Objections To Subcontractors Sample Clauses

Objections To Subcontractors. Upon execution of this Agreement, and at such later times as may be applicable, Design/Builder shall furnish Owner, in writing, the names of persons or entities proposed by Design/Builder to act as Subcontractors on the Project. Design/Builder shall provide such information regarding such proposed Subcontractors as Owner deems necessary. Owner shall promptly reply to Design/Builder, in writing, stating any objections Owner may have to such proposed Subcontractors. Design/Builder shall not enter into a subcontract with an intended Subcontractor with reference to whom Owner objects. Any consent or failure to reject by Owner shall in no way relieve Design/Builder of any of its duties or warranties under the Contract.
Sample 1Sample 2Sample 3See All (6)
AutoNDA by SimpleDocs
Objections To Subcontractors. Upon execution of this Agreement, and at such later times as may be applicable, Design/Builder shall furnish Owner, in writing, the names of persons or entities proposed by Design/Builder to act as Subcontractors on the Project. Design/Builder shall provide such information regarding such proposed Subcontractors as Owner deems necessary. Owner shall promptly reply to Design/Builder, in writing, stating any objections Owner may have to such proposed Subcontractors. Design/Builder shall not enter into a subcontract with an intended Subcontractor with reference to whom Owner objects. In the event Owner objects to such proposed Subcontractor, Design/Builder shall be entitled to the additional costs and time in retaining a Subcontractor acceptable to the Owner. Any consent or failure to reject by Owner shall in no way relieve Design/Builder of any of its duties or warranties under the Contract.
Sample 1Sample 2
Objections To Subcontractors. Upon execution of this Agreement, and at such later times as may be applicable, Contractor shall furnish AFI, in writing, the names of persons or entities proposed by Contractor to act as Subcontractors on the Project. Contractor shall provide such information regarding such proposed Subcontractors as AFI deems necessary. AFI shall promptly reply to Contractor, in writing, stating any objections AFI may have to such proposed Subcontractors. Contractor shall not enter into a subcontract with an intended Subcontractor with reference to whom AFI objects. Any consent or failure to reject by AFI shall in no way relieve Contractor of any of its duties or warranties under the Contract. Removal Of Subcontractors And Personnel: If, at any time during the course of the Project, AFI reasonably determines that the performance of any Subcontractor or any member of Contractor's contruction staff working on the Project is unsatisfactory, AFI's Representative may require Contractor to remove such Subcontractor or staff member from the Project immediately and replace the staff member at no cost or penalty to AFI for delays or inefficiencies the change may cause.
Sample 1

Related to Objections To Subcontractors

  • Payment to Subcontractors (If applicable) As required by Minnesota Statute § 16A.1245, the prime Contractor must pay all subContractors, less any retainage, within 10 calendar days of the prime Contractor’s receipt of payment from the State for undisputed services provided by the subContractor(s) and must pay interest at the rate of one and one-half percent per month or any part of a month to the subContractor(s) on any undisputed amount not paid on time to the subContractor(s).

  • To Subcontractor(s) a. Within seven (7) days of the Contractor’s receipt of payment from the County for the proportionate share of the payment received for work performed by the subcontractor(s) under the contract a Contractor awarded a contract under this solicitation is hereby obligated:

  • Payments to Subcontractors Develop and implement a procedure for the review, processing and payment of applications by subcontractors for progress and final payments.

  • APPLICABILITY TO SUBCONTRACTORS Respondent agrees that all contracts it awards pursuant to the contract awarded as a result of this Agreement will be bound by the foregoing terms and conditions.

  • Prompt Payment to Subcontractors (a) Within 7 days of receipt by the Contractor of each payment from the City under this contract, the Contractor shall pay all Subcontractors (which term includes subconsultants and suppliers) based on work completed or service provided under the subcontract. Should any payment to the Subcontractor be delayed by more than 7 days after receipt of payment by the Contractor from the City under this contract, the Contractor shall pay the Subcontractor interest, beginning on the 8th day, at the rate of 1% per month or fraction thereof on such unpaid balance as may be due. By appropriate litigation, Subcontractors shall have the right to enforce this subsection (a) directly against the Contractor, but not against the City of Durham.

  • PAYMENT TO SUB-CONTRACTORS 12.1 Transnet reserves the right, in its sole discretion, to make payment directly to the sub-contractor of the Supplier/Service Provider, subject to the following conditions:

  • Objections to New Subprocessors (a) If Customer has a legitimate reason under Data Protection Law to object to the new Subprocessors’ processing of Personal Data, Customer may terminate the Agreement (limited to the Cloud Service for which the new Subprocessor is intended to be used) on written notice to SAP. Such termination shall take effect at the time determined by the Customer which shall be no later than thirty days from the date of SAP’s notice to Customer informing Customer of the new Subprocessor. If Customer does not terminate within this thirty day period, Customer is deemed to have accepted the new Subprocessor.

  • Right to Subcontract The Carrier at its discretion may subcontract on any terms the whole or any part of the Carriage.

  • Technical Objections to Grievances It is the intent of both Parties of this Agreement that no grievance shall be defeated merely because of a technical error, other than time limitations in processing the grievance through the grievance procedure. To this end, an arbitration board shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance, in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.

  • Indemnification by Subcontractors To the fullest extent permitted by law, an Interconnection Party that uses a subcontractor to carry out any of the Interconnection Party’s obligations under this Appendix 2 shall require each of its subcontractors to indemnify, hold harmless and defend each other Interconnection Party, its representatives and assigns from and against any and all claims and/or liability for damage to property, injury to or death of any person, including the employees of any Interconnection Party or of any Affiliate of any Interconnection Party, or any other liability incurred by the other Interconnection Party or any of its Affiliates, including all expenses, legal or otherwise, to the extent caused by any act or omission, negligent or otherwise, by such subcontractor and/or its officers, directors, employees, agents and assigns, that arises out of or is connected with the operation of the facilities of either Interconnected Entity described in this Appendix 2; provided, however, that no Interconnection Party or Affiliate thereof shall be entitled to indemnity under this Section 18.3 in respect of any injury, loss, or damage to the extent that such loss, injury, or damage results from the negligence or willful misconduct of the Interconnection Party or Affiliate seeking indemnity.

Time is Money Join Law Insider Premium to draft better contracts faster.