Obligations of the Concessionaire 5.1.1 Subject to and on the terms and conditions of this Agreement, the Concessionaire shall, at its own cost and expense, procure finance for and undertake the design, engineering, procurement, construction, operation and maintenance of the Project and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
5.1.2 The Concessionaire shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
5.1.3 Subject to the provisions of Clauses 5.1.1 and 5.1.2, the Concessionaire shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
5.1.4 The Concessionaire shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement carry out the following but not be limited to:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits (other than those set forth in Clause 4.1.3), and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for materials, methods, processes and systems used or incorporated into the Project;
(c) perform and fulfil its obligations under the Financing Agreements;
(d) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed by it or its Contractors in connection with the performance of its obligations under this Agreement;
(e) make reasonable efforts to facilitate the acquisition of land required for the purposes of the Agreement;
(f) ensure and procure that its Contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Concessionaire's obligations under this Agreement;
(g) not do or omit to do any act, deed or thing which may in any manner be violative of any of the provisions of this Agreement;
(h) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(i) modify/demolish the existing structures on the Site at its own cost and consequences. The Concessionaire shall ensure that the demolition and construction of the existing structures is also in compliance with the prevailing building bye laws, zoning regulations as prescribed by H&UPD, GoUP, other appropriate authority or any regulatory authority (ASI, TTZ, NGT etc.). XXX policy of GoI and GoUP shall be admissible as and where applicable. The Concessionaire shall be responsible for safe and hassle-free disposal of the scrap from the Site;
(j) (deleted)
(k) transfer the Bus Terminal and the Commercial Complex to the Authority upon Termination of this Agreement, in accordance with the provisions thereof.
(l) develop a centralized covered Bus Terminal with adequate number of bus bays along with RCC yard area, passenger movement spaces, furniture fixtures, electrical fittings, utilities and other related requirements;
(m) {where Bus Terminal and workshops/ depots are adjoining, the development of workshops unit with necessary structural provisions and RCC yard, furniture fixtures, electrical fittings with minimum 6 meters of working/ maintenance shed height with no access from and/ to commercial areas as a mandatory requirement. However, Authority shall take separate electricity connection for the workshop area and shall pay for the electricity usage in it}1;
(n) construct and maintain public amenities like ablution units etc.;
(o) all the passenger amenities, Workshop facilities as well as UPSRTC staff facilities shall be maintained hygienic, neat and clean during the concession period;
(p) accesses either through staircases, overbridges or underpasses for movement of pedestrians from one platform to the other in a safe and fully secured manner;
(q) a dedicated office for UPSRTC staff with a sufficient usable area along with change rooms and toilets as per the specifications of UPSRTC shall be made available unconditionally and free of cost for the entire concession period on ground and first floors only of the Bus Terminal;
(r) all the facilities for plumbing, internal electrification and all the other allied works to render the office functional (partitions excluded);
(s) facility for parking adequate number of 4 wheelers, 3 Wheelers and 2 wheelers of passengers and commercial area users. The parking facility for Bus Terminal and for the Commercial Complex shall be segregated. (Refer prevailing Government of Housing and Urban Planning department circulars/ G.O’s); 1 This provision to be used only for Sites where workshops are adjoining the Bus Terminal
(t) all the other allied facilities for fire protection, accesses in the form of ramps, protective railings, ventilation system etc.;
(u) day to day operation and management of the Project as per this Agreement; and
(v) bear the expenses of electricity and water in the Bus Terminal during the Concession Period of Bus Terminal, except electricity and water charges for Authority’s office, workshop, drivers or staff dormitory and electric bus charging which shall be borne by the Authority.
Sole purpose of the Concessionaire The Concessionaire having been set up for the sole purpose of exercising the rights and observing and performing its obligations and liabilities under this Agreement, the Concessionaire or any of its subsidiaries shall not, except with the previous written consent of the Authority, be or become directly or indirectly engaged, concerned or interested in any business other than as envisaged herein.
Obligations of the Contractor (i) Subject to and on the terms and conditions of this Agreement, the Contractor shall undertake the survey, investigation, design, engineering, procurement, construction, and maintenance of the Project Highway and observe, fulfil, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Contractor shall comply with all Applicable Laws and Applicable Permits (including renewals as required) in the performance of its obligations under this Agreement.
