Notice by Successful Respondent Sample Clauses

Notice by Successful Respondent. Without limiting its obligations under this Agreement, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or DIR Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall work with DIR, the DIR Customers, and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the DIR Customers, and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the DIR Customers and DIR Contractors.
Sample 1Sample 2Sample 3See All (8)
AutoNDA by SimpleDocs
Notice by Successful Respondent. Without limiting its obligations under this CTSA, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall work with DIR, the Customers, and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the Customers, and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the Customers and DIR Contractors.
Sample 1Sample 2Sample 3See All (4)
Notice by Successful Respondent. Without limiting its obligations under this Agreement, Successful Respondent shall expeditiously notify DIR when it becomes aware that an act or omission of DIR or DCS Customer personnel or a DIR Contractor shall cause, or has caused, a problem or delay in providing the Services, and shall work with DIR, the DCS Customers, and the DIR Contractor to prevent or circumvent such problem or delay. Successful Respondent shall cooperate with DIR, the DCS Customers, and DIR Contractors to resolve differences and conflicts arising between the Services and other activities undertaken by DIR, the DCS Customers and DIR Contractors.
Sample 1

Related to Notice by Successful Respondent

  • Notification to Unsuccessful Job Applicants The parties agree that any unsuccessful candidate for an ONA job posting will be notified, in writing, within one (1) week of the decision being made and prior to the posting of the name of the successful candidate. The parties further agree that the above notification will be copied to the ONA Bargaining Unit President.

  • Notice of Legal Actions The Contractor must notify the Department of any legal actions filed against it for a violation of any laws, rules, codes, ordinances or licensing requirements within 30 days of the action being filed. The Contractor must notify the Department of any legal actions filed against it for a breach of a contract of similar size and scope to this Contract within 30 days of the action being filed. Failure to notify the Department of a legal action within 30 days of the action will be grounds for termination for cause of the Contract.

  • Conflict of Interest Questionnaire - Form CIQ No response Do not upload this form unless you have a reportable conflict with TIPS. There is an Attribute entitled “Conflict of Interest Questionnaire Requirement” immediately followed by an Attribute entitled “Conflict of Interest Questionnaire Requirement – Form CIQ – Continued.” Properly respond to those Attributes and only upload this form if applicable/instructed. If upload is required based on your response to those Attributes, the Conflict of Interest Questionnaire – Form CIQ must be downloaded from the “Attachments” section of the IonWave eBid System, reviewed, properly completed, and uploaded at this location.

  • ONLY No response If proposing on Part 2, the vendor must download the Vendor Agreement from the attachment tab, fill in the requested information and upload the completed agreement. DO NOT UPLOAD encrypted or password protected files.

  • Notice of Hearing At least ten (10) days prior to the scheduled hearing, the claimant and his representative designated in writing by him, if any, shall receive written notice of the date, time, and place of such scheduled hearing. The claimant or his representative, if any, may request that the hearing be rescheduled, for his convenience, on another reasonable date or at another reasonable time or place.

  • Alternate or Supplemental Pricing Documents No response Optional. If when completing Pricing Form 1 & Pricing Form 2 you direct TIPS to view additional, alternate, or supplemental pricing documentation, you may upload that documentation.

  • Notice of Legal Matter or Litigation Grantee will send notice to the Substance Use Disorder (SUD) email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx of any litigation or legal matter related to or affecting this Contract within seven (7) calendar days of becoming aware of the litigation or legal matter.

  • Interest Questionnaire - Form CIQ No response Do not upload this form unless you have a reportable conflict with TIPS. There is an Attribute entitled “Conflict of Interest Questionnaire Requirement” immediately followed by an Attribute entitled “Conflict of Interest Questionnaire Requirement – Form CIQ – Continued.” Properly respond to those Attributes and only upload this form if applicable/instructed. If upload is required based on your response to those Attributes, the Conflict of Interest Questionnaire – Form CIQ must be downloaded from the “Attachments” section of the IonWave eBid System, reviewed, properly completed, and uploaded at this location.

  • Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.

  • Filing of Amendments; Response to Commission Requests The Company will promptly advise the Representatives of any proposal to amend or supplement at any time the Initial Registration Statement, any Additional Registration Statement or any Statutory Prospectus and will not effect such amendment or supplementation without the Representatives’ consent; and the Company will also advise the Representatives promptly of (i) the effectiveness of any Additional Registration Statement (if its Effective Time is subsequent to the execution and delivery of this Agreement), (ii) any amendment or supplementation of a Registration Statement or any Statutory Prospectus, (iii) any request by the Commission or its staff for any amendment to any Registration Statement, for any supplement to any Statutory Prospectus or for any additional information, (iv) the institution by the Commission of any stop order proceedings in respect of a Registration Statement or the threatening of any proceeding for that purpose, and (v) the receipt by the Company of any notification with respect to the suspension of the qualification of the Offered Securities in any jurisdiction or the institution or threatening of any proceedings for such purpose. The Company will use its best efforts to prevent the issuance of any such stop order or the suspension of any such qualification and, if issued, to obtain as soon as possible the withdrawal thereof.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!