Notification and Defense of Claims The Indemnitee agrees promptly to notify the Indemnitors in writing upon being served with any summons, citation, subpoena, complaint, indictment, information, or other document relating to any Proceeding or matter which may be subject to indemnification or advancement of Expenses covered hereunder, but the failure so to notify the Indemnitors will not relieve the Indemnitors from any liability that the Indemnitors may have to Indemnitee under this Agreement unless the Indemnitors are materially prejudiced thereby. With respect to any such Proceeding as to which Indemnitee notifies the Indemnitors of the commencement thereof:
(A) The Indemnitors will be entitled to participate therein at their own expense.
(B) Except as otherwise provided below, the Indemnitors will be entitled to assume the defense thereof, with counsel reasonably satisfactory to Indemnitee. After notice from the Indemnitors to Indemnitee of the Indemnitors’ election so to assume the defense thereof, the Indemnitors will not be liable to Indemnitee under this Agreement for any legal or other expenses subsequently incurred by Indemnitee in connection with the defense thereof other than reasonable costs of investigation or as otherwise provided below. Indemnitee shall have the right to employ Indemnitee’s own counsel in such Proceeding, but the fees and disbursements of such counsel incurred after notice from the Indemnitors of the Indemnitors’ assumption of the defense thereof shall be at the expense of Indemnitee unless (a) the employment by counsel by Indemnitee has been authorized by the Indemnitors, (b) the Indemnitee shall have reasonably concluded that there may be a conflict of interest between the Indemnitors and the Indemnitee in the conduct of the defense of such action, (c) such Proceeding seeks penalties or other relief against the Indemnitee with respect to which the Indemnitors could not provide monetary indemnification to the Indemnitee (such as injunctive relief or incarceration) or (d) the Indemnitors shall not in fact have employed counsel to assume the defense of such action, in each of which cases the fees and disbursements of counsel shall be at the expense of the Indemnitors. The Indemnitors shall not be entitled to assume the defense of any Proceeding brought by or on behalf of the Indemnitors, or as to which Indemnitee shall have reached the conclusion specified in clause (b) above, or which involves penalties or other relief against Indemnitee of the type referred to in clause (c) above.
(C) The Indemnitors shall not be liable to indemnify Indemnitee under this Agreement for any amounts paid in settlement of any action or claim effected without the Indemnitors’ written consent. The Indemnitors shall not settle any action or claim in any manner that would impose any penalty or limitation on Indemnitee without Indemnitee’s written consent. Neither the Indemnitors nor Indemnitee will unreasonably withhold or delay consent to any proposed settlement.
Notification and Defense of Claim Promptly after receipt by Indemnitee of notice of the commencement of any action, suit or proceeding, Indemnitee shall, if a claim in respect thereof is to be made against the Company under this Agreement, notify the Company of the commencement thereof; but the omission so to notify the Company shall not relieve it from any liability which it may have to Indemnitee. With respect to any such action, suit or proceeding as to which Indemnitee notifies the Company of the commencement thereof:
(a) the Company shall be entitled to participate therein at its own expense;
(b) except as otherwise provided below, to the extent that it may wish, the Company jointly with any other indemnifying party similarly notified shall be entitled to assume the defense thereof, with counsel reasonably satisfactory to Indemnitee. After notice from the Company to Indemnitee of its election so to assume the defense thereof, the Company shall not be liable to Indemnitee under this Agreement for any legal or other expenses subsequently incurred by Indemnitee in connection with the defense thereof other than reasonable costs of investigation or as otherwise provided below. Indemnitee shall have the right to employ his own chosen counsel in such action, suit or proceeding but the fees and expenses of such counsel incurred after notice from the Company of its assumption of the defense thereof shall be at the expense of Indemnitee, unless (i) the employment of such counsel by Indemnitee has been authorized by the Company, (ii) Indemnitee shall have reasonably concluded that there may be a conflict of interest between the Company and Indemnitee in the conduct of the defense of such action, suit or proceeding or (iii) the Company shall not in fact have employed its counsel to assume the defense of such action, in each of which cases the fees and expenses of Indemnitee’s counsel shall be at the expense of the Company. The Company shall not be entitled to assume the defense of any action, suit or proceeding brought by or on behalf of the Company or as to which Indemnitee shall have made the conclusion described in (ii) of this Section 7(b); and
(c) the Company shall not be liable to indemnify Indemnitee under this Agreement for any amounts paid in settlement of any action or claim effected without the Company’s written consent. The Company shall not settle any action or claim in any manner which would impose any penalty, equitable remedy or injunctive or other relief or limitation on Indemnitee without Indemnitee’s written consent. Neither the Company nor Indemnitee shall unreasonably withhold their consent to any proposed settlement.