(iii) Subject to the provisions of Clauses 4.1 (i) and 4.1 (ii), the Contractor shall discharge its obligations in accordance with Good Industry Practice and as a reasonable and prudent person.
(iv) The Contractor shall remedy any and all loss, defects, or damage to the Project Highway from the Appointed Date until the end of the Construction Period at the Contractor’s cost, save and except to the extent that any such loss, defect, or damage shall have arisen from any wilful default or neglect of the Authority.
(v) The Contractor shall remedy any and all loss, defect or damage to the Project Highway during the Defects Liability Period at the Contractor’s cost to the extent that such loss, defect or damage shall have arisen out of the reasons specified in Clause 17.3.
(vi) The Contractor shall remedy any and all loss or damage to the Project Highway during the Maintenance Period at the Contractor’s cost, including those stated in Clause 14.1 (ii), save and except to the extent that any such loss or damage shall have arisen on account of any wilful default or neglect of the Authority or on account of a Force Majeure Event.
(vii) The Contractor shall, at its own cost and expense, in addition to and not in derogation of its obligations elsewhere set out in this Agreement:
(a) make, or cause to be made, necessary applications to the relevant Government Instrumentalities with such particulars and details as may be required for obtaining Applicable Permits set forth in Schedule-F and obtain and keep in force and effect such Applicable Permits in conformity with the Applicable Laws;
(b) procure, as required, the appropriate proprietary rights, licences, agreements and permissions for Materials, methods, processes and systems used or incorporated into the Project Highway;
(c) make reasonable efforts to maintain harmony and good industrial relations among the personnel employed byit or its Sub-contractors in connection with the performance of its obligations under this Agreement;
(d) ensure and procure that its Sub-contractors comply with all Applicable Permits and Applicable Laws in the performance by them of any of the Contractor’s obligations under this Agreement;
(e) not do or omit to do any act, deed or thing which may in any manner violate any provisions of this Agreement;
(f) support, cooperate with and facilitate the Authority in the implementation and operation of the Project in accordance with the provisions of this Agreement;
(g) ensure that the Contractor and its Sub-contractors comply with the safety and welfare measures for labour in accordance with the Applicable Laws and Good Industry Practice;
(h) keep, on Site, a copy of this Agreement, publications named in this Agreement, the Drawings, Documents relating to the Project, and Change of Scope orders and other communications given under this Agreement. The Authority’s Engineer and its authorised personnel shall have the right of access to all these documents at all reasonable times;
(i) cooperate with other contractors employed by the Authority and personnel of any public authority; and
(j) not interfere unnecessarily or improperly with the convenience of the public, or the access to and use and occupation of all roads and footpaths, irrespective of whether they are public or in the possession of the Authority or of others.
(viii) The Contractor shall undertake all necessary superintendence to plan, arrange, direct, manage, inspect and test the Works. The Contractor shall provide all necessary superintendence of the Works for the proper fulfilling of the Contractor's obligations under the Agreement. Such superintendence shall be given by competent person having adequate knowledge of the operations to be carried out (including the methods and techniques required, the hazards likely to be encountered and methods of preventing accidents) for the satisfactory and safe execution of the Works.
(ix) The Contractor shall obtain and maintain a project related bank account operational at site where all transactions related to the payment of work will be done. The Contractor shall submit a monthly account statement and a detailed report on utilization of funds transferred to this project related bank account to Authority’s Engineer. Notwithstanding anything contrary to this agreement, the authority, in the interest and to ensure timely completion of the work, reserves the right to audit such bank accounts to ensure that there is no diversion of funds from this project specific account to any other project being implemented by the Contractor.
(x) The Contractor shall provide the documents of the Contractor specified in the Agreement, and all Contractors' personnel; Goods, consumables and other things and services, whether of a temporary or permanent nature, required in and for the execution, completion of Works and remedying defects.
(xi) The Contractor shall perform the Works in conformity with the Project requirements and other requirements and standards prescribed under or pursuant to the Agreement.
