIKE AND LOCKOUT During the term of this Agreement there shall be no lockout by the Company, and no strike, stoppage of work, or slow-down, either partial or general, authorized by the Union.
Gaming, betting and lotteries The Hirer shall ensure that nothing is done on or in relation to the premises in contravention of the law relating to gaming, betting and lotteries.
STRIKES AND LOCK-OUTS The Contractor shall forthwith notify the Engineer of the commencing of any strike or lock-out and the Engineer on account of any delay caused thereby may, after consultation with the Employer, grant such extension of time as he considers reasonable without prejudice to the right of the Employer to exercise after the expiration of such reasonable extension of time the rights and powers under these Conditions in case of default by the Contractor.
BOARD AND LODGING (While fighting Company Responsibility Fires)
a) Employees who commute from home or camp are expected to ‘carry a lunch’. Additional meals where required will be at Company expense.
b) Employees required to live away from their private residence will receive board and lodging at Company expense.
c) Employees living in fly camps will receive board and lodging at Company expense.
Sublease Limitation For so long as Landlord or any Affiliated Person as to Landlord shall seek to qualify as a real estate investment trust, anything contained in this Agreement to the contrary notwithstanding, Tenant shall not sublet the Leased Property on any basis such that the rental to be paid by any sublessee thereunder would be based, in whole or in part, on either (a) the income or profits derived by the business activities of such sublessee, or (b) any other formula such that any portion of such sublease rental would fail to qualify as "rents from real property" within the meaning of Section 856(d) of the Code, or any similar or successor provision thereto.
Traffic Management 9.2.1 During the Operating Period, Developer shall be responsible for the general management of traffic on the Project. Developer shall manage traffic so as to preserve and protect safety of traffic on the Project and Related Transportation Facilities and, to the maximum extent practicable, to avoid disruption, interruption or other adverse effects on traffic flow, throughput or level of service on the Project and Related Transportation Facilities. Developer shall conduct traffic management in accordance with all applicable Technical Provisions, Technical Documents, Laws and Governmental Approvals, and in accordance with the Traffic Management Plan.
9.2.2 Developer shall prepare and submit to TxDOT and the Independent Engineer for TxDOT approval a Traffic Management Plan for managing traffic on the Project and Related Transportation Facilities after the commencement of traffic operations on any portion of the Project, addressing (a) orderly and safe movement and diversion of traffic on Related Transportation Facilities during Project construction, (b) orderly and safe movement of traffic on the Project and (c) orderly and safe diversion of traffic on the Project and Related Transportation Facilities necessary in connection with field maintenance and repair work or Renewal Work or in response to Incidents, Emergencies and lane closures. Developer shall prepare the Traffic Management Plan according to the schedule set forth in the Technical Provisions. The Traffic Management Plan shall comply with the Technical Provisions and Technical Documents concerning traffic management and traffic operations. Developer shall carry out all traffic management during the Term in accordance with the approved Traffic Management Plan.
9.2.3 Developer shall implement the Traffic Management Plan to promote safe and efficient operation of the Project and Related Transportation Facilities at all times during the course of any construction or operation of the Project and during the Utility Adjustment Work.
9.2.4 TxDOT shall have at all times, without obligation or liability to Developer, the right
9.2.4.1 Issue Directive Letters to Developer regarding traffic management
9.2.4.2 Provide on the Project, via message signs or other means consistent with Good Industry Practice, non-Discriminatory traveler and driver information, and other public information (e.g. amber alerts), provided that the means to disseminate such information does not materially interfere with the functioning of the ETCS.
Xxxxxxx Xxxxxxx Restrictions/Market Abuse Laws The Participant acknowledges that, depending on his or her country, the broker’s country, or the country in which the Shares are listed, the Participant may be subject to xxxxxxx xxxxxxx restrictions and/or market abuse laws in applicable jurisdictions, which may affect his or her ability to accept, acquire, sell, or attempt to sell or otherwise dispose of Shares or rights to Shares (e.g., Restricted Share Units), or rights linked to the value of Shares, during such times as he or she is considered to have “inside information” regarding the Company (as defined by applicable laws or regulations in the applicable jurisdictions, including the United States and the Participant’s country). Local xxxxxxx xxxxxxx laws and regulations may prohibit the cancellation or amendment of orders the Participant placed before possessing inside information. Furthermore, the Participant may be prohibited from (i) disclosing the inside information to any third party, including fellow employees (other than on a “need to know” basis) and (ii) “tipping” third parties or causing them to otherwise buy or sell securities. Any restrictions under these laws or regulations are separate from and in addition to any restrictions that may be imposed under any applicable Company xxxxxxx xxxxxxx policy. The Participant acknowledges that it is his or her responsibility to comply with any applicable restrictions, and the Participant should consult his or her personal advisor on this matter.
Meals and Lodging Meals and lodging expenses shall be paid in accordance with the Financial Policy and Procedures issued by the Administrative Office of the Courts.
Log and Load Reporting Service This contract may at the States discretion, require the services of a State approved third party log and load reporting service. Purchaser shall ensure log volume measurement, weight, or scale and weight data for each load is received by the log and load reporting service within 1 business day of logs being measured or weighed. If during the term of this contract, the State discontinues use of the Log and Load Reporting Service, the State will notify the Purchaser in writing, and will approve an alternative log and load reporting process. Determination of volume and grade of any forest products shall be conducted by a state approved third party scaling organization and in accordance with the Westside log scaling and grading rules and Xxxxxxxx Volume Table, revised July 1, 1972, contained in the Northwest Log Rules Eastside and Westside Log Scaling Handbook (developed and produced by the Northwest Log Rules Advisory Group) and in effect on the date of confirmation of this contract. Special scaling specifications shall be noted on the State’s Brand Designation form which is hereby incorporated to this contract by reference. Forest Product measurement and weighing facilities required by this contract must be approved by the State. Forest products sold under the contract which require log scaling shall be scaled, measured, or counted by a State approved third party log scaling organization. Forest products sold under the contract which require weighing shall be weighed at a location that meets Washington State Department of Agriculture approval. Prior to forest products being hauled, the Contract Administrator must authorize in writing the use of State approved measurement and/or weighing facilities that are at or en-route to final destinations. Forest products from this sale shall be measured or weighed at facilities, which are currently approved for use by the State and are currently authorized for this sale. The State reserves the right to verify load volume and weights with State employees or contractors at the State's own expense. The State reserves the right to revoke the authorization of previously approved measurement locations.
Secure Information Handling and Transfers 7.1 Physical and electronic handling, processing and transferring of DWP Data, including secure access to systems and the use of encryption where appropriate.
