Other Accounts in the Construction Fund Sample Clauses

Other Accounts in the Construction Fund. (a) The Trustee shall distribute amounts in the Pre-Opening Expenses Account to or to the order of the Pre-Opening Services Manager upon receipt by the Trustee of a Requisition executed by the Pre-Opening Services Manager in the form attached hereto as Exhibit D (“Pre-Opening Requisition”) to pay the Pre-Opening Expenses for the Hotel in accordance with the Pre-Opening Services Agreement. No later than six months after the Opening Date, the Pre-Opening Services Manager is required under the terms of the Pre-Opening Services Agreement to notify the Commission and the Trustee of the amount of Pre-Opening Expenses that remain unpaid. All amounts in excess of such amount shall be transferred by the Trustee to the Debt Service Reserve Fund. Upon the earlier to occur of (i) no moneys remaining on deposit in the Pre-Opening Expenses Account, and (ii) five years after the Opening Date, the Trustee shall close the Pre-Opening Expenses Account, and shall transfer all amounts, if any, remaining therein to the Debt Service Reserve Fund. (b) Except as otherwise provided by Supplemental Trust Agreement or in Section 9.04, prior to the Opening Date, the Trustee shall transfer amounts in the Hotel Account and the Pre-Opening Expenses Account of the Construction Fund at the Direction of the Commission to the Debt Service Account and apply such amounts to the payment of principal of and interest on the Bonds when due, as required by Section 5.07(a); provided, that with respect to the Guaranteed Fixed Price of the Hotel, the Project Manager and the Design-Builder and, with respect to the Pre-Opening Expenses only, the Pre-Opening Services Manager, each shall first certify to the Trustee that the amounts remaining in the Hotel Account and in the Pre- Opening Expenses Account, as the case may be, after such transfer are sufficient to pay all of the remaining Guaranteed Fixed Price of the Hotel and Pre-Opening Expenses, respectively. (c) Amounts in the Preliminary Operating Capital Account shall be used to pay the initial Operating Expenses of the Hotel, including any prepayment of Operating Expenses requested in writing by the Manager in its reasonable discretion. Upon receipt of written notice from the Manager that the Opening Date of the Hotel is scheduled to occur within seven days, the Trustee shall transfer an amount equal to the Xxxxx Cash Amount to the Manager from the amounts on deposit in the Preliminary Operating Capital Account and shall transfer the remaining amoun...
Sample 1
AutoNDA by SimpleDocs

Related to Other Accounts in the Construction Fund

  • Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.

  • Audit Rights Period for Construction-Related Accounts and Records Accounts and records related to the design, engineering, procurement, and construction of Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades shall be subject to audit for a period of twenty-four months following Connecting Transmission Owner’s issuance of a final invoice in accordance with Article 12.2 of this Agreement.