(xii) The Contractor shall carry out such work incidental and contingent to the original Scope of the Project to comply with Good Industry Practices.
(xiii) The Contractor shall maintain required staff and necessary Contractor’s equipment and materials within the reach of the Site during the Defects Liability Period so that any defects arising are promptly attended.
Obligations of the Customer 3.1 The Customer agrees to:
(a) The Customer shall give the Company not less than 14 days prior written notice of any proposed change of ownership of the Customer and or any change in the Customer’s details (including but not limited to, changes in the customer’s name, address, contact phone/fax numbers or business practice). The Customer shall be liable for any loss incurred by the Company as a result of the Customers failure to comply with this clause.
(b) Pay the Company the Price for carrying out the Works in accordance with this agreement;
(c) Provide the Company with all necessary plans, specifications, services and amenities, so as to allow the Company to carry out the Works, provide access to the Location and ensure to the Company’s reasonable satisfaction that the Location remains in a state and condition that is safe for the Company and its employees and agents;
(d) Ensure the Location complies with all necessary bylaws and restrictions is structurally sound (in accordance with all legislation governing safety in the workplace);
(e) Not to cause any disruption or obstruction to the carrying out of any Works and to follow any reasonable instructions provided by the Company about the Works;
(f) Where the Works requires co-ordination with other trades then the Customer will supply the Company with a schedule detailing all relevant information so as to allow the Company sufficient time to co-ordinate with the Customer’s other tradespersons;
(g) Permit the Company to attach such reasonable signage as the Company may wish to any Works so as to identify that the Company is carrying out the Works;
(h) In circumstances where it wishes to make a claim against the Company pursuant to the guarantee given in clause 13.2, exclusively permit the Company or its authorised representative to remedy or make good any defects in its Workmanship and not permit any other third party to do so.
3.2 Without prejudice to any other right or remedy of the Company, if the Customer fails to carry out or perform any of its obligations pursuant to this clause 3 (excepting clause 3.1(g)) then, in addition to any Additional Expenses Charge that may apply, the Company may charge the Customer a Services Delay Charge for each day (or part thereof) that the Company is, in its reasonable opinion, unable and/or not required to carry out or perform the Works as a result of such breach by the Customer.
3.3 Where the Customer requests any Related Work to be carried out, the Company will use its best endeavours to source suppliers and/or contractors to carry out the Related Work, but the Customer is responsible for the commissioning, controlling, and payment for such work.
3.4 The Customer acknowledges that unless otherwise agreed in writing between the Customer and the Company, the Customer shall be responsible for obtaining, paying for and maintaining in force all permits, approvals, authorisations, authorities, licences and consents of all regulatory authorities whatsoever which are or may be necessary or advisable in connection with the Works.
Obligations Independent The obligations of each Guarantor hereunder are those of primary obligor, and not merely as surety, and are independent of the Secured Obligations and the obligations of any other guarantor, and a separate action may be brought against each Guarantor to enforce this Guaranty whether or not the Borrower or any other person or entity is joined as a party.
Actions with Respect to Shared Collateral; Prohibition on Contesting Liens (a) With respect to any Shared Collateral, (i) only the Applicable Authorized Representative shall act or refrain from acting with respect to the Shared Collateral (including with respect to any intercreditor agreement with respect to any Shared Collateral), (ii) the Applicable Authorized Representative shall not follow any instructions with respect to such Shared Collateral (including with respect to any intercreditor agreement with respect to any Shared Collateral) from any Non-Controlling Authorized Representative and (iii) no Non-Controlling Authorized Representative or other Secured Party (other than the Applicable Authorized Representative) shall or shall instruct the Applicable Authorized Representative to, commence any judicial or nonjudicial foreclosure proceedings with respect to, seek to have a trustee, receiver, liquidator or similar official appointed for or over, attempt any action to take possession of, exercise any right, remedy or power with respect to, or otherwise take any action to enforce its security interest in or realize upon, or take any other action available to it in respect of, any Shared Collateral (including with respect to any intercreditor agreement with respect to any Shared Collateral), whether under any Security Document, applicable law or otherwise, it being agreed that only the Applicable Authorized Representative, acting on the instructions of the Secured Parties (other than any Non-Controlling Secured Parties) and in accordance with the applicable Security Documents, shall be entitled to take any such actions or exercise any such remedies with respect to Shared Collateral. Notwithstanding the equal priority of the Liens securing each Series of Obligations, the Applicable Authorized Representative may deal with the Shared Collateral as if such Applicable Authorized Representative had a senior Lien on such Collateral. No Non-Controlling Authorized Representative or Non-Controlling Secured Party will contest, protest or object to any foreclosure proceeding or action brought by the Applicable Authorized Representative or Controlling Secured Party or any other exercise by the Applicable Authorized Representative or Controlling Secured Party of any rights and remedies relating to the Shared Collateral, or to cause the Applicable Authorized Representative to do so. The foregoing shall not be construed to limit the rights and priorities of any Secured Party, Applicable Authorized Representative or Authorized Representative with respect to any Collateral not constituting Shared Collateral.