Notification and Defense of Proceeding Promptly after receipt by the Indemnitee of notice of any Proceeding, the Indemnitee shall, if a request for indemnification or an advancement of Expenses in respect thereof is to be made against the Company under this Agreement, notify the Company in writing of the commencement thereof; but the omission so to notify the Company shall not relieve it from any liability that it may have to the Indemnitee. Notwithstanding any other provision of this Agreement, with respect to any such Proceeding of which the Indemnitee notifies the Company:
(a) The Company shall be entitled to participate therein at its own expense;
(b) Except as otherwise provided in this Section 15(b), to the extent that it may wish, the Company, jointly with any other indemnifying party similarly notified, shall be entitled to assume the defense thereof, with counsel satisfactory to the Indemnitee. After notice from the Company to the Indemnitee of its election so to assume the defense thereof, the Company shall not be liable to the Indemnitee under this Agreement for any expenses of counsel subsequently incurred by the Indemnitee in connection with the defense thereof except as otherwise provided below. The Indemnitee shall have the right to employ the Indemnitee’s own counsel in such Proceeding, but the fees and expenses of such counsel incurred after notice from the Company of its assumption of the defense thereof shall be at the expense of the Indemnitee unless (i) the employment of counsel by the Indemnitee has been authorized by the Company, (ii) the Indemnitee shall have reasonably concluded that there may be a conflict of interest between the Company and the Indemnitee in the conduct of the defense of such Proceeding, or (iii) the Company shall not within 60 calendar days of receipt of notice from the Indemnitee in fact have employed counsel to assume the defense of the Proceeding, in each of which cases the fees and expenses of the Indemnitee’s counsel shall be at the expense of the Company. The Company shall not be entitled to assume the defense of any Proceeding brought by or on behalf of the Company or as to which the Indemnitee shall have made the conclusion provided for in (ii) above; and
(c) Notwithstanding any other provision of this Agreement, the Company shall not be liable to indemnify the Indemnitee under this Agreement for any amounts paid in settlement of any Proceeding effected without the Company’s written consent, or for any judicial or other award, if the Company was not given an opportunity, in accordance with this Section 15, to participate in the defense of such Proceeding. The Company shall not settle any Proceeding in any manner that would impose any penalty or limitation on or disclosure obligation with respect to the Indemnitee, or that would directly or indirectly constitute or impose any admission or acknowledgment of fault or culpability with respect to the Indemnitee, without the Indemnitee’s written consent. Neither the Company nor the Indemnitee shall unreasonably withhold its consent to any proposed settlement.
Procedure for Notification and Defense of Claim (a) To obtain indemnification under this Agreement, Indemnitee shall submit to the Company a written request therefor specifying the basis for the claim, the amounts for which Indemnitee is seeking payment under this Agreement, and all documentation related thereto as reasonably requested by the Company.
(b) In the event that the Company shall be obligated hereunder to provide indemnification for or make any advancement of Expenses with respect to any Proceeding, the Company shall be entitled to assume the defense of such Proceeding, or any claim, issue or matter therein, with counsel approved by Indemnitee (which approval shall not be unreasonably withheld or delayed) upon the delivery to Indemnitee of written notice of the Company’s election to do so. After delivery of such notice, approval of such counsel by Indemnitee and the retention of such counsel by the Company, the Company will not be liable to Indemnitee under this Agreement for any fees or expenses of separate counsel subsequently employed by or on behalf of Indemnitee with respect to the same Proceeding; provided that (i) Indemnitee shall have the right to employ separate counsel in any such Proceeding at Indemnitee’s expense and (ii) if (A) the employment of separate counsel by Indemnitee has been previously authorized by the Company, (B) Indemnitee shall have reasonably concluded that there may be a conflict of interest between the Company and Indemnitee in the conduct of such defense, or (C) the Company shall not continue to retain such counsel to defend such Proceeding, then the fees and expenses actually and reasonably incurred by Indemnitee with respect to his or her separate counsel shall be Expenses hereunder.
(c) In the event that the Company does not assume the defense in a Proceeding pursuant to paragraph (b) above, then the Company will be entitled to participate in the Proceeding at its own expense.
