NOTICE TO BUYER OF CALIFORNIA CONSTRUCTION CLAIMS STATUTE Sample Clauses

NOTICE TO BUYER OF CALIFORNIA CONSTRUCTION CLAIMS STATUTE. The California Legislature has enacted Title 7, Part 2 of Division 2 of the Civil Code, commonly referred to as the Construction Claims Statute or SB 800 (hereinafter “the Code”) which provides certain standards, requirements and procedures for claims of construction defects in new homes first sold after January 1, 2003. Chapter 2 of the Code provides certain standards regarding the functionality of the home (“Functionality Standards”) and lengths of time for these standards by which the Buyer may pursue repair/redress under the Code (Civil Code Sections 896 and 897). Under the Code, the Seller shall elect whether it will follow the standards and procedures of the Code or provide alternative standards and procedures which are still in compliance with the Code. Seller shall provide a copy of the Code to Buyer. By initialing this section, Buyer acknowledges receipt of the entire part of the Code and that the Code is binding on Buyer’s successors-in-interest pursuant to Civil Code Section 945. Therefore, Buyer acknowledges being obligated to provide a copy of the Code to a subsequent purchaser of the Property from Buyer. BUYER'S INITIALS /
Sample 1
AutoNDA by SimpleDocs

Related to NOTICE TO BUYER OF CALIFORNIA CONSTRUCTION CLAIMS STATUTE

  • All Claims Must be Arbitrated It is the intention of the parties that this agreement bind all parties whose claims may arise out of or relate to treatment or service provided by the physician including any spouse or heirs of the patient and any children, whether born or unborn at the time of the occurrence giving rise to any claim. In the case of any pregnant mother, the term “patient” herein shall mean both the mother and the mother’s expected child or children. All claims for monetary damages exceeding the jurisdictional limit of the small court against the physician, and physician’s partners, associates, association, corporation partnership, and the employees, agents, and estates of any of them, must be arbitrated including, without limitation, claims for loss of consortium, wrongful death, emotional distress, or punitive damages. Filing any action in any court by the physician to collect any fee from the patient shall not waive the right to compel arbitration of any malpractice claim.

  • California Civil Code § 1542 It is possible that other claims not known to the Parties arising out of the facts alleged in the Notice and relating to the Products will develop or be discovered. CPA on behalf of itself only, on one hand, and Empire, on the other hand, acknowledge that this Agreement is expressly intended to cover and include all such claims up through the Effective Date, including all rights of action therefore. The Parties acknowledge that the claims released in §§ 5.1 and 5.2, above, may include unknown claims, and nevertheless waive California Civil Code § 1542 as to any such unknown claims. California Civil Code § 1542 reads as follows: A GENERAL RELEASE DOES NOT EXTEND TO CLAIMS THAT THE CREDITOR OR RELEASING PARTY DOES NOT KNOW OR SUSPECT TO EXIST IN HIS OR HER FAVOR AT THE TIME OF EXECUTING THE RELEASE AND THAT, IF KNOWN BY HIM OR HER, WOULD HAVE MATERIALLY AFFECTED HIS OR HER SETTLEMENT WITH THE DEBTOR OR RELEASED PARTY. CPA and Empire each acknowledge and understand the significance and consequences of this specific waiver of California Civil Code § 1542.

  • Agreement Made in California; Venue The formation, interpretation and performance of this Agreement shall be governed by the laws of the State of California. Venue for all litigation relative to the formation, interpretation and performance of this Agreement shall be in San Francisco.

  • Certification of claims by Statutory Auditors Any claim or document provided by the Concessionaire to the Authority in connection with or relating to receipts, income, payments, costs, expenses, accounts or audit, and any matter incidental thereto shall be valid and effective only if certified by its Statutory Auditors. For the avoidance of doubt, such certification shall not be required for exchange of information in the normal course of business including the submission of Monthly Fee Statements under Clause 19.5.

  • NOTICE TO BUYER OF LABOR DISPUTES Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer.

  • Statutory Notice Pursuant to section 119.0701(2)(a), F.S., for contracts for services with a contractor acting on behalf of a public agency, as defined in section 119.011(2), F.S., the following applies: IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA STATUTES, TO THE CONTRACTOR’S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT, CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT THE TELEPHONE NUMBER, EMAIL ADDRESS, AND MAILING ADDRESS PROVIDED IN THE RESULTING CONTRACT OR PURCHASE ORDER. Pursuant to section 119.0701(2)(b), F.S., for contracts for services with a contractor acting on behalf of a public agency as defined in section 119.011(2), F.S., the Contractor shall:

  • California Law This Agreement shall be subject to and construed in accordance with the laws of the State of California.

  • Resolution of Claims and Disputes 4.4.1 The Architect will review Claims and take one or more of the following preliminary actions within ten days of receipt of a Claim: (1) request additional supporting data from the claimant, (2) submit a schedule to the parties indicating when the Architect expects to take action, (3) reject the Claim in whole or in part, stating reasons for rejection, (4) recommend approval of the Claim by the other party or (5) suggest a compromise. The Architect may also, but is not obligated to, notify the surety, if any, of the nature and amount of the Claim.

  • Submission of a Claim to Arbitration 1. An investor that meets the conditions precedent in Article 22 (Conditions Precedent to Submission of a Claim to Arbitration) may submit a claim to arbitration under:

  • Resolution of Disputes Choice of Law (a) This Transition Agreement shall be construed and enforced in accordance with the laws of the State of California without regard to the principles of conflicts of law.

Time is Money Join Law Insider Premium to draft better contracts faster.