Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing.
2.1.2 The Train Operator may serve a Suspension Notice where a Network Rail Event of Default has occurred and is continuing.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT.
B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate.
B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner.
B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment.
B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
Owner’s Right to Make Changes Without invalidating the Contract, the Owner, by Change Order and without notice to the sureties, may authorize or order extra work or changes by altering, adding to, or deducting from the Work or the Contract Time, the Contract Sum being adjusted accordingly. All Change Orders shall be performed under the conditions of the original Contract except that any claim for extension of time caused thereby shall be adjusted at the time of signing of the Change Order. (See Change Order formats in Section 7.) Prior to the issuance of the Proceed Order, the Contractor and the Owner shall advise each other in writing of their designees authorized to accept and approve changes to the Contract Sum and the limits to each designee's authority. Should any designee or limits of authority change during the time this Contract is in effect, the Contractor or Owner shall give written notice to the other as provided in Article 1.
BUYER’S RIGHT TO CANCEL If after completion of an appraisal by a licensed appraiser, Buyer receives written notice from the Lender or the appraiser that the Property has appraised for less than the Purchase Price (a “Notice of Appraised Value”), Buyer may cancel the REPC by providing written notice to Seller (with a copy of the Notice of Appraised Value) no later than the Financing & Appraisal Deadline referenced in Section 24(c); whereupon the Xxxxxxx Money Deposit shall be released to Buyer without the requirement of further written authorization from Seller.
Landlord’s Right to Enter Landlord and its agents shall have the right to enter the Leased Premises during normal business hours after giving Tenant reasonable notice and subject to Tenant’s reasonable security measures for the purpose of (i) inspecting the same; (ii) showing the Leased Premises to prospective purchasers, mortgagees or tenants; (iii) making necessary alterations, additions or repairs; and (iv) performing any of Tenant’s obligations when Tenant has failed to do so. Landlord shall have the right to enter the Leased Premises during normal business hours (or as otherwise agreed), subject to Tenant’s reasonable security measures, for purposes of supplying any maintenance or services agreed to be supplied by Landlord. Landlord shall have the right to enter the Outside Areas during normal business hours for purposes of (i) inspecting the exterior of the Building and the Outside Areas; (ii) posting notices of nonresponsibility (and for such purposes Tenant shall provide Landlord at least thirty days’ prior written notice of any work to be performed on the Leased Premises); and (iii) supplying any services to be provided by Landlord. Any entry into the Leased Premises or the Outside Areas obtained by Landlord in accordance with this paragraph shall not under any circumstances be construed or deemed to be a forcible or unlawful entry into, or a detainer of, the Leased Premises, or an eviction, actual or constructive of Tenant from the Leased Premises or any portion thereof.
LANDLORD'S RIGHT OF ENTRY Tenant agrees to permit Landlord and the authorized representatives of Landlord and of Lender to enter upon the Demised Premises at all reasonable times for the purposes of inspecting the Demised Premises and Tenant's compliance with this Lease, and making any necessary repairs thereto; provided that, except in the case of an emergency, Landlord shall give Tenant reasonable prior notice of Landlord's intended entry upon the Demised Premises. Nothing herein shall imply any duty upon the part of Landlord to do any work required of Tenant hereunder, and the performance thereof by Landlord shall not constitute a waiver of Tenant's default in failing to perform it. Landlord shall not be liable for inconvenience, annoyance, disturbance or other damage to Tenant by reason of making such repairs or the performance of such work in the Demised Premises or on account of bringing materials, supplies and equipment into or through the Demised Premises during the course thereof, and the obligations of Tenant under this Lease shall not thereby be affected; provided, however, that Landlord shall use reasonable efforts not to disturb or otherwise interfere with Tenant's operations in the Demised Premises in making such repairs or performing such work. Landlord also shall have the right upon reasonable notice to enter the Demised Premises at all reasonable times to exhibit the Demised Premises to any prospective purchaser or mortgagee thereof, or, during the last six (6) months of the Term, to any prospective tenant thereof.
LESSOR'S RIGHT OF ENTRY The Lessor or the Lessor's agent may enter at reasonable hours to inspect or show the Premises to prospective lenders and purchasers, and to do anything the Lessor may be required to do hereunder or which the Lessor may deem necessary for the good of the Premises or any building of which they are apart. During the last [#] days of the Term, the Lessor may display a "For Rent" sign on the Premises and show the Premises to prospective lessees.
Landlord’s Right to Cure If Landlord breaches any of its obligations under this Lease, Tenant shall notify Landlord in writing and shall take no action respecting such breach so long as Landlord promptly begins to cure the breach and diligently pursues such cure to its completion. Landlord may cure any default by Tenant; any expenses incurred shall become Additional Rent due from Tenant on demand by Landlord.