Minimum Orders Client may order Manufacturing Services for batches of Products only in multiples of the Minimum Order Quantities as set out in Schedule B to a Product Agreement.
Minimum Vendor License Requirements Vendor shall maintain, in current status, all federal, state, and local licenses, bonds and permits required for the operation of the business conducted by Vendor. Vendor shall remain fully informed of and in compliance with all ordinances and regulations pertaining to the lawful provision of goods or services under the TIPS Agreement. TIPS and TIPS Members reserve the right to stop work and/or cancel a TIPS Sale or terminate this or any TIPS Sale Supplemental Agreement involving Vendor if Vendor’s license(s) required to perform under this Agreement or under the specific TIPS Sale have expired, lapsed, are suspended or terminated subject to a 30‐day cure period unless prohibited by applicable statue or regulation.
Coverage Minimum Requirement Commercial General Liability Insurance, including Bodily Injury, Personal Injury, Property Damage, Advertising Injury, and Medical Payments Each Occurrence General Aggregate $ 1,000,000 $ 2,000,000 Automobile Liability Insurance - Any Auto Each Occurrence General Aggregate $ 1,000,000 $ 2,000,000 Professional Liability $ 1,000,000 Workers Compensation Statutory Limits Employer’s Liability $ 1,000,000
Coverage Minimum Limits Commercial General Liability $1,000,000 per occurrence $2,000,000 aggregate Automobile Liability including coverage for owned, non-owned and hired vehicles $1,000,000 per occurrence
MINIMUM ORDER QUANTITY The State makes no commitment to purchase any minimum or maximum quantity, or dollar volume of products from the selected suppliers. Utilization of this agreement will be on an as needed basis by State Agencies and/or Cooperative Participants, Cities, Counties, Schools K-12, Colleges and Universities. The State will award to multiple suppliers; however, the State reserves the right to purchase like and similar products from other suppliers as necessary to meet operational requirements.
Minimum Requirements Consultant shall, at its expense, procure and maintain for the duration of the Agreement insurance against claims for injuries to persons or damages to property which may arise from or in connection with the performance of the Agreement by the Consultant, its agents, representatives, employees or subconsultants. Consultant shall also require all of its subconsultants to procure and maintain the same insurance for the duration of the Agreement. Such insurance shall meet at least the following minimum levels of coverage:
Minimum Order When the Government requires supplies or services covered by this contract in an amount of less than one each, the Government is not obligated to purchase, nor is the Contractor obligated to furnish those supplies or services under the contract.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Minimum Tangible Net Worth The Parent and the Borrower shall not permit Tangible Net Worth at any time to be less than (i) $731,508,263 plus (ii) 75% of the Net Proceeds of all Equity Issuances effected at any time after the Agreement by the Parent, the Borrower or any of the Subsidiaries of the Parent to any Person other than the Parent, the Borrower or any of the Subsidiaries of the Parent.
