Obligations relating to Inter-Connection Sample Clauses

Obligations relating to Inter-Connection. 6.2.1 In consideration of this Agreement and the applicable charges, the covenants and warranties on the part of the Concessionaire herein contained, MOR, in accordance with the terms and conditions set forth herein, hereby grants to the Concessionaire, commencing from [180 (one hundred and eighty days)] days prior to Scheduled Completion Date, leave and licence rights in respect of the land owned by MOR for the purpose of connecting the Rail System to [nearest existing Station or existing rail head] (“Railway Land”), and for no other purpose whatsoever. In consideration of the grant of leave and licence rights in respect of the Railway Land, the Concessionaire shall pay to MOR a sum of Re.1 (Rupee one) per annum. In the event of delay for any reason other than Force Majeure or breach of this Agreement by the Concessionaire, and only if the Independent Engineer determines that the Concessionaire is unable to achieve COD on account of the delay or denial of Right of Way to any part of the Railway Land, MOR shall pay to the Concessionaire, Damages in a sum calculated at the rate of Rs. [1,000] per day of delay and until such Right of Way is granted.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Obligations relating to Inter-Connection. 6.2.1 In consideration of this Agreement and the applicable charges, the covenants and warranties on the part of the SPD herein contained, Railways, in accordance with the terms and conditions set forth herein, hereby grants to the SPD, commencing from [180 (one hundred and eighty days)] days prior to Scheduled Commercial Operation Date, leave and rights in respect of the land/ rooftops owned by Railways for the purpose of connecting the rooftop solar project to [nearest existing evacuation point] (“rooftop”), and for no other purpose whatsoever.
Sample 1Sample 2
Obligations relating to Inter-Connection. 5.2.1 In consideration of this Agreement and the applicable charges, the covenants and warranties on the part of the Developer herein contained, MOR, in accordance with the terms and conditions set forth herein, hereby grants to the Developer, commencing from the Effective Date, leave and licence rights, Right of Way in respect of the land owned by MOR for the purpose of connecting the Rail System to [nearest existing Station or existing rail head] (“Railway Land”), and for no other purpose whatsoever. In consideration of the grant of leave and licence rights in respect of the Railway Land, the Developer shall pay to MOR a sum of Re.1 (Rupee one) per annum. In the event of delay for any reason other than Force Majeure or breach of this Agreement by the Developer, and only if the Independent Engineer determines that the Developer is unable to achieve COD on account of the delay or denial of Right of Way to any part of the Railway Land, MOR shall pay to the Developer, Damages in a sum calculated at the rate of Rs. [1,000] per day of delay and until such Right of Way is granted.
Sample 1Sample 2
Obligations relating to Inter-Connection. 6.2.1 In consideration of this Agreement and the applicable charges, the covenants and warranties on the part of the SPD herein contained, Railways, in accordance with the terms and conditions set forth herein, hereby grants to the SPD, commencing from 180 (one hundred and eighty days) days prior to Scheduled Commercial Operation Date, leave and rights in respect of the land/ rooftops owned by Railways for the purpose of connecting the rooftop solar project to sub-station i.e. nearest existing evacuation point (“rooftop”), and for no other purpose whatsoever, within the timelines given in schedule N.
Sample 1
Obligations relating to Inter-Connection. The Concessionaire shall enter into and comply with agreements for interconnection of the Transmission System to the grid, sub-stations, licensees or consumers, as the case may be, under and in accordance with Applicable Laws.
Sample 1

Related to Obligations relating to Inter-Connection

  • Obligations relating to Project Agreements 5.2.1 It is expressly agreed that the Concessionaire shall, at all times, be responsible and liable for all its obligations under this Agreement notwithstanding anything contained in the Project Agreements or any other agreement, and no default under any Project Agreement or agreement shall excuse the Concessionaire from its obligations or liability hereunder.

  • Participating TO Obligations The Participating TO shall maintain the Participating TO’s Transmission System and the Participating TO’s Interconnection Facilities in a safe and reliable manner and in accordance with this LGIA.

  • Obligations relating to Change in Ownership 5.3.1 The Concessionaire shall not undertake or permit any Change in Ownership, except with the prior approval of the Authority.

  • CAISO and Participating TO Obligations The CAISO and Participating TO shall cause the Participating TO’s Transmission System to be operated and controlled in a safe and reliable manner and in accordance with this LGIA. The Participating TO at the Interconnection Customer’s expense shall cause the Participating TO’s Interconnection Facilities to be operated, maintained and controlled in a safe and reliable manner and in accordance with this LGIA. The CAISO and Participating TO may provide operating instructions to the Interconnection Customer consistent with this LGIA and Participating TO and CAISO operating protocols and procedures as they may change from time to time. The Participating TO and CAISO will consider changes to their operating protocols and procedures proposed by the Interconnection Customer.

  • Other Provisions Relating to the Grievance Procedure 1. No reprisal of any kind shall be taken by or against any participant in the grievance procedure by reason of such participation.

  • FEES AND EXPENSES RELATING TO SERVICES 15.1 In consideration of the provision of the Services, Transnet will pay to the Service Provider the Fees detailed in the relevant schedule or Work Order.

  • INDEMNIFICATION RELATING TO INTELLECTUAL PROPERTY Contractor shall indemnify and hold the Department and the State of Utah harmless from and against any and all damages, expenses (including reasonable attorneys' fees), claims, judgments, liabilities, and costs in any action or claim brought against the Department or the State of Utah for infringement of a third party’s copyright, trademark, trade secret, or other proprietary right. The parties agree that if there are any limitations of Contractor’s liability, such limitations of liability will not apply to this section.

  • Agreements Relating to Sentencing 10. The government agrees to recommend that the Court impose a sentence of imprisonment within the applicable guidelines range and to make no further recommendation concerning what sentence of imprisonment should be imposed.

  • Our Liability for Failing to Make Transfers If we do not complete a transaction to or from the Card on time or in the correct amount according to our Agreement with you, we may be liable for your losses or damages. However, there are some exceptions. We will not be liable, for instance:

  • OBJECTING TO THE SETTLEMENT You can tell the Court that you do not agree with the Settlement or some part of it.

Time is Money Join Law Insider Premium to draft better contracts faster.