Amortization Schedule We do not provide an initial amortization schedule at the time of project agreement release but maintain a "Loan Summary Spreadsheet" on our website on the Financial Tab under "Loans". Once your loan is put into billing an amortization schedule will be posted to the same website, with a copy mailed to the Chief Financial Officer the month following project closeout.
Contract Schedule The information set forth in the Contract Schedule is true and correct.
Shift Schedule The words "shift schedule" when used in this Agreement shall mean a timetable of the shifts and off days assigned to a position or group of positions which commences at the beginning of a pay period and includes one complete rotation of said shifts.
Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement.
2. Time off, based upon service in the Industry Vacation Plan, may be granted to an employee by mutual agreement between the Employer and the employee. The Employer shall not be required to give time off based upon service under the Industry Vacation Plan. However, if such additional industry vacation time off is granted to an employee, such time off shall be counted as time worked for the purpose of computing the employee's earned vacation benefits on his next anniversary date of employment.
Repayment Schedule Repayments shall be made semiannually (twice per year). The Semiannual Loan Payment shall be computed based upon the principal amount of the Loan plus the estimated Loan Service Fee and the principle of level debt service. The Semiannual Loan Payment amount may be adjusted, by amendment of this Agreement, based upon revised information. After the final disbursement of Loan proceeds, the Semiannual Loan Payment shall be based upon the actual Project costs, the actual Loan Service Fee and the Loan Service Fee capitalized interest, if any, and actual dates and amounts of disbursements, taking into consideration any previous payments. Actual Project costs shall be established after the Department's inspection of the completed Project and associated records. The Department will deduct the Loan Service Fee and any associated interest from the first available repayments following the Final Amendment. Each Semiannual Loan Payment shall be in the amount of $140,599 until the payment amount is adjusted by amendment. The interest portion of each Semiannual Loan Payment shall be computed on the unpaid balance of the principal amount of the Loan, including Capitalized Interest. Interest also shall be computed on the unpaid balance of the Loan Service Fee. Interest shall be computed as of the due date of each Semiannual Loan Payment. Semiannual Loan Payments shall be received by the Department beginning on October 15, 2021 and semiannually thereafter on April 15 and October 15 of each year until all amounts due hereunder have been fully paid. Funds transfer shall be made by electronic means. The Semiannual Loan Payment amount is based on the total amount to be repaid of $5,105,900, which consists of the Loan principal and the estimated Loan Service Fee.
Vacation Schedules (a) Completed vacation schedules will be posted by April 30th of each year. The schedule will be circulated commencing February 1st of the same year.
(b) An employee who does not exercise her seniority rights within two (2) weeks of receiving the vacation schedule, shall not be entitled to exercise those rights in respect to any vacation time previously selected by an employee with less seniority.
(c) An employee who relocates to another work location where the vacation schedule has already been completed will not be entitled to exercise her seniority rights for that year only. However, every effort shall be made to grant vacation at the time of the employee's choice.
REVIEW OF CONTRACT DOCUMENTS 4.2.1 The Contractor shall carefully study and compare the Contract Documents and shall immediately report in writing to the Architect and the State any error, inconsistency or omission he may discover. The Contractor shall not be liable to the State or the Architect for any damage resulting from any such errors, inconsistencies or omissions in the Contract Documents. The
Payment Schedule The purchase price for timber sold under this contract shall be paid in advance as follows: The first payment shall be paid within 30 days of the notification of high bid or before operating, whichever occurs first. The first payment shall be 10 percent of the total estimated bid value. The total estimated bid value shall be the sum obtained by multiplying the estimated timber volumes by the prices given in Section 44 less the amount of the project work. Cash bid deposits shall be applied to the initial payment. Subsequent payments shall be made in advance of timber removal when log hauling begins. Each payment shall be made before the value of timber removed equals one-half an advance payment or within the time period stated on the billing if PURCHASER is more than one-half of a payment in advance. The amount of each advance payment shall be calculated by dividing the total estimated bid value less the initial payment by 9; with the total estimated bid value being the sum obtained by multiplying the estimated timber volumes by the prices given in Section 44 less the amount of the project work. STATE may accept partial payment, upon written request, if logging is inactive. However, the full amount of advance payment is paid before logging resumes. Partial payment must be sufficient to maintain a payment deposit equal to one-half of a regular advance payment. The total purchase price shall be calculated after all log scale is reported by multiplying prices in Section 44 by the scaled volume. STATE shall refund any advance payment in excess of the total price, or PURCHASER shall pay any deficit within 30 days of notice. PURCHASER's deposit account shall not accrue interest payable to PURCHASER.
Completion Schedule 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof.
6.2 ENGINEER shall adhere to all time limits stated in this Agreement or included in any accepted time schedule. All such time limits shall be of the essence to this Agreement.
6.3 In all events the various stages and phases of ENGINEER’S services are to be completed in such sequence and at such times, and with approved or agreed upon time limits, as may be required to assure the timely, continuous, efficient and diligent prosecution of the work and services provided for by this Agreement.
6.4 OWNER may at any time, by written order, make changes within the general scope of the Agreement in the services of work to be performed. If ENGINEER believes that such a change justifies an increase in ENGINEER’S contract time or contract price required to perform the series under this Agreement it must assert such claim in writing within thirty (30) days of receipt of OWNER’S written order giving rise to the claim. No claim for adjustment in the contract time or contract price will be valid if not submitted in accordance with this paragraph. No services for which ENGINEER will charge additional compensation shall be furnished without the written authorization of OWNER.
6.5 ENGINEER shall carry on all work required under this Agreement and maintain the schedule for services during all disputes or disagreements with OWNER. No work shall be delayed or postponed pending resolution of any disputes or disagreements except as permitted in Article 8, or as ENGINEER and OWNER may otherwise agree in writing.
6.6 If the commencement, prosecution or completion of the services under this Agreement, or of the construction of the Project is delayed by any act, omission, delay, neglect or default of ENGINEER, or anyone employed by ENGINEER, or by any damage or acts caused by the negligent acts or omission by ENGINEER, then ENGINEER shall be liable to OWNER for any and all costs, assessments, expense, liabilities or damages caused thereby, in accordance with Section 4.8.
6.7 ENGINEER shall not be responsible for any time delays in the Project, or in the performance of services under this Agreement, to the extent such delays are caused solely by any act, omission, neglect or default of OWNER or anyone employed by OWNER, or by the unreasonable delay of any review agency or utility, or for any delay or damage caused by fire or the combined action of workers and which are in no way chargeable, in whole or in part, to ENGINEER, or by any other conditions or circumstances beyond the control of ENGINEER, its employee, agent, or other persons for whose acts or omissions ENGINEER is responsible. In the event of such delay, ENGINEER shall be entitled to an adjustment in the schedules or agreed time limitations for the performance of services, and this Agreement shall be modified in writing accordingly. Any claim of ENGINEER for adjustment under this cause must be asserted in writing within thirty (30) days from the date of the occurrence of the event giving rise to the claim, unless OWNER grants a further period of time before the date of final payment to ENGINEER. The adjustment of time for the performance of services, as provided in this paragraph, shall be ENGINEER’s sole exclusive right, entitlement and remedy in the event of such delays, and ENGINEER shall have no claim against OWNER for adjustment for increase in costs of performance, or other damages occurred in connection therewith.
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