  • Deposits in the Escrow Account During the Escrow Period, persons subscribing to purchase Shares will be instructed by the Company, the Dealer Manager and the Selected Dealers to make checks for subscriptions payable to the order of “UMB Bank, N.A., as Escrow Agent for Terra Income Fund 6, Inc.” When a Selected Dealer’s internal supervisory procedures are conducted at the site at which the subscription agreement and check were initially received by the Selected Dealer from the subscriber, the Selected Dealer shall transmit the subscription agreement and check to the Escrow Agent by the end of the next business day following receipt of the check and subscription agreement. When, pursuant to the Selected Dealer’s internal supervisory procedures, the Selected Dealer’s final internal supervisory procedures are conducted at a different location (the “Final Review Office”), the Selected Dealer shall transmit the check and subscription agreement to the Final Review Office by the end of the next business day following the Selected Dealer’s receipt of the subscription agreement and check. The Final Review Office will, by the end of the next business day following its receipt of the subscription agreement and check, forward both the subscription agreement and check to the Escrow Agent. If any subscription agreement solicited by the Selected Dealer is rejected by the Dealer Manager or the Company, then the subscription agreement and check will be returned to the rejected subscriber within ten business days from the date of rejection. The Escrow Agent shall have no liability or responsibility regarding a Selected Dealer’s internal supervisory procedures. Completed subscription agreements and checks in payment for the purchase price shall be remitted to the Escrow Agent’s address in Exhibit B designated for the receipt of such agreements and funds, and wires or Automated ClearingHouse (ACH) payments shall be transmitted directly to the Escrow Account. Subscription agreements received by the Escrow Agent shall be scanned and emailed by the Escrow Agent to DST Systems, Inc. the "Transfer Agent") within 24 hours of receipt by the Escrow Agent. The Escrow Agent shall also deliver the original subscription agreements to the Transfer Agent. Deposits shall be held in the Escrow Account until such funds are disbursed in accordance with this Agreement. Prior to disbursement of the funds deposited in the Escrow Account (the "Escrowed Funds"), such funds shall not be subject to claims by creditors of the Company or any of its affiliates. If any of the instruments of payment are returned to the Escrow Agent for nonpayment prior to receipt of the Break Escrow Affidavit (as described below), the Escrow Agent shall promptly notify the Company in writing via mail, email or facsimile of such nonpayment, and the Escrow Agent is authorized to debit the Escrow Account in the amount of such returned payment and the Escrow Agent shall delete the appropriate account from the records maintained by the Escrow Agent. The Escrow Agent will maintain a written account of each sale, which account shall set forth, among other things, the following information: (i) the subscriber’s name and address, (ii) the subscriber’s social security number or tax identification number, (iii) the number of Shares purchased by such subscriber, (iv) the amount paid by such subscriber for such Shares and (v) the state of residence. During the Escrow Period, neither the Company nor the Dealer Manager will be entitled to any principal funds received into the Escrow Account.

  • Establishment of Escrow Accounts; Deposits in Escrow Accounts The Company shall segregate and hold all funds collected and received pursuant to each Mortgage Loan which constitute Escrow Payments separate and apart from any of its own funds and general assets and shall establish and maintain one or more Escrow Accounts. The Escrow Account shall be an Eligible Account. Funds deposited in each Escrow Account shall at all times be insured in a manner to provide maximum insurance under the insurance limitations of the FDIC, or must be invested in Permitted Investments. Funds deposited in the Escrow Account may be drawn on by the Company in accordance with Section 4.07. The creation of any Escrow Account shall be evidenced by a letter agreement in the form shown in Exhibit C. The original of such letter agreement shall be furnished to the Purchaser on the Closing Date, and upon request to any subsequent purchaser. The Company shall deposit in the Escrow Account or Accounts on a daily basis, and retain therein: (i) all Escrow Payments collected on account of the Mortgage Loans, for the purpose of effecting timely payment of any such items as required under the terms of this Agreement; (ii) all Insurance Proceeds which are to be applied to the restoration or repair of any Mortgaged Property; and (iii) all Servicing Advances for Mortgagors whose Escrow Payments are insufficient to cover escrow disbursements. The Company shall make withdrawals from the Escrow Account only to effect such payments as are required under this Agreement, and for such other purposes as shall be as set forth or in accordance with Section 4.07. The Company shall be entitled to retain any interest paid on funds deposited in the Escrow Account by the depository institution other than interest on escrowed funds required by law to be paid to the Mortgagor and, to the extent required by law, the Company shall pay interest on escrowed funds to the Mortgagor notwithstanding that the Escrow Account is non-interest bearing or that interest paid thereon is insufficient for such purposes. The Purchaser shall not be responsible for any losses suffered with respect to investment of funds in the Escrow Account.

