Upon completion of the Project the Recipient shall make a full and complete accounting to the OPWC of the Eligible Project Cost.
Condition of the Property THE LESSEE ACKNOWLEDGES AND AGREES THAT IT IS LEASING THE PROPERTY "AS IS" WITHOUT REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) BY THE LESSOR AND SUBJECT TO (A) THE EXISTING STATE OF TITLE, (B) THE RIGHTS OF ANY PARTIES IN POSSESSION THEREOF, (C) ANY STATE OF FACTS WHICH AN ACCURATE SURVEY OR PHYSICAL INSPECTION MIGHT SHOW, AND (D) VIOLATIONS OF REQUIREMENTS OF LAW WHICH MAY EXIST ON THE DATE HEREOF OR ON THE ACQUISITION DATE. THE LESSOR HAS NOT MADE AND SHALL NOT BE DEEMED TO HAVE MADE ANY REPRESENTATION, WARRANTY OR COVENANT (EXPRESS OR IMPLIED) AND SHALL NOT BE DEEMED TO HAVE ANY LIABILITY WHATSOEVER AS TO THE TITLE (OTHER THAN FOR LESSOR LIENS), VALUE, HABITABILITY, USE, CONDITION, DESIGN, OPERATION, OR FITNESS FOR USE OF THE PROPERTY (OR ANY PART THEREOF), OR ANY OTHER REPRESENTATION, WARRANTY OR COVENANT WHATSOEVER, EXPRESS OR IMPLIED, WITH RESPECT TO THE PROPERTY (OR ANY PART THEREOF) AND THE LESSOR SHALL NOT BE LIABLE FOR ANY LATENT, HIDDEN, OR PATENT DEFECT THEREIN (OTHER THAN FOR LESSOR LIENS) OR THE FAILURE OF THE PROPERTY, OR ANY PART THEREOF, TO COMPLY WITH ANY REQUIREMENT OF LAW.
Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Modification of the Small Generating Facility The Interconnection Customer must receive written authorization from the NYISO and Connecting Transmission Owner before making any change to the Small Generating Facility that may have a material impact on the safety or reliability of the New York State Transmission System or the Distribution System. Such authorization shall not be unreasonably withheld. Modifications shall be done in accordance with Good Utility Practice. If the Interconnection Customer makes such modification without the prior written authorization of the NYISO and Connecting Transmission Owner, the Connecting Transmission Owner shall have the right to temporarily disconnect the Small Generating Facility. If disconnected, the Small Generating Facility will not be reconnected until the unauthorized modifications are authorized or removed.
Execution of the Project (a) The Recipient declares its commitment to the objectives of the Project as set forth in Schedule 2 to this Agreement, and, to this end, shall carry out the Project through its MoE with due diligence and efficiency and in conformity with appropriate financial, economic, environmental and administrative practices, and shall provide, promptly as needed, the funds, facilities, services and other resources required for the Project.
(b) Without limitation upon the provisions of paragraph (a) of this Section and except as the Recipient and the Association shall otherwise agree, the Recipient shall carry out the Project in accordance with the Implementation Program set forth in Schedule 4 to this Agreement.
(a) Except as the Association shall otherwise agree, procurement of the goods, works and consultants’ services required for the Project and to be financed out of the proceeds of the Grant shall be governed by the provisions of Schedule 3 to this Agreement, as said provisions may be further elaborated in the Procurement Plan.
(b) The Recipient shall update the Procurement Plan in accordance with terms of reference acceptable to the Association, and furnish such update to the Association not later than twelve (12) months after the date of the preceding Procurement Plan, for the Association’s approval.
Section 3.03. Without limitation upon any of its obligations under paragraph (a) of Section 3.01 of this Agreement and except as the Recipient and the Association shall otherwise agree, the Recipient shall: (i) not later than by the effectiveness of this Agreement open a separate project account (the Project Account) in a commercial bank acceptable to the Association; (ii) thereafter maintain the Project Account during the entire Project implementation period, and replenish said Account regularly with funds sufficient to ensure the Recipient’s Project co-financing obligations; and (iii) use the amount in the Project Account exclusively for financing the Recipient’s contribution to Project expenditures.
Section 3.04. For the purposes of Section 6.09 of the General Conditions and without limitation thereto, the Recipient shall:
(a) prepare, on the basis of guidelines acceptable to the Association, and furnish to the Association not later than six (6) months after the Closing Date or such later date as may be agreed for this purpose between the Recipient and the Association, a plan designed to ensure the continued achievement of the Project’s objectives; and
(b) afford the Association a reasonable opportunity to exchange views with the Recipient on said plan.
COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project
(a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020.
(b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control.
(c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. Does Vendor agree? Yes, Vendor agrees Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body.
Cooperation of the Parties The Seller undertakes to notify the Buyer of any obstacles on his part, which may negatively influence proper and timely delivery of the Equipment.
Possession of the Property The Parties hereby agree that the exclusive possession of the Property shall be delivered by the Seller to the Buyer on
Construction of the Agreement The Agreement sets forth the entire understanding between two sophisticated business entities with legal counsel as to its subject and supersedes all prior agreements, conditions, warranties, representations, arrangements and communications, including purchase orders issued by Client, whether oral or written, and whether with or by Accenture, any of its affiliates, or any of their employees, officers, directors, agents or shareholders. Each party acknowledges that it entered into the Agreement solely based on the agreements and representations contained herein, and has not relied upon any representations, warranties, promises, or inducements of any kind, whether oral or written, and from any source. If a court of competent jurisdiction finds any term of the Agreement to be invalid, illegal or otherwise unenforceable, such term or provision will not affect the other terms of this Agreement and will be deemed modified to the extent necessary, in the court’s opinion, to render such term enforceable while preserving to the fullest extent permissible the intent and agreements of the parties set forth in this Agreement. No waiver or modification of any provision of the Agreement will be effective unless it is in writing and signed by the party against which it is sought to be enforced. The delay or failure by either party to exercise or enforce any of its rights under this Agreement is not a waiver of that party’s right to later enforce those rights, nor will any single or partial exercise of any such right preclude any other or further exercise of these rights or any other right. There are no third-party beneficiaries to the Agreement. In the event of a conflict between these GTC and an Order Form, the Order Form controls for purposes of that Order Form only.