(d) The Company shall not be liable to indemnify Indemnitee under this Agreement for any amounts paid in settlement of any Proceeding effected without its prior written consent (which consent shall not be unreasonably withheld or delayed). The Company shall not, without the prior written consent of Indemnitee (which consent shall not be unreasonably withheld or delayed), enter into any settlement which (i) includes an admission of fault of Indemnitee, any non-monetary remedy imposed on Indemnitee or any monetary damages for which Indemnitee is not wholly and actually indemnified hereunder or (ii) with respect to any Proceeding with respect to which Indemnitee may be or is made a party or may be otherwise entitled to seek indemnification hereunder, does not include the full release of Indemnitee from all liability in respect of such Proceeding.
Procedures for Notification and Defense of Claim (a) Indemnitee shall notify the Company in writing of any matter with respect to which Indemnitee intends to seek indemnification or advancement of Expenses as soon as reasonably practicable following the receipt by Indemnitee of notice thereof. The written notification to the Company shall include, in reasonable detail, a description of the nature of the Proceeding and the facts underlying the Proceeding. The failure by Indemnitee to notify the Company will not relieve the Company from any liability which it may have to Indemnitee hereunder or otherwise than under this Agreement, and any delay in so notifying the Company shall not constitute a waiver by Indemnitee of any rights, except to the extent that such failure or delay materially prejudices the Company.
(b) If, at the time of the receipt of a notice of a Proceeding pursuant to the terms hereof, the Company has directors’ and officers’ liability insurance in effect that may be applicable to the Proceeding, the Company shall give prompt notice of the commencement of the Proceeding to the insurers in accordance with the procedures set forth in the applicable policies. The Company shall thereafter take all commercially-reasonable action to cause such insurers to pay, on behalf of Indemnitee, all amounts payable as a result of such Proceeding in accordance with the terms of such policies.
(c) In the event the Company may be obligated to make any indemnity in connection with a Proceeding, the Company shall be entitled to assume the defense of such Proceeding with counsel approved by Indemnitee, which approval shall not be unreasonably withheld, conditioned or delayed, upon the delivery to Indemnitee of written notice of its election to do so. After delivery of such notice, approval of such counsel by Indemnitee and the retention of such counsel by the Company, the Company will not be liable to Indemnitee for any fees or expenses of counsel subsequently incurred by Indemnitee with respect to the same Proceeding. Notwithstanding the Company’s assumption of the defense of any such Proceeding, the Company shall be obligated to pay the fees and expenses of Indemnitee’s separate counsel to the extent (i) the employment of separate counsel by Indemnitee is authorized by the Company, (ii) counsel for the Company or Indemnitee shall have reasonably concluded that there is a conflict of interest between the Company and Indemnitee in the conduct of any such defense such that Indemnitee needs to be separately represented, (iii) the Company is not financially or legally able to perform its indemnification obligations or (iv) the Company shall not have retained, or shall not continue to retain, counsel to defend such Proceeding. The Company shall have the right to conduct such defense as it sees fit in its sole discretion. Regardless of any provision in this Agreement, Indemnitee shall have the right to employ counsel in any Proceeding at Indemnitee’s personal expense. The Company shall not be entitled, without the consent of Indemnitee, to assume the defense of any claim brought by or in the right of the Company.
(d) Indemnitee shall give the Company such information and cooperation in connection with the Proceeding as may be reasonably appropriate.
(e) The Company shall not be liable to indemnify Indemnitee for any settlement of any Proceeding (or any part thereof) without the Company’s prior written consent, which shall not be unreasonably withheld, conditioned or delayed.
(f) The Company shall not settle any Proceeding (or any part thereof) in a manner that imposes any penalty or liability on Indemnitee without Indemnitee’s prior written consent, which shall not be unreasonably withheld, conditioned or delayed.
Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
16.2 To the furthest extent permitted by California law, Developer shall also defend Indemnitees, at its own expense, including but not limited to attorneys’ fees and costs, against all Claims caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Facilities Lease by Developer, its Subcontractors, vendors, or suppliers. However, without impacting Developer’s obligation to provide an immediate and ongoing defense of Indemnitees, Developer’s defense obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent caused by the sole negligence, active negligence, or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. The District shall have the right to accept or reject any legal representation that Xxxxxxxxx proposes to defend the Indemnitees. If any Indemnitee provides its own defense due to failure to timely respond to tender of defense, rejection of tender of defense, or conflict of interest of proposed counsel, Developer shall reimburse such Indemnitee for any expenditures. Developer’s defense obligation shall not be construed to negate, abridge, or otherwise reduce any right or obligation of defense that would otherwise exist as to any Indemnitee or other person described herein. Developer’s defense obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any provision of law, any failure or alleged failure to timely and properly fulfill all of its obligations under the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developer’s obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR. Developer shall give prompt notice to the District in the event of any Claim(s).
