Service Level Expectations Without limiting any other requirements of the Agreement, the Service Provider shall meet or exceed the following standards, policies, and guidelines:
Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Indemnity Limitation for TIPS Sales Texas and other jurisdictions restrict the ability of governmental entities to indemnify others. Vendor agrees that if any "Indemnity" provision which requires the TIPS Member to indemnify Vendor is included in any TIPS sales agreement/contract between Vendor and a TIPS Member, that clause must either be stricken or qualified by including that such indemnity is only permitted, "to the extent permitted by the laws and constitution of [TIPS Member's State]” unless the TIPS Member expressly agrees otherwise. Any TIPS Sale Supplemental Agreement containing an "Indemnity" clause that conflicts with these terms is rendered void and unenforceable.
Required Coverages For Generation Resources Of 20 Megawatts Or Less Each Constructing Entity shall maintain the types of insurance as described in section 11.1 paragraphs (a) through (e) above in an amount sufficient to insure against all reasonably foreseeable direct liabilities given the size and nature of the generating equipment being interconnected, the interconnection itself, and the characteristics of the system to which the interconnection is made. Additional insurance may be required by the Interconnection Customer, as a function of owning and operating a Generating Facility. All insurance shall be procured from insurance companies rated “A-,” VII or better by AM Best and authorized to do business in a state or states in which the Interconnection Facilities are located. Failure to maintain required insurance shall be a Breach of the Interconnection Construction Service Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Free Look Period The free look period shall be applicable at the inception of the policy and:
Innovative/Flexible Scheduling Where the Hospital and the Union agree, arrangements regarding Innovative Scheduling/Flexible Scheduling may be entered into between the parties on a local level. The model agreement with respect to such scheduling arrangements is set out below: MODEL AGREEMENT WITH RESPECT TO INNOVATIVE SCHEDULING/FLEXIBLE SCHEDULING MEMORANDUM OF AGREEMENT Between: The Hospital - And: The Ontario Public Service Employees Union (and its Local ) This Model Agreement shall be part of the Collective Agreement between the parties herein, and shall apply to the employees described in Article 1 of the Model Agreement.
How Do I Correct an Excess Contribution? If you make a contribution in excess of your allowable maximum, you may correct the excess contribution and avoid the 6% penalty tax for that year by withdrawing the excess contribution and its earnings on or before the date, including extensions, for filing your tax return for the tax year for which the contribution was made (generally October 15th). Any earnings on the withdrawn excess contribution may also be subject to the 10% early distribution penalty tax if you are under age 59½. In addition, although you will still owe penalty taxes for one or more years, excess contributions may be withdrawn after the time for filing your tax return. Excess contributions for one year may be carried forward and applied against the contribution limitation in succeeding years. An individual who is partially or entirely ineligible to make contributions to a Xxxx XXX may transfer amounts of up to the yearly contribution limits to a non-deductible Traditional IRA (subject to reduction for amounts remaining in the Xxxx XXX plus other Traditional IRA contributions).
Refund after Scaling Completed Any cash deposit, in excess of that required to meet charges under B4.2, shall be refunded or transferred within 15 days of Purchaser’s request after Scaling is completed, except for amounts estimated to be required under B9.5. B4.3 Payment Guaranteed by Xxxx or Deposited Securities. To guarantee payment, Purchaser may fur- nish and maintain an acceptable surety bond or deposit in a Federal Depository negotiable securities of the United States. The securities shall be deposited through the Re- gional Fiscal Agent accompanied by a power of attorney and agreement authorizing the bond-approving officer to sell or collect such securities if payment is not made within 15 days of billing by Forest Service. The penal sum of such surety bond or the market value at time of deposit of such negotiable securities shall be the maximum amount of the payment guaranteed. For payment purposes, penal sum of the surety bond or market value at time of deposit of negotiable securities shall be in lieu of the performance bond furnished under B9.1.
