Accidents If a death, serious personal injury or substantial property damage occurs in connection with CONTRACTOR’s performance of this Agreement, CONTRACTOR shall immediately notify Mendocino County Risk Manager's Office by telephone. CONTRACTOR shall promptly submit to COUNTY a written report, in such form as may be required by COUNTY of all accidents which occur in connection with this Agreement. This report must include the following information: (1) name and address of the injured or deceased person(s); (2) name and address of CONTRACTOR's sub-contractor, if any; (3) name and address of CONTRACTOR's liability insurance carrier; and (4) a detailed description of the accident and whether any of COUNTY's equipment, tools, material, or staff were involved.
SAVINGS/FORCE MAJEURE A Force Majeure occurrence is an event or effect that cannot be reasonably anticipated or controlled and is not due to the negligence or willful misconduct of the affected party. Force Majeure includes, but is not limited to, acts of God, acts of war, acts of public enemies, terrorism, strikes, fires, explosions, actions of the elements, floods, or other similar causes beyond the control of the Contractor or the Commissioner in the performance of the Contract where non- performance, by exercise of reasonable diligence, cannot be prevented. The affected party shall provide the other party with written notice of any Force Majeure occurrence as soon as the delay is known and provide the other party with a written contingency plan to address the Force Majeure occurrence, including, but not limited to, specificity on quantities of materials, tooling, people, and other resources that will need to be redirected to another facility and the process of redirecting them. Furthermore, the affected party shall use its commercially reasonable efforts to resume proper performance within an appropriate period of time. Notwithstanding the foregoing, if the Force Majeure condition continues beyond thirty (30) days, the Parties shall jointly decide on an appropriate course of action that will permit fulfillment of the Parties’ objectives hereunder. The Contractor agrees that in the event of a delay or failure of performance by the Contractor, under the Contract due to a Force Majeure occurrence:
a. The Commissioner may purchase from other sources (without recourse to and by the Contractor for the costs and expenses thereof) to replace all or part of the Products which are the subject of the delay, which purchases may be deducted from the Contract quantities without penalty or liability to the State, or
b. The Contractor will make commercially reasonable efforts to provide Authorized Users with access to Products first in order to fulfill orders placed before the Force Majeure event occurred. The Commissioner agrees that Authorized Users shall accept allocated performance or deliveries during the occurrence of the Force Majeure event. Neither the Contractor nor the Commissioner shall be liable to the other for any delay in or failure of performance under the Contract due to a Force Majeure occurrence. Any such delay in or failure of performance shall not constitute default or give rise to any liability for damages. The existence of such causes of such delay or failure shall extend the period for performance to such extent as determined by the Contractor and the Commissioner to be necessary to enable complete performance by the Contractor if reasonable diligence is exercised after the cause of delay or failure has been removed. Notwithstanding the above, at the discretion of the Commissioner where the delay or failure will significantly impair the value of the Contract to the State or to Authorized Users, the Commissioner may terminate the Contract or the portion thereof which is subject to delays, and thereby discharge any unexecuted portion of the Contract or the relative part thereof. In addition, the Commissioner reserves the right, in his/her sole discretion, to make an equitable adjustment in the Contract terms and/or pricing should extreme and unforeseen volatility in the marketplace affect pricing or the availability of supply. "Extreme and unforeseen volatility in the marketplace" is defined as market circumstances which meet the following criteria: (i) the volatility is due to causes outside the control of Contractor; (ii) the volatility affects the marketplace or industry, not just the particular Contract source of supply; (iii) the effect on pricing or availability of supply is substantial; and (iv) the volatility so affects Contractor's performance that continued performance of the Contract would result in a substantial loss. Failure of the Contractor to agree to any adjustment shall be a dispute under the Disputes clause; provided however, that nothing in this clause shall excuse the Contractor from performing in accordance with the Contract as changed.
Catastrophic Leave Program Leave credits, as defined below, may be transferred from one (1) or more employees to another employee, on an hour-for-hour basis, in accordance with departmental policies upon the request of both the receiving employee and the transferring employee and upon approval of the employee's appointing authority, under the following conditions:
A. The receiving employee is required to be absent from work due to injury or the prolonged illness of the employee, employee's spouse, registered domestic partner, a domestic partner listed on an “Affidavit for Enrollment of Domestic Partners,” submitted to employee benefits, parent or child, has exhausted all earned leave credits, including but not limited to sick leave, compensatory time, holiday credits and disability leave and is therefore facing financial hardship.
