Overruns; Qualified Overruns Sample Clauses

Overruns; Qualified Overruns. At any time during the performance of any Reimbursable Replacement, Reimbursable Structural Work or Reimbursable Legal Requirement Alteration, Tenant may give notice (an "Overrun Notice") to Landlord specifying any cost (an "Overrun") in excess of the Base Cost which Tenant expects to incur and which Tenant contends was unforeseeable by Tenant at the time of commencement of the work (each Overrun Notice to specify the nature of, and reasons for, the Overrun in question in reasonably complete and specific detail). Within 10 business days after receipt of an Overrun Notice, Landlord shall notify Tenant as to whether or not in Landlord's judgment the Overrun in question is reasonable in amount under the circumstances and was unforeseeable by Tenant at the time of commencement of the work. If Tenant shall dispute Landlord's judgment, the reasonableness of the amount of, and the foreseeability by Tenant of, the Overrun in question shall be determined by the Appropriate Engineer. Any Overrun determined by Landlord or the Appropriate Engineer to be reasonable in amount under the circumstances and unforeseeable by Tenant at the time of commencement of the work shall be a "Qualified Overrun".
AutoNDA by SimpleDocs

Related to Overruns; Qualified Overruns

  • Cost Overruns The Borrower shall ensure that all cost-overruns over the estimated construction costs of the Project as certified by a quantity surveyor or the Architect or as ascertained by the Lender as and when they occur shall be funded by the Borrower’s own equity;

  • Project Cost Overruns In the event that the Recipient determines that the moneys granted pursuant to Section II hereof, together with the Local Subdivision Contribution, are insufficient to pay in full the costs of the Project, the Recipient may make a request for supplemental assistance to its District Committee. The Recipient must demonstrate that such funding is necessary for the completion of the Project and the cost overrun was the result of circumstances beyond the Recipient's control, that it could not have been avoided with the exercise of due care, and that such circumstances could not have been anticipated at the time of the Recipient's initial application. Should the District Committee approve such request the action shall be recorded in the District Committee's official meeting minutes and provided to the OPWC Director for the execution of an amendment to this Agreement.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.

  • Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.

  • Construction Budget The total amount of funds indicated by the District for the entire Project plus all other costs, including design, construction, administration, and financing.

  • Project Overview Project Title [Drafting note: ARENA to complete. Insert full long name in accordance with ARENA’s naming convention] i.e. [GMS Number] [Powerworks, voltage control on the Pacific Islands Study] [GMS Number] [study/ project/ fellowship/ scholarship/ R&D Project] Contract Number [Drafting note: ARENA to complete – to be obtained from ARENA’s GMS] Recipient [Drafting note: Recipient to insert full legal name and ABN] Guidelines and policies Advancing Renewables Program – Program Guidelines, 2020 (xxxxx://xxxxx.xxx.xx/xxxxxx/0000/00/XXXXX_XXX_Xxxxxxxxxx_XX_Xxxxxx_Xxxxx_XXXXX.xxx) ARENA Variation Policy (xxxxx://xxxxx.xxx.xx/xxxxxx/0000/00/xxxxx-xxxxxxx-xxxxxxxxx-xxxxxxxxx-xxxxxx.xxx) ARENA Report Writing Guidelines (xxxxx://xxxxx.xxx.xx/xxxxxx/0000/00/xxxxx-xxxxxx-xxxxxxx-xxxxxxxxxx.xxx)

  • Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain. (b) Employees shall not be required to start a concrete pour in Inclement Weather. (c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear. (d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay. (e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.

  • Development Budget Attached hereto as Exhibit "B" and incorporated herein by this reference is the Development Budget in an amount equal to $_____________. Owner acknowledges and represents that the attached Development Budget includes the total costs and expenses to acquire, develop, renovate and construct the Real Property and the Apartment Housing.

  • Capital Budget Any amendment that is mutually agreed upon shall be set forth in writing and signed by both parties. It is acknowledged by Owner that capital expenditures required as a result of an emergency situation shall not reduce amounts available pursuant to the Capital Budget or otherwise hereunder, other than to the extent a Capital Budget item is subsumed within the capital expenditures required as a result of the occurrence of the emergency;

  • Construction Cost Budget The total cost to District of all elements of the Project designed or specified by the Architect, as adjusted at the end of each design phase in accordance with this Agreement. The Construction Cost Budget does not include the compensation of the Architect and the Architect’s Consultants, the cost of land, rights-of-way, financing or other costs which are the responsibility of the District, including construction management.

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!