Contract Deliverables The Contractor shall provide information technology staff augmentation services, including comprehensive management of staff, as set forth in this Contract. The term “staff” refers to the temporary staff provided by the Contractor to render information technology services identified by Customers, but that staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks. Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. The Department’s intent is for Contractor’s information technology staff to provide services closely related to those described in the Job Family Descriptions document. Detailed scopes of work, specific requirements of the work to be performed, and any requirements of staff shall be provided by the Customer in a Request for Quote. The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified information technology staff to perform the services requested by the Customer. The Contractor shall provide Customers with staff who must have sufficient skill and experience to perform the services assigned to them. All of the information technology staff augmentation services to be furnished by the Contractor under the Contract shall meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances. The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market. The Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of staff. The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s information technology staff. The Contractor shall maintain during the term of the Contract all licenses, permits, qualifications, insurance and approvals of whatever nature that are legally required to perform the information technology staff augmentation services.
Purchaser Deliverables The Purchaser shall have delivered its Purchaser Deliverables in accordance with Section 2.2(b).
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Delivery Date the date (or period) for delivery of the Goods or Services as specified and agreed in the Contract.
Project Delivery Contractor shall construct the Project in accordance with the Contract Documents, and Contractor shall deliver the Project completed in accordance with the Contract Documents, substantially free from defects, and within the Contract Time.
Delayed Delivery Contracts If the Prospectus provides for sales of Offered Securities pursuant to Delayed Delivery Contracts, the Company hereby authorizes the Underwriters to solicit offers to purchase Contract Securities on the terms and subject to the conditions set forth in the Prospectus pursuant to Delayed Delivery Contracts. Delayed Delivery Contracts may be entered into only with institutional investors approved by the Company of the types set forth in the Prospectus. On the Closing Date, the Company will pay to the Manager as compensation for the accounts of the Underwriters the commission set forth in the Underwriting Agreement in respect of the Contract Securities. The Underwriters will not have any responsibility in respect of the validity or the performance of any Delayed Delivery Contracts. If the Company executes and delivers Delayed Delivery Contracts with institutional investors, the aggregate amount of Offered Securities to be purchased by the several Underwriters shall be reduced by the aggregate amount of Contract Securities; such reduction shall be applied to the commitment of each Underwriter pro rata in proportion to the amount of Offered Securities set forth opposite such Underwriter's name in the Underwriting Agreement, except to the extent that the Manager determines that such reduction shall be applied in other proportions and so advises the Company; provided, however, that the total amount of Offered Securities to be purchased by all Underwriters shall be the aggregate amount set forth above, less the aggregate amount of Contract Securities.
Purchasers Deliverables Such Purchaser shall have delivered its Purchaser Deliverables in accordance with Section 2.2(b).
Post-Closing Deliverables (a) Within ten (10) days of the Closing Date, Seller and/or Seller’s Affiliates shall give any notices required to be given under the Material Contracts in connection with the consummation of the Transaction and shall further provide to Purchaser at Closing with true and complete copies of such notices. From and following the date of this Agreement, Seller and the Company shall use commercially reasonable efforts to (i) obtain any consents or authorizations required under the terms of the Material Contracts in connection with the consummation of the Transaction and (ii) prepare the documents to be executed pursuant to Section 2.2(e) as required under the terms of the Material Contracts in connection with the consummation of the Transaction. If, as of Closing (i) any notice has not been given or any authorization or consent has not been obtained under the terms of the Contracts included in the Assets (including as may be required under the terms of the Assumed Contracts in connection with the consummation of the Transaction) or (ii) any conveyance or assignment documents required to vest title to all Owned Real Property and easements in the Company have not been executed prior to Closing, in each case other quitclaim deeds with respect to Owned Office Properties as specifically required to be delivered at Closing in accordance with Section 2.2(e), notwithstanding anything in this Agreement to the contrary, such failure shall not give rise to any right to indemnification under Article IX.