B. The transfers must be for a minimum of four (4) hours and in whole hour increments thereafter.
C. Transfers shall be allowed to cross-departmental lines in accordance with the policies of the receiving department.
D. The total maximum leave credits received by an employee shall normally not exceed five hundred twenty (520) hours; however, if approved by his/her appointing authority, the total leave credits may be up to one thousand forty (1,040) hours. Total leave credits in excess of one thousand forty (1,040) hours will be considered on a case-by-case basis by the appointing authority subject to the approval of the Chief Administrative Officer.
E. The transfers are irrevocable, and will be indistinguishable from other leave credits belonging to the receiving employee. Transfers will be subject to all taxes required by law.
F. Leave credits that may be transferred under this program are defined as the transferring employee’s vacation credits or up to twenty-four (24) hours of sick leave per fiscal year.
G. Transfers shall be administered according to the rules and regulations of the Auditor and Controller, and made on a form prescribed by the Auditor and Controller. Approvals of the receiving and donating employee, the donating employee's appointing authority and the receiving employee's appointing authority (in the case of an interdepartmental transfer) will be provided for on such form.
H. This program is not subject to the Grievance Procedure of this Agreement.
Corrective Measures If the Participating Generator fails to meet or maintain the requirements set forth in this Agreement and/or the CAISO Tariff, the CAISO shall be permitted to take any of the measures, contained or referenced in the CAISO Tariff, which the CAISO deems to be necessary to correct the situation.
Catastrophic Leave The County will administer a Catastrophic Leave procedure designed to permit individual donations of annual leave, vacation, healthcare leave (8 hours maximum per fiscal year), compensatory and/or PIP leave time to an employee who is required to be on an extended unpaid leave due to a catastrophic medical condition or other serious circumstances.
Pandemic An epidemic that spreads over a wide area, crossing borders and defined as a pandemic by the World Health Organisation (WHO) and/or by the competent local authorities of the country where the loss occurred. Isolation of the person, in the event of suspected illness or proven illness, decided by a competent local authority, in order to avoid a risk of spreading said illness in the context of an epidemic or pandemic.
Accident Prevention Health and Safety Committee (a) The Employer and the Union agree that they mutually desire to maintain standards of safety and health in the workplace in order to prevent accidents, injury and illness.
(b) Recognizing its responsibilities under the applicable legislation, the Employer agrees to accept as a member of its Accident Prevention – Health & Safety Committee at least three (3) representatives, one from each base, selected or appointed by the Union from amongst bargaining unit employees. At any time where a vote is required, an equal number of representatives from each side shall be entitled to vote.
(c) Such Committee shall identify potential dangers and hazards, institute means of improving health and safety programs and recommend actions to be taken to improve conditions related to safety and health.
(d) The Employee agrees to co-operate reasonably in providing necessary information to enable the Committee to fulfill its functions.
(e) Meetings shall be held quarterly or more frequently at the call of the Chair if required. The Committee shall maintain minutes of all meetings and make the same available for review.
(f) Any representative appointed or select in accordance with (b) hereof shall serve a term of one (1) calendar year from the date of appointment which may be renewed for further periods of one (1) year. The Union will encourage its representative(s) to serve at least one (1) year. Time off for such representative(s) to attend meetings of the Accident Prevention – Health & Safety Committee in accordance with the foregoing shall be granted and time so spent attending such meetings shall be deemed to be work time for which the representative(s) shall be paid by the Employer at his regular or premium rate as may be applicable.
(g) The Union agrees to endeavour to obtain the full co-operation of its membership in the observation of all safety rules and practices.
(h) Pregnant employees may request to be transferred from their current duties if, in the professional opinion of the employee’s physician, the pregnancy may be at risk. If such a transfer is not feasible, the pregnant employee, if she so requests, will be granted an unpaid leave of absence before commencement of the maternity leave referred to in Article 16.04
FLORIDA CONVICTED/SUSPENDED/DISCRIMINATORY COMPLAINTS By submission of an offer, the respondent affirms that it is not currently listed in the Florida Department of Management Services Convicted/Suspended/Discriminatory Complaint Vendor List.
ENDANGERED SPECIES The Endangered Species Act of 1973 (16 U.S.C. § 1531, et seq.) as amended, particularly section 7 (16 U.S.C. § 1536).
Communicable Disease Bodily injury" or "property damage" which arises out of the transmission of a communi- cable disease by an "insured";