(b) Each of the Authorized Representatives agrees that it will not accept any Lien on any Collateral for the benefit of any Series of Obligations (other than funds deposited for the discharge or defeasance of any Additional Agreement) other than pursuant to the Security Documents and pursuant to Sections 2.05(c) or (j), 2.11(d) or (e) or 2.22 of the Credit Agreement, and by executing this Agreement (or a Joinder Agreement), each Authorized Representative and the Series of Secured Parties for which it is acting hereunder agree to be bound by the provisions of this Agreement and the other Security Documents applicable to it.
(c) Each of the Secured Parties agrees that it will not (and hereby waives any right to) contest or support any other Person in contesting, in any proceeding (including any Insolvency or Liquidation Proceeding), the perfection, priority, validity, attachment or enforceability of a Lien held by or on behalf of any of the Secured Parties in all or any part of the Collateral, or the provisions of this Agreement; provided that nothing in this Agreement shall be construed to prevent or impair the rights of any of the Applicable Authorized Representative or any Authorized Representative to enforce this Agreement.
Obligations with Respect to Loan Parties The obligations of the Borrower to direct or prohibit the taking of certain actions by the other Loan Parties as specified herein shall be absolute and not subject to any defense the Borrower may have that the Borrower does not control such Loan Parties.
Remedies; Disposition of the Collateral If any Event of Default shall have occurred and be continuing, then any Collateral repossessed by the Collateral Agent under or pursuant to Section 7.1 hereof and any other Collateral whether or not so repossessed by the Collateral Agent, may be sold, assigned, leased or otherwise disposed of under one or more contracts or as an entirety, and without the necessity of gathering at the place of sale the property to be sold, and in general in such manner, at such time or times, at such place or places and on such terms as the Collateral Agent may, in compliance with any mandatory requirements of applicable law, determine to be commercially reasonable. Any of the Collateral may be sold, leased or otherwise disposed of, in the condition in which the same existed when taken by the Collateral Agent or after any overhaul or repair at the expense of the relevant Assignor which the Collateral Agent shall determine to be commercially reasonable. Any such disposition which shall be a private sale or other private proceedings permitted by such requirements shall be made upon not less than 10 days' prior written notice to the relevant Assignor specifying the time at which such disposition is to be made and the intended sale price or other consideration therefor, and shall be subject, for the 10 days after the giving of such notice, to the right of the relevant Assignor or any nominee of such Assignor to acquire the Collateral involved at a price or for such other consideration at least equal to the intended sale price or other consideration so specified. Any such disposition which shall be a public sale permitted by such requirements shall be made upon not less than 10 days' prior written notice to the relevant Assignor specifying the time and place of such sale and, in the absence of applicable requirements of law, shall be by public auction (which may, at the Collateral Agent's option, be subject to reserve), after publication of notice of such auction (where required by applicable law) not less than 10 days prior thereto. The Collateral Agent may, without notice or publication, adjourn any public or private sale or cause the same to be adjourned from time to time by announcement at the time and place fixed for the sale, and such sale may be made at any time or place to which the sale may be so adjourned. To the extent permitted by any such requirement of law, the Collateral Agent may bid for and become the purchaser of the Collateral or any item thereof, offered for sale in accordance with this Section without accountability to the relevant Assignor. If, under mandatory requirements of applicable law, the Collateral Agent shall be required to make disposition of the Collateral within a period of time which does not permit the giving of notice to the relevant Assignor as hereinabove specified, the Collateral Agent need give such Assignor only such notice of disposition as shall be reasonably practicable in view of such mandatory requirements of applicable law. Each Assignor agrees to do or cause to be done all such other acts and things as may be reasonably necessary to make such sale or sales of all or any portion of the Collateral valid and binding and in compliance with any and all applicable laws, regulations, orders, writs, injunctions, decrees or awards of any and all courts, arbitrators or governmental instrumentalities, domestic or foreign, having jurisdiction over any such sale or sales, all at such Assignor's expense.
