Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Legal Action Notice A prompt report of any legal actions pending or threatened in writing against Borrower or any of its Subsidiaries that could result in damages or costs to Borrower or any of its Subsidiaries of, individually or in the aggregate, One Hundred Thousand Dollars ($100,000) or more; and
Notice of Events As soon as Guarantor obtains knowledge thereof, Guarantor shall give Guarantied Party written notice of any condition or event which has resulted in (a) a material adverse change in the financial condition of Guarantor or Company or (b) any Event of Default or Potential Event of Default.
Notice of Impositions Lessor shall give prompt Notice to Lessee of all Impositions payable by Lessee hereunder of which Lessor at any time has knowledge, provided that Lessor’s failure to give any such Notice shall in no way diminish Lessee’s obligations hereunder to pay such Impositions, but such failure shall obviate any default hereunder for a reasonable time after Lessee receives Notice of any Imposition which it is obligated to pay during the first taxing period applicable thereto.
Notice of Claim Promptly after receipt by an Investor Indemnitee or Company Indemnitee of notice of the commencement of any action or proceeding (including any governmental action or proceeding) involving an Indemnified Liability, such Investor Indemnitee or Company Indemnitee, as applicable, shall, if a claim for an Indemnified Liability in respect thereof is to be made against any indemnifying party under this Article V, deliver to the indemnifying party a written notice of the commencement thereof; but the failure to so notify the indemnifying party will not relieve it of liability under this Article V except to the extent the indemnifying party is prejudiced by such failure. The indemnifying party shall have the right to participate in, and, to the extent the indemnifying party so desires, jointly with any other indemnifying party similarly noticed, to assume control of the defense thereof with counsel mutually reasonably satisfactory to the indemnifying party and the Investor Indemnitee or Company Indemnitee, as the case may be; provided, however, that an Investor Indemnitee or Company Indemnitee shall have the right to retain its own counsel with the actual and reasonable third party fees and expenses of not more than one counsel for such Investor Indemnitee or Company Indemnitee to be paid by the indemnifying party, if, in the reasonable opinion of counsel retained by the indemnifying party, the representation by such counsel of the Investor Indemnitee or Company Indemnitee and the indemnifying party would be inappropriate due to actual or potential differing interests between such Investor Indemnitee or Company Indemnitee and any other party represented by such counsel in such proceeding. The Investor Indemnitee or Company Indemnitee shall cooperate fully with the indemnifying party in connection with any negotiation or defense of any such action or claim by the indemnifying party and shall furnish to the indemnifying party all information reasonably available to the Investor Indemnitee or Company Indemnitee which relates to such action or claim. The indemnifying party shall keep the Investor Indemnitee or Company Indemnitee reasonably apprised as to the status of the defense or any settlement negotiations with respect thereto. No indemnifying party shall be liable for any settlement of any action, claim or proceeding effected without its prior written consent, provided, however, that the indemnifying party shall not unreasonably withhold, delay or condition its consent. No indemnifying party shall, without the prior written consent of the Investor Indemnitee or Company Indemnitee, consent to entry of any judgment or enter into any settlement or other compromise which does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Investor Indemnitee or Company Indemnitee of a release from all liability in respect to such claim or litigation. Following indemnification as provided for hereunder, the indemnifying party shall be subrogated to all rights of the Investor Indemnitee or Company Indemnitee with respect to all third parties, firms or corporations relating to the matter for which indemnification has been made. The indemnification required by this Article V shall be made by periodic payments of the amount thereof during the course of the investigation or defense, as and when bills are received and payment therefor is due.
Notice of Complaints Each Seller shall promptly notify the applicable Purchaser upon becoming aware of any complaint concerning any Serviced Appointment made by any party to the Serviced Corporate Trust Contracts, any Securityholder, any Credit Enhancement Provider or any rating agency.
CAFA Notice Pursuant to 28 U.S.C. § 1715, not later than ten (10) days after the Agreement is filed with the Court, the Settlement Administrator shall cause to be served upon the Attorneys General of each U.S. State in which Settlement Class members reside, the Attorney General of the United States, and other required government officials, notice of the proposed settlement as required by law, subject to Paragraph 5.1 below.
Notice of Legal Actions The Contractor must notify the Department of any legal actions filed against it for a violation of any laws, rules, codes, ordinances or licensing requirements within 30 days of the action being filed. The Contractor must notify the Department of any legal actions filed against it for a breach of a contract of similar size and scope to this Contract within 30 days of the action being filed. Failure to notify the Department of a legal action within 30 days of the action will be grounds for termination for cause of the Contract.
Notice of Material Events The Borrower will notify the Administrative Agent, for distribution to the LC Issuer and each Lender, promptly, and not later than five (5) Business Days in the case of subsection (b) below and not later than ten (10) Business Days in the case of any other subsection below, after any Responsible Officer or general counsel of the Borrower has knowledge thereof, stating that such notice is being given pursuant to this Agreement, of: (a) the occurrence of any event or circumstance that has had, or could reasonably be expected to have, a Material Adverse Effect, (b) the occurrence of any Default, (c) the acceleration of the maturity of any Indebtedness owed by the Borrower or any of its Subsidiaries or of any default by the Borrower or any of its Subsidiaries under any Contractual Obligation of the Borrower or such Subsidiary, if such acceleration or default has had or could reasonably be expected to have a Material Adverse Effect, (d) the occurrence of any Termination Event, (e) the filing of any suit or proceeding, or the assertion in writing of a claim against the Borrower or any Material Subsidiary or with respect to the Borrower’s or any Material Subsidiary’s properties which could reasonably be expected to result in liability to Borrower or such Material Subsidiary in excess of $50,000,000; (f) the occurrence of any event of default by the Borrower or any of its Subsidiaries in the payment or performance of (i) any material obligations such Person is required to pay or perform under the terms of any indenture, mortgage, deed of trust, security agreement, lease, and franchise, or other agreement, contract or other instrument or obligation to which it is a party or by which it or any of its properties is bound, or (ii) any Indebtedness, to the extent, in the case of clauses (i) and (ii), such event of default could reasonably be expected to have a Material Adverse Effect; and (g) any announcement of any change in a Rating. Each notice pursuant to this Section shall be accompanied by a statement of a Responsible Officer of the Borrower setting forth details of the occurrence referred to herein and stating what action the Borrower, Subsidiary or Material Subsidiary, as applicable, has taken and proposes to take with respect thereto. Each notice pursuant to Section 6.03(b) shall describe with particularity any all provisions of this Agreement and if, applicable, other Loan Documents, that have been breached.
Notice of Nonpayment The Trustee shall notify the Grantor and the Division by certified mail within 10 days following expiration of the 30-day period after the anniversary of the establishment of the Trust, if no payment is received from the Grantor during that period. After the pay-in period is completed, the Trustee shall not be required to send a notice of nonpayment.