NOTICE TO BUYER OF LABOR DISPUTES Sample Clauses

NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
AutoNDA by SimpleDocs
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Purchase Order, Seller shall immediately give notice thereof, including all relevant information, with respect to Buyer. Seller agrees to insert the substance of this clause, including this paragraph in any subcontract hereunder as to which a labor dispute may delay the timely performance of this Purchase Order.
NOTICE TO BUYER OF LABOR DISPUTES. (1) Whenever an actual or potential labor dispute is delaying or threatening to delay the performance of this Agreement, Seller shall immediately give notice thereof to Buyer. Such notice shall include all relevant information with respect to such disputes.
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this PO, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
NOTICE TO BUYER OF LABOR DISPUTES. Except as otherwise prohibited by law, Seller shall immediately notify Buyer of any actual or potential labour dispute that may disrupt the timely performance of this contract or impair the quality of the Services to be delivered, whether Xxxxx has requested such status or not. When requested by Xxxxx, Seller will in a timely manner provide status on labour contracts and pending negotiations and prepare a contingency plan including incurred costs to address potential disruptions to the satisfaction of Buyer acting reasonably. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer.
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Supplier knows or, in the exercise of reasonable judgment, should know, that any actual or potential labor dispute is delaying or threatens to delay Supplier’s timely performance of the Purchase Order, Supplier shall immediately provide written notice and all relevant information relating thereto to Buyer. Supplier shall insert the substance of this Paragraph 17 in any subcontract as to which a labor dispute may delay the timely performance of the Purchase Order.
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this contract, Seller shall immediately give notice thereof, including all relevant information, with respect hereto to Buyer. Seller agrees to insert the substance of this clause in any subcontract hereunder as to which a labor dispute may delay the timely performance of this contract.
AutoNDA by SimpleDocs
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice, including all relevant information, to Buyer. GENERAL DYNAMICS LAND SYSTEMS 00-000-0000 (11/01/15)
NOTICE TO BUYER OF LABOR DISPUTES. Whenever Seller has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, Seller shall immediately give notice thereof, including all relevant information, to Buyer PACKING AND SHIPPING Seller shall pack the materials to prevent damage and deterioration. Unless otherwise set forth in this Contract, Seller shall package the goods in accordance with the requirements of Boeing Document D37522-6 “Supplier Packaging”. Buyer may charge Seller for damage to or deterioration of any goods resulting from improper packing or packaging. If the Contract specifies FOB destination (place of delivery), then in addition to any other shipping instructions, Seller shall forward materials freight prepaid. Seller shall make the transportation arrangements, pay the shipping costs, and remain responsible for the materials until the materials are delivered and the Buyer takes possession at the destination. If the Contract specifies FOB origin (place of shipment), then in addition to any other shipping instructions, Seller shall forward goods collect. For goods shipped within the United States, Seller shall make no declaration concerning the value of the goods shipped except on goods where the tariff rating is dependent upon released or declared value. In such event, Seller shall release or declare such value at the maximum value within the lowest rating. Seller will ship the goods in accordance with the provisions set forth in the Boeing Domestic Shipment Routing Guide to be accessed through Buyer’s supplier portal at xxxxx://xxxxxx.xxxxxxx.xxx/. Sellers need a One Time Password (OTP) token to log into the Boeing Supplier Portal. Upon Xxxxx’s request, Seller will identify packaging charges showing material and labor costs for container fabrication. Seller shall provide with each container shipped under this Contract an Advanced Shipping Notice (“ASN”). For each container shipped, Seller shall provide two (2) readable copies of the ASN barcode as follows: one (1) copy is to be securely affixed to the outside of each container and one (1) copy is to be loose inside each container. Non-conforming shipments are subject to rejection and repackaging at Seller’s expense. Instructions and guidelines related to the ASN process can be found on the Boeing Supplier Portal. Seller shall access by selecting the “Enterprise ASN Instructions” hyper-link under the header “Exostar Resources”. A copy of these instructions can...

Related to NOTICE TO BUYER OF LABOR DISPUTES

  • Labor Disputes No labor disturbance by or dispute with employees of the Company or any of its Subsidiaries exists or, to the knowledge of the Company, is threatened which would reasonably be expected to result in a Material Adverse Effect.

  • Corrective Action Plan Within fifteen (15) Business Days following the establishment of the Joint Remediation Committee, the Purchasers, in consultation with the Sellers, shall prepare and submit to the Joint Remediation Committee an initial draft of the Corrective Action Plan. The parties shall work in good faith through the Joint Remediation Committee to finalize the Corrective Action Plan within fifteen (15) Business Days of the Purchasers’ submission of the initial draft of the Correct Action Plan. At the end of such period, if the Sellers reasonably determine that the Corrective Action Plan proposed by the Purchasers (as may be modified over the course of such period) would not reasonably be expected to satisfactorily address the Major Default, then the Sellers may escalate the issue to the Head of Commercial Capital (or equivalent leader of any successor business unit) of the Seller Group and the Chief Executive Officer of the Bank Assets Purchaser (the “Senior Executives”) and the Senior Executives shall work collaboratively (including with the Joint Remediation Committee) to develop a mutually agreeable Corrective Action Plan within fifteen (15) Business Days.

  • Expedited Arbitration (a) The Parties may by mutual agreement refer to expedited arbitration any outstanding grievances considered suitable for this process, and shall set dates and locations for hearings of groups of grievances considered suitable for expedited arbitration.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!