(b) Seller shall (i) for twelve (12) months following the Closing Date, use commercially reasonable efforts to, as and when requested by Purchaser, give any notice that has not been given or obtain any authorization or consent that has not been obtained prior to the Closing that is required under the terms of the Contracts included in the Assets (including as may be required under the terms of the Assumed Contracts in connection with the consummation of the Transaction) and (ii) as soon as practicable following Closing (but no more than 90 days following Closing), deliver to Purchaser an accurate list and description of all Owned Real Property and execute and deliver to Purchaser all real estate conveyance documents required to vest title to all Owned Real Property and easements in the Company (to the extent not previously delivered at Closing). Following Closing, until such required notices are given or such required consents are obtained or such documents are executed, Seller agrees to enter into a commercially reasonable alternative arrangement to provide (and cause its Affiliates to provide, as applicable), the Company and Purchaser’s Affiliates with the benefits (e.g., in respect of any applicable Sign Location Lease, the right to operate the Structures on the property covered thereby) to which such notice or consent relates, including by enforcing at the written request of Purchaser (and at Purchaser’s sole cost and expense) any of the rights under such Contract (including the right of termination); and to the extent the Company (or Purchaser’s Affiliate) receives such benefits (or Seller enforces any rights under such Contract at Purchaser’s written request), Purchaser shall be responsible for the performance of the Seller’s obligations thereunder, at Purchaser’s sole cost and expense, acting in good faith and in the ordinary course of business. If within the twelve (12) month period following the Closing Date (aa) either Party (or their Affiliates) receives written notice from a landowner or counterparty (or counsel for the landowner or counterparty) purporting to terminate a particular Sign Location Lease which is a Material Contract or a Bus Transit Contract, as a result of the failure to obtain a consent required by the terms of such lease or Bus Transit Contract, or (bb) any such landlord or counterparty files suit (or initiates arbitration, if applicable) against either Party (or their respective Affiliates) seeking termination of the applicable Sign Location Lease or Bus Transit Contract, as a result of the failure to obtain a consent required by the terms of such lease or Bus Transit Contract, or (cc) any such landowner or counterparty requires payment of a material sum or some other material concession from the Company in exchange for any such required consent (and in the case of a demand for a material sum of money, where Seller elects to not pay such amount upon request of the Company), then in each such instance, the Company or Purchaser may within ten days following the expiration of such twelve month period (or such later period as provided below) by written notice to Seller either (i) elect to relinquish all of its right, title and interest in and to such Sign Location Lease or Bus Transit Contract, as applicable (and any Assets solely related thereto), to Seller, in which case the Purchaser shall be entitled to a payment from Seller in an amount equal to that portion of the Purchase Price allocable to such item or asset, which shall be based on a multiple equal to the product of 7.1 times net revenues less site lease expense for calendar year 2014; or (ii) elect to retain such rights over the item or asset, in which case there would be no such payment to the Company or Purchaser, as applicable; provided, however, that (x) Purchaser shall upon request by Seller, assist and cooperate with Seller in effecting the commercially reasonable alternative arrangement referred to above and in obtaining the applicable required consent, and (y) before Purchaser shall have the right to exercise its rights under subpart (i) above, Seller shall have the right (at Seller’s sole cost) to defend any such action by a landlord or counterparty and/or to negotiate a settlement and/or cure any alleged breach of the applicable lease or Bus Transit Contract and so long as Seller is diligently doing so, Seller shall have until the expiration of the following periods to cure or settle such matter (i) if Purchaser is still permitted to operate at such location during the pendency of such matter, until such matter is finally adjudicated or (ii) if Purchaser is not permitted to operate at such location during the pendency of such matter and Seller elects not to replace the lost net cash flow at such location during the pendency of such matter, a two (2) month period from the date Purchaser is first not able to operate at such location (provided, further, that, in the case of both (i) and (ii) above, if Purchaser in good faith determines that the Company or Purchaser’s applicable Affiliate could reasonably be expected to be subject to liability to such landlord or counterparty by continuing to operate such asset, Purchaser may require that Seller confirm in writing to Purchaser Seller’s duty to defend and indemnify Purchaser with respect thereto, including but not limited to damages for trespass, where applicable). Purchaser acknowledges that failure to timely notify Seller of such an election in accordance with the foregoing shall be deemed an acceptance by Purchaser of such Sign Location Lease or Bus Transit Contract, as applicable and related Assets and a relinquishment of any right to payment from Seller. For the avoidance of doubt, any amounts that may become due to Purchaser (or the Company) under this paragraph shall not be subject to the limitations set forth in Section 9.2(c).