16.3 Without limitation of the provisions herein, if Xxxxxxxxx’s obligation to indemnify and hold harmless the Indemnitees or its obligation to defend Indemnitees as provided herein shall be determined to be void or unenforceable, in whole or in part, it is the intention of the Parties that these circumstances shall not otherwise affect the validity or enforceability of Developer’s agreement to indemnify, defend, and hold harmless the rest of the Indemnitees, as provided herein. Further, Developer shall be and remain fully liable on its agreements and obligations herein to the fullest extent permitted by law.
Enforcement and Defense (a) Each Party shall promptly notify the other of any knowledge it acquires of any potential infringement of the Collaboration Patents by a Third Party.
(b) If any Patent within the Collaboration Patents is infringed by a Third Party in any country in the Territory in connection with the manufacture, use and sale of a product the same as or substantially similar to a Product in the Field in such country, TESARO shall have the primary right, but not the obligation, to institute, prosecute, and control any action or proceeding with respect to such infringement of such Patent, by counsel of its own choice, and AnaptysBio shall have the right, at its own expense, to be represented in that action by counsel of its own choice. If TESARO fails to bring an action or proceeding within a period of one hundred twenty (120) days after a request by AnaptysBio to do so, AnaptysBio shall have the right to bring and control any such action by counsel of its own choice, and TESARO shall have the right to be represented in any such action by counsel of its own choice at its own expense.
(c) If one Party brings an action or proceeding in accordance with Section 9.3(b), the second Party agrees to be joined as a party plaintiff if necessary and to give the first Party reasonable assistance and authority to file and prosecute the suit. The costs and expenses of the Party bringing suit under this Section shall be borne by such Party, and any damages or other monetary awards recovered shall be shared as follows: The amount of such recovery actually received by the Party controlling such action shall first be applied to the out-of- pocket costs of such action, and then (i) if TESARO is the Party that brings such action or proceeding, then AnaptysBio shall be paid an amount equal to the royalties, if any, that would have been due upon sales of the infringing product as if such infringing sales had been Net Sales of a Product sold by or under the authority of TESARO, and the remaining portion of such recovery shall be paid to TESARO, or (ii) if AnaptysBio is the Party that brings such action or proceeding, then the remaining portion of such recovery shall be retained by AnaptysBio. A settlement or consent judgment or other voluntary final disposition of a suit under this Section 9.3 may be entered into without the consent of the Party not bringing the suit. Neither Party shall, however, have the right to enter into any settlement or consent to any claim to the effect that the patent protection offered under any part of the Collaboration Patents would be materially negatively affected, without the consent of the other Party, such consent not to be unreasonably withheld.
Notice and Defense of Claims As soon as reasonably practicable after receipt by the Indemnified Party of notice of any liability or claim incurred by or asserted against the Indemnified Party that is subject to indemnification under this Article III, the Indemnified Party shall give notice thereof to Contributor, including liabilities or claims to be applied against the indemnification deductible established pursuant to Section 3.4 hereof; provided that failure to give notice to Contributor will not relieve Contributor from any liability that it may have to any Indemnified Party, unless, and only to the extent that, such failure (a) shall have caused prejudice to the defense of such claim or (b) shall have materially increased the costs or potential liability of Contributor by reason of the inability or failure of Contributor (due to such lack of prompt notice) to be involved in any investigations or negotiations regarding any such claim. Such notice shall describe in reasonable detail the facts known to such Indemnified Party giving rise to such claim, and the amount or good faith estimate of the amount of Losses arising therefrom. Unless prohibited by law, such Indemnified Party shall deliver to Contributor, promptly after such Indemnified Party’s receipt thereof, copies of all notices and documents received by such Indemnified Party relating to such claim. The Indemnified Party shall permit Contributor, at Contributor’s option and expense, to assume the defense of any such claim by counsel selected by Contributor and reasonably satisfactory to the Indemnified Party, and to settle or otherwise dispose of the same; provided, however, that the Indemnified Party may at all times participate in such defense at its sole expense; and provided further, however, that Contributor shall not, in defense of any such claim, except with the prior written consent of the Indemnified Party in its sole and absolute discretion, consent to the entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff in question to all Indemnified Parties a full and complete release of all liabilities in respect of such claims, or that does not result only in the payment of money damages which are paid (or deemed paid) in full by Contributor. If Contributor shall not have undertaken such defense within 20 days after such notice, or within such shorter time as may be reasonable under the circumstances to the extent required by applicable law, then the Indemnified Party shall have the right to undertake the defense, compromise or settlement of such liability or claim on behalf of and for the account of Contributor and at Contributor’s sole cost and expense (subject to the limitations in Section 3.4 hereof).