Accounts and Payments in Respect of General Intangibles (a) In addition to, and not in substitution for, any similar requirement in the Credit Agreement, if required by the Collateral Agent at any time during the continuance of (A) an Event of Default under clause (a) or clause (e)(ii) of Section 9.1 of the Credit Agreement or (B) any other Event of Default in connection with the exercise of remedies by the Administrative Agent pursuant to Section 9.2 of the Credit Agreement, (i) any payment of accounts or payment in respect of general intangibles, when collected by any Grantor, shall be promptly (and, in any event, within 2 Business Days) deposited by such Grantor in the exact form received, duly indorsed by such Grantor to the Collateral Agent, in a Security Cash Collateral Account, subject to withdrawal by the Collateral Agent as provided in Section 6.4, and (ii) until so turned over, such payment shall be held by such Grantor in trust for the Collateral Agent, segregated from other funds of such Grantor. Each such deposit of proceeds of accounts and payments in respect of general intangibles shall be accompanied by a report identifying in reasonable detail the nature and source of the payments included in the deposit.
(b) At any time during the continuance of (A) an Event of Default under clause (a) or clause (e)(ii) of Section 9.1 of the Credit Agreement or (B) any other Event of Default in connection with the exercise of remedies by the Administrative Agent pursuant to Section 9.2 of the Credit Agreement:
(i) each Grantor shall, upon the Collateral Agent’s request, deliver to the Collateral Agent all original and other documents evidencing, and relating to, the Contractual Obligations and transactions that gave rise to any account or any payment in respect of general intangibles, including all original orders, invoices and shipping receipts and notify account debtors that the accounts or general intangibles have been collaterally assigned to the Collateral Agent and that payments in respect thereof shall be made directly to the Collateral Agent; and
(ii) the Collateral Agent may, without notice, limit or terminate the authority of a Grantor to collect its accounts or amounts due under general intangibles or any thereof and, in its own name or in the name of others, communicate with account debtors to verify with them to the Collateral Agent’s satisfaction the existence, amount and terms of any account or amounts due under any general intangible. In addition, the Collateral Agent may (at the direction of the Administrative Agent) at any time enforce such Grantor’s rights against such account debtors and obligors of general intangibles.
(c) At any time during the continuance of an Event of Default, each Grantor shall take all actions, deliver all documents and provide all information necessary or reasonably requested by the Collateral Agent (at the direction of the Administrative Agent) to ensure any Internet Domain Name is registered.
(d) Anything herein to the contrary notwithstanding, each Grantor shall remain liable under each account and each payment in respect of general intangibles to observe and perform all the conditions and obligations to be observed and performed by it thereunder, all in accordance with the terms of any agreement giving rise thereto. No Secured Party shall have any obligation or liability under any agreement giving rise to an account or a payment in respect of a general intangible by reason of or arising out of any Loan Document or the receipt by any Secured Party of any payment relating thereto, nor shall any Secured Party be obligated in any manner to perform any obligation of any Grantor under or pursuant to any agreement giving rise to an account or a payment in respect of a general intangible, to make any payment, to make any inquiry as to the nature or the sufficiency of any payment received by it or as to the sufficiency of any performance by any party thereunder, to present or file any claim, to take any action to enforce any performance or to collect the payment of any amounts that may have been assigned to it or to which it may be entitled at any time or times.
Obligations of the Consultant Conduct of the Services
