LICENSES AND STANDARDS 11 CONTRACTOR warrants that it and its personnel, described in Paragraph 27 of 12 this Agreement, who are subject to individual registration and/or licensing requirements, have all 13 necessary licenses and permits required by the laws of the United States, State of California 14 (hereinafter referred to as “State”), County of Orange, and all other appropriate governmental 15 agencies to perform the services described in this Agreement, and agrees to maintain, and require 16 its personnel to maintain, these licenses and permits in effect for the duration of this Agreement.
Design Criteria and Standards All Projects/Services shall be performed in accordance with instructions, criteria and standards set forth by the Director.
Specifications and Standards a) All articles supplied shall strictly conform to the specifications, trademark laid down in the bidding document and wherever articles have been required according to ISI/ ISO/ other applicable specifications/ certifications/ standards, those articles should conform strictly to those specifications/ certifications/ standards. The supply shall be of best quality and description. The decision of the competent authority/ purchase committee whether the articles supplied conforms to the specifications shall be final and binding on the supplier/ selected bidder.
Design Standards Most recent edition of the “Owner’s Design Standards,” including any partial updates as may be directed by the Owner.
Property Standards Owner must maintain the Unit, and any common areas of the property accessible to the Tenant under the Lease, in decent, safe and sanitary condition and comply with all applicable state or local codes and requirements for rental properties. Upon notice by the Program Administrator following any inspection (whether conducted in-person or virtually in accordance with the Program guidelines), Owner will promptly correct any violations of Program requirements and this Contract. If the Owner fails to correct such violations, the Program Administrator may terminate this Contract and the Rental Assistance Payment even if the Tenant continues occupancy under the Lease. Owner/Representative Initials:
Ordinances and Statutes Lessee shall comply with all statutes, ordinances and requirements of all municipal, state and federal authorities now in force, or which may hereafter be in force, pertaining to the premises, occasioned by or affecting the use thereof by Lessee.
Condition of Improvements The risk of destruction or substantial damage by fire or Act of God prior to delivery of deed is assumed by Seller. Xxxxxx agrees that on possession, the Real Estate shall be in the same condition as it is on the date of this contract, except for ordinary wear and tear. If the Real Estate should be damaged or destroyed by fire or other casualty and if, prior to Closing, the real Estate shall not be repaired or restored by and at the Sellers expense, to a condition as good as it was prior to the damage or destruction, then Purchaser, at his option, may terminate this contract by written notice to Seller and the Down Payment Shall be returned to Purchaser. While this contract is pending, Sellers shall not change any existing lease or enter into any new lease, nor make any substantial alterations or repairs without the consent of the Purchaser. In addition, the Purchaser also has an insurable interest in the property from date of this contract. Purchaser is hereby notified that insurance should be placed upon the property immediately to protect Purchasers’ interest.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians. (ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked. (iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority. (iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Ownership of Improvements All modifications, alterations and improvements made or added to the Leased Premises by Tenant (other than Tenant’s inventory, equipment, movable furniture, wall decorations and trade fixtures) shall be deemed real property and a part of the Leased Premises, but shall remain the property of Tenant during the Lease, and Tenant hereby covenants and agrees not to grant a security interest in any such items to any party other than Landlord. Any such modifications, alterations or improvements, once completed, shall not be altered or removed from the Leased Premises during the Lease Term without Landlord’s written approval first obtained in accordance with the provisions of Paragraph 6.1 above. At the expiration or sooner termination of this Lease, all such modifications, alterations and improvements other than Tenant’s inventory, equipment, movable furniture, wall decorations and trade fixtures, shall automatically become the property of Landlord and shall be surrendered to Landlord as part of the Leased Premises as required pursuant to Article 2, unless Landlord shall require Tenant to remove any of such modifications, alterations or improvements in accordance with the provisions of Article 2, in which case Tenant shall so remove same. Landlord shall have no obligations to reimburse Tenant for all or any portion of the cost or value of any such modifications, alterations or improvements so surrendered to Landlord. All modifications, alterations or improvements which are installed or constructed on or attached to the Leased Premises by Landlord and/or at Landlord’s expense shall be deemed real property and a part of the Leased Premises and shall be property of Landlord. All lighting, plumbing, electrical, heating, ventilating and air conditioning fixtures, partitioning, window coverings, wall coverings and floor coverings installed by Tenant shall be deemed improvements to the Leased Premises and not trade fixtures of Tenant.
Regulatory Requirements and Governing Law 43 14.1 Regulatory Requirements. 43 14.2 Governing Law 44 ARTICLE 15. NOTICES 44 15.1 General. 44 15.2 Xxxxxxxx and Payments. 44 15.3 Alternative Forms of Notice 44 15.4 Operations and Maintenance Notice 44 ARTICLE 16. FORCE MAJEURE 45 16.1 Force Majeure 45 ARTICLE 17. DEFAULT 45 17.1 Default. 45 ARTICLE 18. INDEMNITY, CONSEQUENTIAL DAMAGES AND INSURANCE 46 18.1 Indemnity. 46 18.2 No Consequential Damages. 47 18.3 Insurance 47 ARTICLE 19. ASSIGNMENT 49 19.1 Assignment. 49 ARTICLE 20. SEVERABILITY 49 20.1 Severability. 49 ARTICLE 21. COMPARABILITY 50 21.1 Comparability. 50 ARTICLE 22. CONFIDENTIALITY 50 22.1 Confidentiality. 50 ARTICLE 23. ENVIRONMENTAL RELEASES 53 23.1 Developer and Connecting Transmission Owner Notice 53 ARTICLE 24. INFORMATION REQUIREMENT 53 24.1 Information Acquisition. 53 24.2 Information Submission by Connecting Transmission Owner 54 24.3 Updated Information Submission by Developer 54 24.4 Information Supplementation 54 ARTICLE 25. INFORMATION ACCESS AND AUDIT RIGHTS 55 25.1 Information Access. 55 25.2 Reporting of Non-Force Majeure Events. 55 25.3 Audit Rights. 56 25.4 Audit Rights Periods. 56 25.5 Audit Results. 56 ARTICLE 26. SUBCONTRACTORS 56 26.1 General. 56 26.2 Responsibility of Principal. 57 26.3 No Limitation by Insurance 57 ARTICLE 27. DISPUTES 57 27.1 Submission 57 27.2 External Arbitration Procedures. 57 27.3 Arbitration Decisions. 58 27.4 Costs. 58 27.5 Termination 58 ARTICLE 28. REPRESENTATIONS, WARRANTIES AND COVENANTS 58 28.1 General. 58 ARTICLE 29. MISCELLANEOUS 59 29.1 Binding Effect. 59 29.2 Conflicts. 59 29.3 Rules of Interpretation 59 29.4 Compliance 60 29.5 Joint and Several Obligations. 60 29.6 Entire Agreement. 60 29.7 No Third Party Beneficiaries. 60 29.8 Waiver 60 29.9 Headings. 61 29.10 Multiple Counterparts. 61 29.11 Amendment. 61 29.12 Modification by the Parties. 61 29.13 Reservation of Rights. 61 29.14 No Partnership 62 29.15 Other Transmission Rights. 62 Appendices STANDARD LARGE GENERATOR INTERCONNECTION AGREEMENT THIS STANDARD LARGE GENERATOR INTERCONNECTION AGREEMENT