  • Establishment of Escrow Account; Deposits in Escrow Account With respect to those Mortgage Loans on which the Servicer or any Sub-Servicer collects Escrow Payments, if any, the Servicer shall, and shall cause the Sub-Servicer to, segregate and hold all funds collected and received pursuant to each such Mortgage Loan which constitute Escrow Payments separate and apart from any of its own funds and general assets and shall establish and maintain one or more Escrow Accounts, in the form of trust accounts. Such Escrow Accounts shall be established with a commercial bank, a mutual savings bank or a savings and loan association the deposits of which are insured by the FDIC in a manner which shall provide maximum available insurance thereunder, and which may be drawn on by the Servicer. The Servicer shall give notice to the Trustee of the location of any Escrow Account, and of any change thereof, prior to the use thereof. Nothing in this paragraph shall be deemed to require the Servicer to collect Escrow Payments in the absence of a provision in the related Mortgage requiring such collection. The Servicer shall deposit, or cause to be deposited, in any Escrow Account or Accounts on a daily basis, and retain therein, (i) all Escrow Payments collected on account of any Mortgage Loans, for the purpose of effecting timely payment of any such items as required under the terms of this Agreement and (ii) all amounts representing proceeds of any hazard insurance policy which are to be applied to the restoration or repair of any Mortgaged Property. The Servicer shall make withdrawals therefrom only to effect such payments as are required under this Agreement, and for such other purposes as are set forth in Section 5.11. The Servicer shall be entitled to retain any interest paid on funds deposited in the Escrow Account by the depository institution other than interest on escrowed funds required by law to be paid to the related Mortgagor and, to the extent required by law, the Servicer shall pay interest on escrowed funds to the related Mortgagor notwithstanding that the Escrow Account is non-interest-bearing or that interest paid thereon is insufficient for such purposes.

  • Establishment of and Deposits to Escrow Account The Company shall segregate and hold all funds collected and received pursuant to a Mortgage Loan constituting Escrow Payments separate and apart from any of its own funds and general assets and shall establish and maintain one or more Escrow Accounts, in the form of time deposit or demand accounts, titled, "Countrywide Home Loans Inc., in trust for the Purchaser of Conventional Residential Mortgage Loans, and various Mortgagors". The Escrow Accounts shall be established with a Qualified Depository, in a manner which shall provide maximum available insurance thereunder. Funds deposited in the Escrow Account may be drawn on by the Company in accordance with Section 4.07. The creation of any Escrow Account shall be evidenced by a certification in the form of Exhibit E-1 hereto, in the case of an account established with the Company, or by a letter agreement in the form of Exhibit E-2 hereto, in the case of an account held by a depository other than the Company. A copy of such certification shall be furnished to the Purchaser and, upon request, to any subsequent Purchaser. The Company shall deposit in the Escrow Account or Accounts within two Business Days of receipt, and retain therein: (i) all Escrow Payments collected on account of the Mortgage Loans, for the purpose of effecting timely payment of any such items as required under the terms of this Agreement; and (ii) all amounts representing Insurance Proceeds or Condemnation Proceeds which are to be applied to the restoration or repair of any Mortgaged Property. The Company shall make withdrawals from the Escrow Account only to effect such payments as are required under this Agreement, as set forth in Section 4.07. The Company shall be entitled to retain any interest paid on funds deposited in the Escrow Account by the depository institution, other than interest on escrowed funds required by law to be paid to the Mortgagor. To the extent required by law, the Company shall pay interest on escrowed funds to the Mortgagor notwithstanding that the Escrow Account may be non-interest bearing or that interest paid thereon is insufficient for such purposes.

  • No Construction Loans No Mortgage Loan was made in connection with (i) the construction or rehabilitation of a Mortgage Property or (ii) facilitating the trade-in or exchange of a Mortgaged Property other than a construction-to-permanent loan which has converted to a permanent Mortgage Loan;

  • Maintenance of Accounts and Records Tenant shall keep true records and books of account of Tenant in which full, true and correct entries will be made of dealings and transactions in relation to the business and affairs of Tenant in accordance with GAAP. Tenant shall apply accounting principles in the preparation of the financial statements of Tenant which, in the judgment of and the opinion of its independent public accountants, are in accordance with GAAP, where applicable, except for changes approved by such independent public accountants. Tenant shall provide to Landlord either in a footnote to the financial statements delivered under Section 17.2 which relate to the period in which such change occurs, or in separate schedules to such financial statements, information sufficient to show the effect of any such changes on such financial statements.

  • General Construction 20.2.1. Binding Nature.............................................. 20.2.2. Entire Agreement............................................ 20.2.3. Governing Law............................................... 20.2.4. Indulgences Not Waivers..................................... 20.2.5. Titles Not to Affect Interpretation......................... 20.2.6.

  • Contract Construction 6.27.1 The parties acknowledge that each party and its counsel have reviewed this CONTRACT and that the normal rule of construction to the effect that any ambiguities are to be resolved against the drafting party shall not be employed in the interpretation of this CONTRACT or any amendment or exhibits hereto.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!