Notice and Defense of Third Party Claims Promptly following the earlier of (a) receipt of notice of the commencement by a third party of any Action against or otherwise involving any Indemnified Party or (b) receipt of information from a third party alleging the existence of a claim against an Indemnified Party, in either case, with respect to which indemnification may be sought pursuant to this Agreement (a “Third Party Claim”), the Indemnified Party shall give the Indemnifying Party written notice thereof. The failure of the Indemnified Party to give notice as provided in this Section 6.07 shall not relieve the Indemnifying Party of its obligations under this Agreement, except to the extent that the Indemnifying Party is materially prejudiced by such failure to give notice. Within thirty (30) days after receipt of such notice, the Indemnifying Party shall, by giving written notice thereof to the Indemnified Party, (a) acknowledge, as between the parties hereto, liability for, and at its option elect to assume the defense of such Third Party Claim at its sole cost and expense or (b) object to the claim of indemnification set forth in the notice delivered by the Indemnified Party pursuant to the first sentence of this Section 6.07 setting forth the grounds therefor; provided that if the Indemnifying Party does not within the same thirty (30) day period give the Indemnified Party written notice acknowledging liability or objecting to such claim and setting forth the grounds therefor, the Indemnifying Party shall be deemed to have acknowledged, as between the parties hereto, its liability to the Indemnified Party for such Third Party Claim. Any contest of a Third Party Claim as to which the Indemnifying Party has elected to assume the defense shall be conducted by attorneys employed by the Indemnifying Party and reasonably satisfactory to the Indemnified Party; provided that the Indemnified Party shall have the right to participate in such proceedings and to be represented by attorneys of its own choosing at the Indemnified Party’s sole cost and expense. If the Indemnifying Party assumes the defense of a Third Party Claim, the Indemnifying Party may settle or compromise the claim without the prior written consent of the Indemnified Party if such settlement or compromise is solely for monetary damages for which the Indemnifying Party shall be responsible for; in all other events, the Indemnifying Party may not agree to any settlement or compromise without the prior written consent of the Indemnified Party, which consent shall not be unreasonably withheld or delayed. If the Indemnifying Party does not assume the defense of a Third Party Claim for which it has acknowledged liability for indemnification under Article VI, the Indemnified Party may require the Indemnifying Party to reimburse it on a current basis for its reasonable expenses of investigation, reasonable attorney’s fees and reasonable out-of-pocket expenses incurred in defending against such Third Party Claim, and the Indemnifying Party shall be bound by the result obtained with respect thereto by the Indemnified Party; provided that the Indemnifying Party shall not be liable for any settlement effected without its consent, which consent shall not be unreasonably withheld or delayed. The Indemnifying Party shall pay to the Indemnified Party in cash the amount for which the Indemnified Party is entitled to be indemnified (if any) within 15 days after the final resolution of such Third Party Claim (whether by the final nonappealable judgment of a court of competent jurisdiction or otherwise), or, in the case of any Third Party Claim as to which the Indemnifying Party has not acknowledged liability, within 15 days after such Indemnifying Party’s objection has been resolved by settlement, compromise or the final nonappealable judgment of a court of competent jurisdiction.
Restoration of Rights on Abandonment of Proceedings In case the Trustee shall have proceeded to enforce any right under this Indenture and such proceedings shall have been discontinued or abandoned for any reason, or shall have been determined adversely to the Trustee, then and in every such case the Issuer and the Trustee shall be restored respectively to their former positions and rights hereunder, and all rights, remedies and powers of the Issuer, the Trustee and the Securityholders shall continue as though no such proceedings had been taken.