(c) As soon as practicable following the Closing (but no later than 90 days following Closing), Seller shall deliver to Purchaser Outdoor Advertising Permit transfer documents as are required to validly and fully transfer and assign all such Permits to the Company (or Purchaser’s designated Affiliate).
Seller Deliverables At the Closing, Seller shall deliver, or cause to be delivered (each, a “Seller Deliverable”, and, collectively, the “Seller Deliverables”):
i. to PropCo Purchaser, all agreements, documents, instruments, certificates and other deliverables required to be delivered by the Selling Entities or Real Estate Sellers, as applicable, at or prior to the Closing pursuant to Section 5(a) of the Real Estate Purchase Agreement, in each case, duly executed by the applicable Selling Entities or Real Estate Sellers;
ii. to OpCo Purchaser, an IRS Form W-9 duly executed by each applicable Selling Entity (or, with respect to each Selling Entity that is a disregarded entity for U.S. federal income tax purposes, the regarded owner of such Selling Entity for U.S. federal income tax purposes);
iii. to OpCo Purchaser, stock or other applicable ownership certificates representing all of the outstanding OpCo Acquired Interests; iv. to OpCo Purchaser, the Intellectual Property License, duly executed by the applicable Selling Entities;
v. to OpCo Purchaser, the Transition Services Agreement, duly executed by the applicable Selling Entities, if applicable;
vi. to OpCo Purchaser, control of all keys, codes, combinations, and/or passwords to the machinery, equipment, trucks and automobiles at, on or in the Premises, to the extent in the possession of the applicable Selling Entities;
vii. to OpCo Purchaser, written resignations, effective as of the Closing Date, of all directors and members of the board of directors, board of managers or similar governing body, and officers of each OpCo Acquired Company;
viii. to OpCo Purchaser, the Seller Financing Loan Agreement, duly executed by Seller; ix. to each of OpCo Purchaser and PropCo Purchaser, the Contingent Lease Support Agreement, duly executed by Seller; x. to OpCo Purchaser, an aggregate amount of cash equal to the Reserve Amount (as defined in the Contingent Lease Support Agreement);
xi. to the Title Company, title affidavits in the forms attached hereto as Exhibit I, as well as any other affidavit, indemnity, certificate or instrument reasonably required by the Title Company in order to effectuate the issuance of the Title Policy subject only to Permitted Liens; and xii. to each of OpCo Purchaser and PropCo Purchaser, as applicable, each of the other Ancillary Agreements, duly and validly executed by the parties thereto other than OpCo Purchaser or PropCo Purchaser.
Purchaser Deliveries At the Closing, Purchaser shall deliver to Seller:
(a) The Assignment and Assumption Agreement;
(b) Purchaser’s acceptance of its appointment as successor trustee or custodian, as applicable, of the XXX and Xxxxx Accounts included in the Deposits and assumption of the fiduciary obligations of the trustee or custodian with respect thereto, as contemplated by Section 2.4;
(c) The Branch Lease Assignments and such other instruments and documents as any landlord under a Branch Lease may reasonably require as necessary or desirable for providing for the assumption by Purchaser of a Branch Lease, each such instrument and document in form and substance reasonably satisfactory to the parties and dated as of the Closing Date;
(d) The Tenant Assignments and such other instruments and documents as any subtenant under a Tenant Lease may reasonably require as necessary or desirable for providing for the assumption by Purchaser of a Tenant Lease, each such instrument and document in form and substance reasonably satisfactory to the parties and dated as of the Closing Date;
(e) The Equipment Lease Assignments and such other instruments and documents as any lessor under an Equipment Lease may reasonably require as necessary or desirable for providing for the assumption by Purchaser of an Equipment Lease, each such instrument and document in form and substance reasonably satisfactory to the parties and dated as of the Closing Date;
(f) The Assumed Contract Assignments and such other instruments and documents as any party under an Assumed Contract may reasonably require as necessary or desirable for providing for the assumption by Purchaser of an Assumed Contract, each such instrument and document in form and substance reasonably satisfactory to the parties and dated as of the Closing Date;
(g) The Loan Documents Assignment and such other instruments and documents as Seller may reasonably require as necessary or desirable for providing for the assumption by Purchaser of the Loan Documents, each such instrument and document in form and substance reasonably satisfactory to the parties and dated as of the Closing Date; and
(h) The certificate required to be delivered by Purchaser pursuant to Section 9.2(e).
